Reports of unusual occurrence The Contractor shall, during the Maintenance Period, prior to the close of each day, send to the Authority and the Authority’s Engineer, by facsimile or e- mail, a report stating accidents and unusual occurrences on the Project Highway relating to the safety and security of the Users and Project Highway. A monthly summary of such reports shall also be sent within 3 (three) business days of the closing of month. For the purposes of this Clause 15.4, accidents and unusual occurrences on the Project Highway shall include:
(a) accident, death or severe injury to any person;
(b) damaged or dislodged fixed equipment;
(c) flooding of Project Highway; and
(d) any other unusual occurrence.
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Material Occurrences Promptly notify Agent in writing upon the occurrence of (a) any Event of Default or Default; (b) any event, development or circumstance whereby any financial statements or other reports furnished to Agent fail in any material respect to present fairly, in accordance with GAAP consistently applied, the financial condition or operating results of any Borrower as of the date of such statements; (c) any accumulated retirement plan funding deficiency which, if such deficiency continued for two plan years and was not corrected as provided in Section 4971 of the Code, could subject any Borrower to a tax imposed by Section 4971 of the Code; (d) each and every default by any Borrower which might result in the acceleration of the maturity of any Indebtedness, including the names and addresses of the holders of such Indebtedness with respect to which there is a default existing or with respect to which the maturity has been or could be accelerated, and the amount of such Indebtedness; and (e) any other development in the business or affairs of any Borrower which could reasonably be expected to have a Material Adverse Effect; in each case describing the nature thereof and the action Borrowers propose to take with respect thereto.
ABSENCE FROM DUTY Unless a provision of this agreement states otherwise (e.g. sick leave), an employee not attending for duty will lose their pay for the actual time of such non- attendance.
Approved Leave of Absence During Vacation Where it can be established by the employee through a doctor's certificate that an illness or accident occurred, or where an employee qualifies for bereavement or any other approved leave during his/her period of vacation, there shall be no deduction from vacation credits for such absence. The period of vacation so displaced shall either be added to the vacation or reinstated for use at a later date, at the employee's option, as mutually agreed.
Termination Due To Lack Of Funding Appropriation If, in the judgment of the Director of Accounts and Reports, Department of Administration, sufficient funds are not appropriated to continue the function performed in this agreement and for the payment of the charges hereunder, State may terminate this agreement at the end of its current fiscal year. State agrees to give written notice of termination to contractor at least 30 days prior to the end of its current fiscal year, and shall give such notice for a greater period prior to the end of such fiscal year as may be provided in this contract, except that such notice shall not be required prior to 90 days before the end of such fiscal year. Contractor shall have the right, at the end of such fiscal year, to take possession of any equipment provided State under the contract. State will pay to the contractor all regular contractual payments incurred through the end of such fiscal year, plus contractual charges incidental to the return of any such equipment. Upon termination of the agreement by State, title to any such equipment shall revert to contractor at the end of the State's current fiscal year. The termination of the contract pursuant to this paragraph shall not cause any penalty to be charged to the agency or the contractor.
Partial Disposal During Term of Service Agreement Throughout the Term of the Service Agreement, LEA may request partial disposal of Student Data obtained under the Service Agreement that is no longer needed. Partial disposal of data shall be subject to LEA’s request to transfer data to a separate account, pursuant to Article II, section 3, above.
Continuation of Optional Coverages During Unpaid Leave or Layoff An employee who takes an unpaid leave of absence or who is laid off may discontinue premium payments on optional policies during the period of leave or layoff. If the employee returns within one (1) year, the employee shall be permitted to pick up all optionals held prior to the leave or layoff. For purposes of reinstating such optional coverages, the following limitations shall be applicable. For the first twenty-four (24) months of long-term disability coverage after such a period of leave or layoff during which long-term disability coverage was discontinued, any such disability coverage shall exclude coverage for pre-existing conditions. For disability purposes, a pre-existing condition is defined as any disability which is caused by, or results from, any injury, sickness or pregnancy which occurred, was diagnosed, or for which medical care was received during the period of leave or layoff. In addition, any pre-existing condition limitations that would have been in effect under the policy but for the discontinuance of coverage shall continue to apply as provided in the policy. The limitations set forth above do not apply to leaves that qualify under the Family Medical Leave Act (FMLA).
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
