Premises Building Partial Damage means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is less than fifty percent (50%) of the then Replacement Cost of the building.
Premises Partial Damage means damage or destruction to the Premises, other than Lessee-Owned Alterations and Utility Installations, the repair cost of which damage or destruction is less than fifty percent (50%) of the then Replacement Cost (as defined in Paragraph 9.1(d)) of the Premises (excluding Lessee-Owned Alterations and Utility Installations and Trade Fixtures) immediately prior to such damage or destruction.
Major Damage means damage that in the estimation of the surveyor exceeds USD
Structural damage means a covered building, regardless of the date of its construction, has experienced the following.
Direct Damage has the meaning given to it in clause 26.2;
Environmental Damage means any material injury or damage to persons, living organisms or property or any material pollution or impairment of the environment resulting from the discharge, emission, escape or migration of any substance, energy, noise or vibration;
Loss or Damage means any loss or damage to the Vehicle, including that caused by theft of the Vehicle or by adverse weather events, that requires repair or replacement including the loss of use of the Vehicle (demurrage), legal expenses, assessment fees, towing and recovery costs, storage, service charges and any appraisal fees of the Vehicle;
Accidental Damage means physical damage, breakage or failure of Your Covered Equipment due to an unforeseen and unintentional event occurring either due to handling (e.g., dropping the Covered Equipment or through liquid contact) or due to an external event (e.g., extreme environmental or atmospheric conditions). The damage must affect the functionality of Your Covered Equipment, which includes cracks to the display screen that affect the visibility of the display.
Catastrophic Damage as used hereunder is major change or damage to In- cluded Timber on Sale Area, to Sale Area, to access to Sale Area, or a combination thereof:
Substantial damage means damage of any origin sustained by a structure whereby the cost of restoring the structure to its before damaged condition would equal or exceed 50 percent of the market value of the structure before the damage occurred.
Tenant’s Property means Removable Installations and, other than Installations, any personal property or equipment of Tenant that may be removed without material damage to the Premises, and (z) “Installations” means all property of any kind paid for by Landlord, all Alterations, all fixtures, and all partitions, hardware, built-in machinery, built-in casework and cabinets and other similar additions, equipment, property and improvements built into the Premises so as to become an integral part of the Premises, including, without limitation, fume hoods which penetrate the roof or plenum area, built-in cold rooms, built-in warm rooms, walk-in cold rooms, walk-in warm rooms, deionized water systems, glass washing equipment, autoclaves, chillers, built-in plumbing, electrical and mechanical equipment and systems, and any power generator and transfer switch.
Tenant Party means any of the following persons: Tenant; any assignees claiming by, through, or under Tenant; any subtenants claiming by, through, or under Tenant; and any of their respective agents, contractors, employees, licensees, guests and invitees.
Severe property damage means substantial physical damage to property, damage to the treatment facilities which would cause them to become inoperable, or substantial and permanent loss of natural resources which can reasonably be expected to occur in the absence of a bypass. Severe property damage does not mean economic loss caused by delays in production.
Property damage means physical injury to, destruction of, or loss of use of tangible property.
Landlord Party or “Landlord Parties” shall mean Landlord, any affiliate of Landlord, Landlord’s managing agents for the Building, each mortgagee (if any), each ground lessor (if any), and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents or representatives. For the purposes of this Lease, the term “Tenant Party” or “Tenant Parties” shall mean Tenant, any affiliate of Tenant, any permitted subtenant or any other permitted occupant of the Premises, and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents, invitees or representatives.
Work loss means loss of income from work the injured victim would have performed if the injured victim had not been injured and expenses reasonably incurred by the injured victim in obtaining services in lieu of those the injured victim would have performed for income,
Tenant Parties means Tenant, any affiliate of Tenant, any permitted subtenant or any other permitted occupant of the Premises, and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents, invitees or representatives.
Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.
Landlord Parties means Landlord and Property Manager and their respective officers, directors, partners, shareholders, members and employees.
Tenant Delays means (A) Tenant’s request for changes to Landlord’s Work, regardless of whether any such changes are performed, (B) construction of any such changes, (C) Tenant’s request for materials, finishes, or installations requiring unusually long lead times that were not originally included as a part of Landlord’s Work, (D) Tenant’s delay (which shall mean more than 5 business days) in reviewing, revising, or approving any plans and specifications relating to Landlord’s Work, (E) Tenant’s delay in providing information critical to the normal progression of the Project (Tenant shall provide such information as soon as reasonably possible, but in no event longer than 5 business days after receipt of any request for such information from Landlord), and (F) any other act or omission by Tenant or any Tenant Party (as defined herein), or persons employed by any of such persons, (iv) “Substantially Completed” means the substantial completion of Landlord’s Work (A) in a good and workmanlike manner, (B) in accordance with the requirements described in Exhibit C, and (C) in accordance with all applicable Legal Requirements (including, but not limited to, securing the applicable final building inspection for Landlord’s Work), subject only to normal “punch list” items, and (v) “Existing Tenant Delay” means the refusal or failure by the Existing Tenant (as defined below) to surrender the Premises by July 1, 2010 in accordance with the terms and conditions of the Existing Lease (as defined below). Landlord will promptly perform such punch list items. Tenant shall obtain, at its sole cost and expense, any applicable use and occupancy permit for the Premises issued by the applicable Governmental Authority. If Tenant does not elect to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. If neither Landlord nor Tenant elects to void this Lease within 5 business days of the lapse of such 60 day period, such right to void this Lease shall be waived and this Lease shall remain in full force and effect. Sequoia Pharmaceuticals, Inc. (“Existing Tenant”), is currently leasing the Premises from Landlord, and the lease agreement (“Existing Lease”) between Landlord and Existing Tenant is scheduled to expire on July 1, 2010 subject to Landlord’s right to advance the expiration date. Tenant understands, acknowledges, and agrees that Landlord makes no guaranty, representation, or assurance that Landlord will be able to recapture the Premises from the Existing Tenant by July 1, 2010 and that Landlord shall have no obligation or duty to seek the vacation or removal of the Existing Tenant from the Premises.
