Access to the Authority Sample Clauses

Access to the Authority. The licence, right of way and right to the Depot Site granted to the Operator hereunder shall always be subject to the right of access of the Authority and their employees and agents for inspection, viewing and exercise of their rights and performance of their obligations under this Agreement.
Sample 1Sample 2Sample 3See All (9)
AutoNDA by SimpleDocs
Access to the Authority. 10.7.1 The licence, right of way and right to the Site granted to the Concessionaire hereunder shall always be subject to the right of access of the Authority and their employees and agents for inspection, viewing and exercise of their rights and performance of their obligations under this Agreement. 10.7.2 The Concessionaire shall allow free access to the Site at all times for the authorised representatives of the Authority, lenders, Independent Engineer, and for the persons duly authorised by any Government Instrumentality to inspect the Project or Project Facilities or to investigate any matter within their authority, and upon reasonable notice, the Concessionaire shall provide to such persons, reasonable assistance necessary to carry out their respective duties and functions. 10.7.3 The Concessionaire shall, for the purpose of operation and maintenance of any utility specified in Article 11, allow free access to the Site at all times for the authorised persons of the controlling body of such utility.
Sample 1Sample 2Sample 3See All (5)
Access to the Authority. The license to the Terminal and Right of Way granted to the Operator herein shall always be subject to the right of access of the Authority, its lessor, its employees, agents and representatives for inspection, viewing and exercise of their rights and performance of their obligations under this Contract or as per the requirements of the Applicable Laws and Applicable Permits.
Sample 1Sample 2
Access to the Authority. The Lease Rights to the Land Parcel granted to the Lessee hereunder shall always be subject to the right of access of the Authority and their employees and agents for inspection, viewing and exercise of their rights and performance of their obligations under this Agreement.
Sample 1
Access to the Authority and the Authority’sEngineer‌ (i) The Right of Way given to the Contractor hereunder shall always be subject to the right of access of the Authority and the Authority’s Engineer and their employees and agents for inspection, viewing and exercise of their rights and performance of their obligations under thisAgreement. (ii) The Contractor shall ensure, subject to all relevant safety procedures, that the Authority has un-restricted access to the Site during any emergency situation, as decided by the Authority’sEngineer.
Sample 1
Access to the Authority. The right to the Site granted to the Concessionaire hereunder shall always be subject to the right of access of the Authority and the Authority’s Engineer and other employees and agents of the Authority for inspection, viewing and exercise of their rights and performance of their obligations under this Agreement.
Sample 1
Access to the Authority. ‌ The lease and right to the project granted to the Concessionaire hereunder shall always be subject to the right of access of the Authority and their employees for inspection, viewing and exercise of their rights and performance of their obligations under this agreement.
Sample 1
AutoNDA by SimpleDocs

Related to Access to the Authority

  • Notice to the Authority No later than [45 (forty five)] days prior to commencement of the Construction Period or the Operation Period, as the case may be, the Concessionaire shall by notice furnish to the Authority, in reasonable detail, information in respect of the insurances that it proposes to effect and maintain in accordance with this Article 27. Within [30 (thirty)] days of receipt of such notice, the Authority may require the Concessionaire to effect and maintain such other insurances as may be necessary pursuant hereto, and in the event of any difference or disagreement relating to any such insurance, the Dispute Resolution Procedure in Article 39 shall apply.

  • The Authority As to the Authority, the following section shall survive discharge: Section 2.3 (right to conduct audit).

  • GENERAL COMPLIANCE WITH RESPECT TO THE APARTMENT Subject to Clause 12 above, the Allottee shall, after taking possession, be solely responsible to maintain the [Apartment/Plot] at his/her own cost, in good repair and condition and shall not do or suffer to be done anything in or to the Building, or the [Apartment/Plot], or the staircases, lifts, common passages, corridors, circulation areas, atrium or the compound which may be in violation of any laws or rules of any authority or change or alter or make additions to the [Apartment/Plot] and keep the [Apartment/Plot], its walls and partitions, sewers, drains, pipe and appurtenances thereto or belonging thereto, in good and tenantable repair and maintain the same in a fit and proper condition and ensure that the support, shelter etc. of the Building is not in any way damaged or jeopardized. The Allottee further undertakes, assures and guarantees that he/she would not put any sign-board / name-plate, neon light, publicity material or advertisement material etc. on the face / facade of the Building or anywhere on the exterior of the Project, buildings therein or Common Areas. The Allottees shall also not change the colour scheme of the outer walls or painting of the exterior side of the windows or carry out any change in the exterior elevation or design. Further the Allottee shall not store any hazardous or combustible goods in the [Apartment/Plot] or place any heavy material in the common passages or staircase of the Building. The Allottee shall also not remove any wall, including the outer and load bearing wall of the [Apartment/Plot]. The Allottee shall plan and distribute its electrical load in conformity with the electrical systems installed by the Promoter and thereafter the association of allottees and/or maintenance agency appointed by association of allottees. The Allottee shall be responsible for any loss or damages arising out of breach of any of the aforesaid conditions.

  • PARTIES TO THE AGREEMENT ‌ The parties to the Agreement (hereinafter "Party" or "Parties") are: 1. PDL International Pte Ltd NEPTUNE PACIFIC DIRECT LINE PTE. LTD. ("PDL NPDL") 000 Xxxxx Xxxxxx, #03-00,PIL Building 8 Xxxxxx Road, #03-01 Singapore Xxxxxx Xxxx, Xxxxxxxxx, 000000 228095 2. Pacific Forum Line (Group) Limited ("PFLG") X.X. Xxx 000, 0xx Xxxxx Xxxxxx Xxxxx Lini Highway Port Vila Vanuatu

  • Where the Academy Trust acquires assets for a nil consideration or at an under value it shall be treated for the purpose of this Agreement as having incurred expenditure equal to the market value of those assets at the time that they were acquired. This provision shall not apply to assets transferred to the Academy Trust at nil or nominal consideration and which were previously used for the purposes of an Academy and/or were transferred from an LA, the value of which assets shall be disregarded.

  • Amendments to the Agreement Except to the extent permitted by the Investment Company Act or the rules or regulations thereunder or pursuant to exemptive relief granted by the SEC, this Agreement may be amended by the parties only if such amendment, if material, is specifically approved by the vote of a majority of the outstanding voting securities of the Portfolio (unless such approval is not required by Section 15 of the Investment Company Act as interpreted by the SEC or its staff or unless the SEC has granted an exemption from such approval requirement) and by the vote of a majority of the Independent Trustees cast in person at a meeting called for the purpose of voting on such approval. The required shareholder approval shall be effective with respect to the Portfolio if a majority of the outstanding voting securities of the Portfolio vote to approve the amendment, notwithstanding that the amendment may not have been approved by a majority of the outstanding voting securities of any other Portfolio affected by the amendment or all the Portfolios of the Trust.

  • COMPLIANCE WITH RESPECT TO THE APARTMENT 15.1 Subject to Para 12 above, the Allottee(s) shall, after taking possession, be solely responsible to maintain the said [Apartment] at his/her own cost, in good repair and condition and shall not do or suffer to be done anything in or to the said building [Apartment], or the staircases, lifts, common passages, corridors, circulation areas, atrium or compound which may be in violation of any laws or rules of any authority or change or alter or make additions to the said Apartment, and keep the said Apartment,, its walls and partitions, sewers, drains, pipes and appurtenances thereto or belonging thereto in good and tenantable repair and maintain the same in a fit and proper condition and ensure that the support, shelter etc. of the building is not in any way damaged or jeopardized. 15.2 The Allottee further undertakes, assures and grantees that he/ she would not put any sign-board/ name-plate, neon light, publicity material or advertisement material etc. on the façade of the building or anywhere on the exterior of the Project, building therein or common areas. The Allottee also not change the color scheme of outer wall or painting of the exterior side of windows or carry out any change in the exterior elevation or design. Further the Allottee shall store any hazardous or combustible goods in the [Apartment] or place any heavy material in the common passages or staircase of the building. The Allottee shall also not remove any wall, including the outer and load wall of the [Apartment]. 15.3 The Allottee shall plan and distribute its electric load in conformity with the electric systems installed by the Promoter and thereafter the Association of allottees and/or maintenance agency appointed by the association of allottees. The Allottee shall be responsive for any loss or damages arising out of breach of any of the aforesaid conditions.

  • Pursuant to the Act The Company has filed with the Commission a registration statement and any amendment thereto, on Form S-1 (File No. 333-[●]), including any related preliminary prospectus (the “Preliminary Prospectus”, including any prospectus that is included in the registration statement immediately prior to the effectiveness of the registration statement), for the registration of the Units under the Act, which registration statement and amendment or amendments have been prepared by the Company in conformity with the requirements of the Act, and the rules and regulations (the “Regulations”) of the Commission under the Act. The conditions for use of Form S-1 to register the Offering under the Act, as set forth in the General Instructions to such Form, have been satisfied. Except as the context may otherwise require, such registration statement, as amended, on file with the Commission at the time the registration statement became effective, including the prospectus, financial statements, schedules, exhibits and all other documents filed as a part thereof or incorporated therein and all information deemed to be a part thereof as of such time pursuant to Rule 430A of the Regulations, together with the registration statement filed by the Company pursuant to Rule 462(b) under the Act registering additional Public Securities (the “Rule 462(b) Registration Statement”), is hereinafter called the “Registration Statement,” and the form of the final prospectus dated the Effective Date included in the Registration Statement (or, if applicable, the form of final prospectus containing information permitted to be omitted at the time of effectiveness by Rule 430A of the Regulations, filed by the Company with the Commission pursuant to Rule 424 of the Regulations), is hereinafter called the “Prospectus.” For purposes of this Agreement, “Applicable Time,” as used in the Act, means 5:00 p.m. New York City time, on the date of this Agreement. Prior to the Applicable Time, the Company prepared a Preliminary Prospectus, which was included in the Registration Statement filed on [●], 2021, for distribution by the Underwriters (such Preliminary Prospectus used most recently prior to the Applicable Time, the “Statutory Prospectus”). Other than the Registration Statement, together with any correspondence letters between the Company and/or counsel for the Company and the Commission, no other document with respect to the Registration Statement has been filed under the Act with the Commission. All of the Public Securities have been or will be registered for public sale under the Act pursuant to the Registration Statement. The Registration Statement has been declared effective by the Commission on the date hereof. If, subsequent to the date of this Agreement, the Company or the Representative determines that, at the Applicable Time, the Statutory Prospectus included an untrue statement of a material fact or omitted a statement of material fact necessary to make the statements therein, in light of the circumstances under which they were made, not misleading and the Company and the Representative agree to provide an opportunity to purchasers of the Units to terminate their old purchase contracts and enter into new purchase contracts, then the Statutory Prospectus will be deemed to include any additional information available to purchasers at the time of entry into the first such new purchase contract.

  • Application of the Agreement (1) This Agreement shall apply to investments made in the territory of either Contracting Party in accordance with its legislation by investors of the other Contracting Party prior as well as after the entry into force of this Agreement. (2) This Agreement shall not apply to claims which have been settled or procedures which have been initiated prior to its entry into force.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!