Soft Construction Costs definition

Soft Construction Costs as used herein shall mean the actual, out-of-pocket costs incurred by Tenant in connection with the Tenant Improvements Work and other matters related to Tenant’s taking occupancy of the Premises including, without limitation, permitting, architectural, engineering and design fees, space planning. “Labor and Materials Limitation” as used herein shall mean the costs for free-standing furnishings, fixtures, equipment and other personal property.
Sample 1Sample 2
Soft Construction Costs means all engineering costs associated with the Project and the commissions and expenses involved in obtaining the Performance Bonds, as defined below, and premiums for insurance required of Construction Manager under Section 12.2
Sample 1
Soft Construction Costs means building/land acquisition, architectural, engineering, design, consultant, legal, accounting, developer fees as well as interest reserve, working capital, furniture, and equipment. State means the State of Iowa.
Sample 1

Examples of Soft Construction Costs in a sentence

  • No more than Three Hundred Ten Thousand and No/100 Dollars ($310,000.00) of the 2nd Floor East Premises Related Allowance (i.e., $35.00 per rentable square foot of the 2nd Floor East Premises) may be applied toward hard construction costs and/or Soft Construction Costs on the Interconnecting Stair and/or tenant improvements on the third floor portion of the Premises.

  • The construction of the Minimum Improvements will require a total investment of approximately $5,000,000, which includes $3,500,000 for Hard Construction Costs and $1,500,000 for Soft Construction Costs.

  • The total NVI score was highly correlated to CFQ score (R=0.84, P<0.002) and moderately correlated to the DHI (r=0.51, p<0.002).

  • Article 1 of the lease defines project costs as ‘‘the sum of (a) the Acquisition Costs, (b) the Hard Construction Costs, (c) the Soft Construction Costs, and (d) the Financing Costs.’’ The calculation of monthly rent to be paid by Talecris to Wintermans involves a two-step process: (1) project costs are multiplied by 90% to arrive at ‘‘base rent’’; 8 and (2) base rent is multiplied by 125% and then divided by 12 to arrive at monthly rent.

  • Total construction costs are expected to be a minimum of $5,000,000, which includes $3,500,000 for Hard Construction Costs and $1,500,000 for Soft Construction Costs.

  • Developer agrees that the scope and scale of the Minimum Improvements to be constructed shall not be significantly less than the scope and scale of the Minimum Improvements as detailed and outlined in the Construction Plans, and shall require a total investment of approximately Five Million Dollars ($5,000,000), which includes $3,500,000 for Hard Construction Costs and $1,500,000 for Soft Construction Costs.

  • Construction Costs - The Hard & Soft Construction Costs as shown on that line item of the Unit Loan Budget for each Unit.

  • The City encourages Contractors to diversify their subcontractor utilization of COBID firms from all available divisions of work.• Twenty percent (20%) of Soft Construction Costs or Professional Services for subcontract utilization of COBID firms on projects subject to the Program.

Related to Soft Construction Costs

  • Direct Construction Cost shall have the meaning set forth in Article 11.

  • Construction Costs means any and all costs incurred by the Contractor with respect to the construction and equipping, as the case may be, of the improvements performed, whether paid or incurred prior to or after the date hereof, including, without limitation, costs for Site preparation, the removal or demolition of existing structures, the construction of the Project and related facilities and improvements, and all other work in connection therewith, security of the Site and Project, Contractors’ overhead and supervision at the Project Site, all costs and expenses including any taxes or insurance premiums paid by the Contractor with respect to the Property, and administrative and other expenses necessary or incident to the Project, excluding Contractors’ and Developers’ home office overhead and profit. The term “Construction Costs” includes all Contractor’s costs associated with preparing or generating additional copies of any Construction Documents, as defined below, related to or required for the Project, including preparation or generation of additional Plans and/or Specifications for Contractor’s Subcontractors. In no event shall Construction Costs exceed the Guaranteed Maximum Price.

  • Estimated Construction Cost or “ECC” means the amount calculated by Contractor for the total cost of all elements of the Work based on this Agreement available at the time(s) that the ECC is prepared. The ECC shall be based on current market rates with reasonable allowance for overhead, profit and price escalation and shall include and consider, without limitation, all alternates and contingencies, designed and specified by A/E and the cost of labor and materials necessary for installation of Owner furnished equipment. The ECC shall include all the cost elements included in the AACC, as defined above, and shall represent Contractor’s best current estimate of the Guaranteed Maximum Price it will propose for the Project based on the information then available. The ECC shall not include Contractor’s Pre-Construction Phase Fee, A/E’s Fees, the cost of the land and rights-of-way, or any other costs that are the direct responsibility of Owner.