Physical Damage means tangible damage to a Property that materially adversely affects the use, marketability, or value of the Property, whether caused by accident or otherwise, including, but not limited to damage caused by reason of fire, destruction of tangible property, defects in construction, land subsidence, earth movement or slippage, flood, earthquake, war, civil insurrection, or riot; and further, Physical Damage includes Environmental Impairment and the destruction or removal of chattel items that are considered part of the Property (see Section I., KK., [Property]) For purposes of this definition "material" shall mean an amount equal to or greater than $1,500.00 such that the estimated cost to repair a Property is $1,500.00 or more before the exclusion set forth in Section III., G., (Physical Damage Exclusion) would apply to exclude coverage for a Loan. The presence of radon gas, lead paint or asbestos in the dwelling on the Property shall not be deemed to be Physical Damage.
Tenant Delay means an actual delay in the occurrence of the Substantial Completion Date or the Final Completion Date with respect to Landlord’s Work as the result of:
(1) any unreasonable delay by Tenant in approving the Plans;
(2) any request by Tenant that Landlord delay the commencement or completion of Landlord’s Work for any reason;
(3) any request by Tenant to change the Plans after initial approval thereof by Tenant, or the making of any changes to Landlord’s Work requested by Tenant and agreed to by Landlord after initial approval of the Plans by Tenant;
(4) any failure by Tenant to respond in writing within seven (7) business days after any written request by Landlord for clarification or interpretation of the Plans or for approval of changes in the Plans deemed necessary by Landlord; or
(5) any other act or omission of Tenant or its officers, agents, employees or contractors; Notwithstanding the foregoing, no event shall be deemed to be a Tenant Delay until and unless Landlord has given Tenant written notice (the “Tenant Delay Notice”) advising Tenant (i) that a Tenant Delay is occurring, (ii) of the basis on which Landlord has determined that a Tenant Delay is occurring, and (iii) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay, and Tenant has failed to correct the Tenant Delay specified in the Tenant Delay Notice within forty-eight (48) hours following receipt thereof. No period of time prior to expiration of such 48-hour period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice if Tenant corrects the Tenant Delay specified in the Tenant Delay Notice within such 48-hour period.
Subleased Premises means all that portion of the Leased Premises referred to as airport lot as outlined on the site diagram attached as Schedule "A" to this Sublease; and
Landlord Delay means a delay in the construction of the Tenant Improvements or Compliance Work resulting directly from the acts or omissions of Landlord, Landlord’s employees, agents, or contractors including, but not limited to (i) failure of Landlord to timely approve or disapprove any plans; (ii) interference by Landlord, its employees, agents or contractors with the completion of the Tenant Improvements or Compliance Work (including the impairment of Tenant’s contractors’ or vendors’ or employees’ access to the Premises for any reason (including due to the presence of Landlord’s contractors, vendors or personnel), failure to provide reasonable access to the Building’s loading docks or other facilities necessary for the construction of the Tenant Improvements or Compliance Work and/or the movement of materials and personnel to the Premises for such purpose) and (iii) delays due to the acts or failures to act of Landlord, its agents or contractors with respect to payment of the Tenant Improvement Allowance. If Tenant contends that a Force Majeure Construction Delay or a Landlord Delay has occurred, Tenant acknowledges and agrees that it has inspected the Building and the Site and in no event shall the physical character or condition of the Building and/or Site existing as of the Effective Date constitute a basis for a Landlord Delay (this agreement does not apply to the failure of any Building component to properly operate). Further, in no event shall any delay of Landlord constitute a Landlord Delay unless such delay results in a full day of delay in the construction of the Tenant Improvements or Compliance Work. Tenant shall notify Landlord in writing (the “Delay Notice”) of the event which constitutes such Force Majeure Construction Delay or Landlord Delay; such notice may be via electronic mail to Landlord’s construction representative described above. Tenant will additionally use reasonable efforts to mitigate the effects of any Force Majeure Construction Delay or Landlord Delay through the re-sequencing or re-scheduling of work, if feasible, but this sentence will not be deemed to require Tenant to incur overtime or after-hours costs unless Landlord agrees in writing to bear such costs. If the actions or inactions or circumstances described in the Delay Notice constitute a Landlord Delay, and are not cured by Landlord within one (1) business day after Landlord’s receipt of the Delay Notice, then a Landlord Delay shall be deemed to have occurred commencing as of the expiration of such one (l)-business day period. The Lease Commencement Date and the Lease Expiration Date will each be delayed on a day for day basis for each day of Force Majeure Construction Delay or Landlord Delay.
Damage to Property means physical injury to or destruction of tangible property, including the loss of its use. Tangible property includes the cost of recreating or replacing stocks, bonds, deeds, mortgages, bank deposits and similar instruments, but does not include the value represented by such instruments.
Environmental Damages means all liabilities (including strict liability), losses, damages (excluding consequential, special, exemplary or punitive damages except to the extent such damages were imposed upon an Indemnitee as a result of any claims made against such Indemnitee by a governmental entity or any other third party), judgments, penalties, fines, costs and expenses (including fees, costs and expenses of attorneys, consultants, contractors, experts and laboratories), of any and every kind or character, at law or in equity, contingent or otherwise, matured or unmatured, foreseeable or unforeseeable, made, incurred, suffered, brought, or imposed at any time and from time to time, whether before or after the Release Date and arising in whole or in part from: