Airspace Rights Clause Samples

Airspace Rights. Except to the extent required for the performance of any of the obligations of Concessionaire under this Agreement, nothing contained in this Agreement shall grant to Concessionaire any rights whatsoever in the air space above the Premises. In that regard, County reserves the right to take any action whatsoever that it considers necessary to protect the aerial approaches of the Airport against obstruction, including, but not limited to, demolition or removal of structures upon the Premises, together with the right to prevent Concessionaire from erecting or permitting to be erected any building or other structure at the Airport which, in the opinion of County, would limit the usefulness of or interfere with the operations at the Airport, or constitute a hazard to aircraft.
View SourceView Similar (3)
Airspace Rights. CITY will own the land underneath the structured parking lot be located between 5th and 6th Streets on lots 18, 17a, and 47b of the Tentative Map. However, CITY will only own the airspace rights over that portion of the structured parking lot that encompasses lot 17a as shown on the Tentative Map. If CITY, City Agency or Public Agency decides not to undertake a development project above the structured parking lot on lot 17a, then CITY will provide LANDOWNER with the first opportunity to submit a proposal for development within the airspace above this structured parking lot. In that event, in consideration for LANDOWNER dedication of the land to CITY for this structured parking lot, LANDOWNER shall not owe CITY any amount for LANDOWNER to retain the airspace rights and all necessary temporary and permanent easements for future Development of lot 17a in accordance with the Project Entitlements on mutually acceptable terms and subject to compliance with the provisions of Section 5.12.2. The Parties shall negotiate in good faith to specify the terms of agreement to allow LANDOWNER to retain the airspace rights within a 90 day period after CITY provides written notice to LANDOWNER of CITY’s decision to release such rights. If LANDOWNER and CITY cannot agree on the terms of an agreement for LANDOWNER’s use of the airspace rights on lot 17a, CITY shall be entitled to seek development proposals from other developers without further obligation to LANDOWNER.
View Source
Airspace Rights. This Lease confers no rights either with regard to the subsurface of the Property (other than any basement that is part of the Premises) or with regard to airspace above the top of the roof or any appliance to be affixed to the roof of the Building as shown on Exhibit A, except for access for maintenance to mechanical systems and for, subject to obtaining Landlord's written approval in advance, which approval shall not be unreasonably withheld, installation and maintenance of an antenna an/or satellite dish as may be sought by Tenant. While the Tenant leases more than half of the Rentable Area of the Building, Landlord may not lease or license for use any air space for use which materially interferes with Tenant's use. At no time shall Landlord (1) lease or license for use any airspace to advertise banking or business services that are competitive with Tenant's services or (2) interfere in any way with any approved communications system(s) installed and used on the roof by Tenant.
View Source

Related to Airspace Rights

  • Use Rights The Use Rights in effect when Customer orders Software will apply to Customer’s use of the version of the Software that is current at the time. For future versions and new Software, the Use Rights in effect when those versions and Software are first released will apply. Changes Microsoft makes to the Use Rights for a particular version will not apply unless Customer chooses to have those changes apply.

  • Roof Rights Tenant shall be granted the right to install one (1) antenna in the Antenna Area at Tenant's expense and subject to appropriate governmental approval and Landlord's reasonable approval. Prior to installation of the antenna, Tenant shall submit to Landlord all plans, specifications and drawings. Tenant shall be responsible for the installation, maintenance and operation and liability of the antenna. a) Landlord agrees that during the Term (as defined in Section 3 below), Tenant may install, use and have maintained in the Antenna Area, equipment ("Equipment") as specifically described in documentation delivered by Tenant to Landlord in connection with the initial approval process. All of Tenant's construction and installation work shall be performed at Tenant's sole cost and expense and in good and work-manlike manner. Tenant shall have and retain whatever title and rights to the Equipment as it has or claims to have, exclusive of space in and structural portions of the buildings, which belong to and shall be retained by Landlord. Landlord will cooperate with Tenant, at no cost to Landlord, regarding Tenant's access to utilities and the connection of the utilities to the Equipment b) Landlord agrees that Tenant and/or its contractor may run cables ("Cables") between the Antenna Area and Premises, only in locations specifically approved by Landlord in writing, which approval shall not be unreasonably delayed or withheld. c) The Equipment and Cables shall remain the property of Tenant or its contractor during the Term. Tenant shall, at its sole cost and expense within fourteen (14) days, remove or have removed such Equipment and Cables upon the earlier of (1) the expiration or termination of this Agreement, or (ii) the expiration of the Lease. To the extent reasonably possible, Tenant shall restore Landlord's affected facilities to their original condition, including repainting or touch-up, excepting ordinary wear and tear, and/or damage or destruction due to fire or other casualty. d) Tenant shall bear all expense in connection with the installation, use and maintenance of such Equipment and Cables, and shall be solely responsible for all maintenance, repair and damage caused to the Roof or roof membrane as a result of the installation or any access to the antenna. Tenant shall indemnify, defend, protect and hold Landlord harmless from and against liability, damages, costs and expenses, including reasonable attorneys' fees incurred or suffered by Landlord directly caused by Tenant's installation, use and maintenance of the Equipment and Cables, including without limitation, injury and death to persons, damage to property and interference with other tenants and licensee's rights who are sharing roof-top facilities at the Project. e) Tenant shall maintain in force and effect during the Term, comprehensive liability insurance protecting Landlord against any liability, damages costs or expenses, in connection with the installation, use and maintenance of the Equipment and Cables, and shall supply to Landlord, upon Landlord's written request, the appropriate certificates of such insurance. f) Tenant and its contractors shall comply with all applicable laws, regulations and building codes in connection with the installation, use and maintenance of the Equipment and Cables.

  • Appurtenant Rights The Tenant shall have, as appurtenant to the Premises, the nonexclusive right to use in common with others, subject to reasonable rules of general applicability to occupants of the Building from time to time made by the Landlord of which the Tenant is given notice: (i) the entry, vestibules and main lobby of the Building, first floor mailroom, the common stairways, elevators, elevator ▇▇▇▇▇, boiler room, elevator rooms, sprinkler rooms, mechanical rooms, electric and telephone closets, janitor closets, loading docks and bays, rooftop mechanical penthouses and shafts to the extent they house Building equipment, and the pipes, sprinklers, ducts, conduits, wires and appurtenant fixtures and equipment serving the Premises in common with others, (ii) common walkways and driveways necessary or reasonably convenient for access to the Building, (iii) access to loading area and freight elevator subject to Rules and Regulations then in effect, and (iv) if the Premises at any time include less than the entire rentable floor area of any floor, the common toilets, corridors, vestibules, and elevator lobby of such floor. Tenant shall have 24 hour, seven day per week access to the Premises, freight loading docks and freight elevators, subject to the provisions of this Lease and interruption for External Causes, casualty and condemnation. Landlord shall provide Tenant with access cards for after-hours access. Additionally, the Tenant shall have, as appurtenant to the Premises (and exclusively for use in connection with the occupancy of the Premises), the nonexclusive right of access to and proportionate use of the roof for the purpose of installing and maintaining mechanical equipment, HVAC equipment, emergency generator, antennae and satellite dishes which, in each case, have been pre-approved by the Landlord pursuant to the terms of Article IV, subject however, to reasonable rules of general applicability to occupants of the Building from time to time made by the Landlord of which the Tenant is given notice and any applicable laws, but only to the extent that the Tenant has assumed responsibility for maintenance and repair of such equipment installed by Tenant.

  • Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT. B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate. B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner. B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment. B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.