  • Construction Cost means and includes the cost of the entire construction of the Project, including all supervision, materials, supplies, labor, tools, equipment, transportation and/or other facilities furnished, used or consumed, without deduction on account of penalties, liquidated damages or other amounts withheld from payment to the contractor or contractors, but such cost shall not include the Consulting Engineer/Architect's fee, or other payments to the Consulting Engineer/Architect and shall not include cost of land or Rights-of-Way and Easement acquisition.

  • Soft Costs means the costs of professional work and fees, interim costs, financing fees and expenses, syndication costs, soft costs and Developer’s fees as shown in the Applicant’s properly completed UniApp, Section C - Uses of Funds. Soft Costs do not include operating or replacement reserves.

  • New construction means, for the purposes of determining insurance rates, structures for which the "start of construction" commenced on or after the effective date of an initial FIRM or after December 31, 1974, whichever is later, and includes any subsequent improvements to such structures. For floodplain management purposes, "new construction" means structures for which the "start of construction" commenced on or after the effective date of the floodplain management regulations adopted by a community and includes any subsequent improvements to such structures.

  • Erection, construction, remodeling, repairing means all types of work done on a particular building or work at the site thereof in the construction or development of the project, including without limitation, erecting, construction, remodeling, repairing, altering, painting, and decorating, the transporting of materials and supplies to or from the building or work done by the employees of the Contractor, Subcontractor, or Agent thereof, and the manufacturing or furnishing of

  • Building construction means any physical activity on the site involved in the erection of a structure, cladding, external finish, formwork, fixture, fitting of service installation and the unloading of plant, machinery, materials or the like.

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Construction and Demolition Debris means and includes:

  • Residential construction means construction on single-family or two-family dwellings occupied or used, or intended to be occupied or used, primarily for residential purposes, and includes real property pursuant to chapter 499B.

  • Original construction means the first or initial construction

  • Construction Fee means a fee or other remuneration for acting as general contractor and/or construction manager to construct improvements, supervise and coordinate projects or provide major repairs or rehabilitations on a Property.

  • The constructional plant means all appliances, tools, plants or machinery or whatsoever nature required in or about the execution, completion or maintenance of the works but does not include materials or other things intended to form part of the permanent work.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • Existing construction means any structure for which the "start of construction" commenced before the effective date of the initial floodplain management code or ordinance adopted by the community as a basis for that community's participation in the NFIP.

  • Construction Budget means the cost of acquisition, installation, testing, constructing and developing any Property as determined by the Construction Agent in its reasonable, good faith judgment.

  • Construction Work means any work in connection with⎯

  • construction site means a workplace where construction work is being performed;

  • Construction Zone shall have the meaning set forth in Clause 8.3 (i);

  • Construction Phase means that Phase of the Project which shall commence after the Authority provides the Trade Contractor with written Notice to Proceed with the Construction Phase.

  • Construction and demolition waste means waste from building materials, debris and rubble resulting from construction, remodeling, repair and demolition operations;

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;

  • Pipeline Construction means a substantial disturbance to agricultural land associated with installation, replacement, removal, operation or maintenance of a pipeline, but shall not include work performed during an emergency. Emergency means a condition where there is clear and immediate danger to life or health, or essential services, or a potentially significant loss of property. When the emergency condition ends, pipeline construction will be in accordance with these rules.

  • Commence Construction means that an owner or operator has either undertaken a continuous program of construction or has entered into a contractual obligation to undertake and complete, within a reasonable time, a continuous program of construction.

  • Interconnection Construction Service Agreement means the agreement entered into by an Interconnection Customer, Interconnected Transmission Owner and the Transmission Provider pursuant to Tariff, Part VI, Subpart B and in the form set forth in Tariff, Attachment P, relating to construction of Attachment Facilities, Network Upgrades, and/or Local Upgrades and coordination of the construction and interconnection of an associated Customer Facility. A separate Interconnection Construction Service Agreement will be executed with each Transmission Owner that is responsible for construction of any Attachment Facilities, Network Upgrades, or Local Upgrades associated with interconnection of a Customer Facility.