Rights Reserved. The MCC reserves the right to authorize an amendment to this Contract, terminate the Contract, and/or purchase materials, supplies, equipment and/or services from the best available source during the time of force majeure, and Contractor shall have no recourse against the Purchaser or Participating Entity.
Rights Reserved. The WSIB reserves the right to cancel the Contract and/or to obtain or purchase services from the best available source during the time of Force Majeure, and the Contractor shall have no recourse against the WSIB.
Rights Reserved. The Purchasing Activity reserves the right to authorize an amendment to this Contract, terminate the Contract, and/or purchase materials, supplies, equipment and/or services from the best available source during the time of force majeure, and Contractor shall have no recourse against the State.
Examples of Rights Reserved in a sentence
Rights Reserved: The County reserves the right to cancel the contract and/or purchase materials, equipment or services from the best available source during the time of force majeure, and Contractor shall have no recourse against the County.
So far as consistent with the Rights Reserved below, the time of completion shall be extended by Contract amendment for a period of time equal to the time that the results or effects of such delay prevented the delayed party from performing in accordance with this Contract.
Rights Reserved: The City reserves the right to cancel the Agreement and/or purchase materials, equipment or services from the best available source during the time of force majeure, and Contractor shall have no recourse against the City.
Rights Reserved: The Purchasing Activity reserves the right to authorize an amendment to this Contract, terminate the Contract, and/or purchase materials, supplies, equipment and/or services from the best available source during the time of force majeure, and Contractor shall have no recourse against the State.
Rights Reserved: The City reserves the right to cancel the Contract and/or purchase materials, goods or services from the best available source during the time of force majeure, and Supplier shall have no recourse against the City.
More Definitions of Rights Reserved
Rights Reserved. DES reserves the right to authorize an Amendment to this Master Contract, terminate this Master Contract, and/or purchase Products and/or Services from the best available source during the time of force majeure, and Contractor shall have no recourse against DES and/or Purchaser.
Rights Reserved. The Purchasing Activity reserves the right to authorize an amendment to this Contract, terminate the Contract, and/or purchase materials, supplies, equipment and/or services from the best available source during the time of force majeure, and Contractor shall have no recourse against the State. ALTERNATIVE DISPUTE RESOLUTION FEES AND COSTS In the event that the parties engage in arbitration, mediation or any other alternative dispute resolution forum to resolve a dispute in lieu of litigation, both parties shall share equally in the cost of the alternative dispute resolution method, including cost of mediator or arbitrator. In addition, each party shall be responsible for its own attorneys’ fees incurred as a result of the alternative dispute resolution method. NON-EXCLUSIVE REMEDIES The remedies provided for in this Contract shall not be exclusive but are in addition to all other remedies available under law. LIQUIDATED DAMAGES
Rights Reserved. The WSLCB reserves the right to authorize an amendment to this Agreement, which shall be agreed to, in writing, by both the WSLCB and the Supplier. Either party may request termination of the Agreement during the time of force majeure.
Rights Reserved. The Purchasing Activity reserves the right to authorize an amendment to this Contract, terminate the Contract, and/or purchase materials, supplies, equipment and/or services from the best available source during the time of force majeure, and Contractor shall have no recourse against the State. ALTERNATIVE DISPUTE RESOLUTION FEES AND COSTS In the event that the parties engage in arbitration, mediation or any other alternative dispute resolution forum to resolve a dispute in lieu of litigation, both parties shall share equally in the cost of the alternative dispute resolution method, including cost of mediator or arbitrator. In addition, each party shall be responsible for its own attorneys’ fees incurred as a result of the alternative dispute resolution method. NON-EXCLUSIVE REMEDIES The remedies provided for in this Contract shall not be exclusive but are in addition to all other remedies available under law. LIMITATION OF LIABILITY The parties agree that neither Contractor, Purchasing Activity nor Purchaser shall be liable to each other, regardless of the form of action, for consequential, incidental, indirect, or special damages except a claim related to bodily injury or death, or a claim or demand based on patent, copyright, or other intellectual property right infringement, in which case liability shall be as set forth elsewhere in this Contract. This section does not modify any sections regarding liquidated damages or any other conditions as are elsewhere agreed to herein between the parties. The damages specified in the sections titled Termination for Default and Retention of Records are not consequential, incidental, indirect, or special damages as that term is used in this section. Neither the Contractor, the Purchasing Activity nor Purchaser shall be liable for damages arising from causes beyond the reasonable control and without the fault or negligence of the Contractor, the Purchasing Activity or Purchaser. Such causes may include, but are not restricted to, acts of God or of the public enemy, acts of a governmental body other than the Purchasing Activity or the Purchaser acting in either its sovereign or contractual capacity, war, explosions, fires, floods, earthquakes, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather; but in every case the delays must be beyond the reasonable control and without fault or negligence of the Contractor, the Purchasing Activity or the Purchaser, or their respective Subc...
Rights Reserved. Ranch Hand reserves the right to make changes in design, specifications, and material as deemed necessary without prior notice and without assuming obligation to modify any product previously manufactured.
Rights Reserved. WSDOT Rail Division reserves the right to authorize an amendment to this Ordering Agreement, terminate the Ordering Agreement, and/or purchase materials, supplies, equipment and/or services from the best available source during the time of force majeure, and Contractor shall have no recourse against the State.
Rights Reserved. The Principal reserves notwithstanding, any thing herein contained the following rights. The Representative acknowledges that The Principal shall have the right to promote, solicit and provide the Services directly or indirectly in the Territory or any other part of the world.