Third Party Warranties Third-party equipment, software and peripheral products are covered by the warranties provided by the original manufacturer or the seller of the product. Third party warranties may vary from product to product. It is your responsibility to consult the applicable product documentation for specific warranty information. In addition, you acknowledge that certain third party equipment or software warranties may limit or void the remedies that they offer if unauthorized persons perform support service on the equipment or software. It is your responsibility to ensure that any impact that Verizon's delivery of Technical Support Services might have on third party warranties is acceptable to you.
Customer Warranties Customer warrants that (i) if an entity, it is duly organized and validly existing in good standing; (ii) it is duly authorized to execute, deliver, and perform its obligations under this Agreement; (iii) when duly executed and delivered by each Party, the Agreement will constitute Customer’s legal, valid, and binding obligation, enforceable against it in accordance with its terms; (iv) it is not insolvent and is paying all of its debts as they become due; (v) any payments made pursuant to the Agreement are intended by it to be a substantially contemporaneous exchange for new value given to it; (vi) each payment made of a debt incurred by it under this Agreement is or was in the ordinary course of its business or financial affairs, and (vii) all information supplied by Customer is complete and accurate.
Supplier Warranties The warranties made by Supplier with respect to each Product are solely those that are contained in the product insert accompanying such Product. No other affirmation of fact or promise made by Distributor or its Suppliers, whether or not in this Agreement, by words or action shall constitute a warranty. The foregoing warranty does not extend to any Product that is modified or altered, or treated with abuse, negligence or other improper treatment. Standard Limited Warranty. Distributor shall pass on to Subdistributor so that it may pass on to the customers the Supplier’s standard limited warranty for Products, including limitations set for in subsection (b) Limitation of Liability and Warranty below. Except for the stated warranty set forth on, or included with, the Products as delivered to the Subdistributor and /or its customers, the warranty and remedy set forth in this 0 are exclusive and all other warranties, guarantees or representations, express or implied, by Distributor’s Suppliers with respect to the applicable Products, including, without limitation, warranties of merchantability and fitness for particular purpose, and any other obligation or liability of Distributor and its Suppliers to Subdistributor or to any third party with respect to the Products, are hereby excluded. This warranty is contingent upon proper use of a Product in the application for which such Product was intended and does not cover Products that were modified without Distributor or its Supplier’s prior written approval, that have expired or that were subjected to physical, chemical or electrical stress that the products were not originally designed for.
Product Warranties Except as set forth in Schedule 3.15, (a) there are no warranties express or implied, written or oral, with respect to the Business and (b) there are no pending or threatened claims with respect to any such warranty, and Seller has no liability with respect to any such warranty, whether known or unknown, absolute, accrued, contingent or otherwise and whether due or to become due.
Contractor Warranties 7.12.1 If and to the extent Developer obtains general or limited warranties from any Contractor in favor of Developer with respect to design, materials, workmanship, equipment, tools, supplies, software or services, Developer also shall cause such warranty to be expressly extended to TxDOT and any third parties for whom Work is being performed or equipment, tools, supplies or software is being supplied by such Contractor; provided that the foregoing requirement shall not apply to standard, pre-specified manufacturer warranties of mass- marketed materials, products (including software products), equipment or supplies where the warranty cannot be extended to TxDOT using commercially reasonable efforts. TxDOT agrees to forebear from exercising remedies under any such warranty so long as Developer or a Lender is diligently pursuing remedies thereunder. To the extent that any Contractor warranty would be voided by reason of Developer's negligence in incorporating material or equipment into the Work, Developer shall be responsible for correcting such defect.
7.12.2 Contractor warranties (if any) are in addition to all rights and remedies available under the CDA Documents or applicable Law or in equity, and shall not limit Developer’s liability or responsibility imposed by the CDA Documents or applicable Law or in equity with respect to the Work, including liability for design Defects, latent construction Defects, strict liability, breach, negligence, willful misconduct or fraud.
Seller Warranties 20.1 The Seller warrants that at the Date of this Contract:
(a) the Seller will be able to complete at Completion;
(b) the Seller has no knowledge of any unsatisfied judgment, order or writ affecting the Land;
(c) the Seller has no knowledge of any current or threatened claims, notices or proceedings that may lead to a judgment, order or writ affecting the Land; and
(d) the Seller is not aware of any material change in the matters disclosed in the Housing Development Requirements.
20.2 The Seller warrants that on Completion:
(a) the Seller will have the capacity to complete;
(b) there will be no unsatisfied judgment, order or writ affecting the Land;
(c) the Seller has no knowledge of any current or threatened claims, notices or proceedings that may lead to a judgment order or writ affecting the Land; and
(d) the Seller is not aware of any encroachments by or upon the Land except as disclosed. This warranty does not extend to the location of any dividing fence.
20.3 The Seller gives no warranties as to the present state of repair of any of the Improvements or condition of the Land, except as required by law.
Buyer Warranties 38.1 The Buyer represents and warrants that:
(a) it has full power and capacity to enter into this Contract;
(b) it has the financial capacity to perform its obligations;
(c) it does not require the consent of any third party to this Contract or to perform its obligations;
(d) they are aware of the rights given to purchasers by sections 217-219 (inclusive)of the Act ;
(e) that any alteration, variation or matter referred to in clause 13 of this Contract will not materially prejudice their position and the Buyer agrees to be bound by any such matters or alterations;
(f) it has not relied on or been induced to enter into this Contract by any representation or warranty made by the Seller, a consultant of the Seller, an agent of the Seller or any other person other than as expressly set out in this Contract;
(g) it has relied on its own independent investigations and enquiries about the Scheme, the development and the Lot in entering into this Contract;
(h) it has had the opportunity to obtain independent legal, financial, taxation and accounting advice in relation to the Lot and this Contract; and
(i) the Buyer was not introduced to the lot by any person other than the Agent.
38.2 The Buyer agrees that information in brochures, models or other material of any description in connection with the sale of the Lot are indicative only and are not to be relied on or if relied on, the Buyer acknowledges that it elects to do so at its own risk and with full understanding that the Lot and Scheme may vary from the information in those items as represented in any of them, in accordance with the terms of this Contract. Where there is any inconsistency between plans, the sizes, dimensions and measurements on the draft survey plan contained in the Disclosure Statement (as amended from time to time) prevails.
38.3 The Buyer acknowledges and agrees that it has had the opportunity, prior to signing this Contract, to obtain an independent valuation in relation to the Lot and that no representations or warranties about the likely value of the lot at completion has been made by the Seller, a consultant of the Seller, an agent of the Seller.
38.4 The Buyer acknowledges and agrees that it had the opportunity to investigate the Land and the financial viability and/or performance of any investment in the Lot prior to signing this Contract and during the statutory 5 day cooling off period.
Vendor Warranties 6.1 The vendor warrants that these general conditions 1 to 35 are identical to the general conditions 1 to 35 in the form of contract of sale of land published by the Law Institute of Victoria Limited and the Real Estate Institute of Victoria Pty Ltd in the month and year set out at the foot of this page.
6.2 The warranties in general conditions 6.3 and 6.4 replace the purchaser’s right to make requisitions and inquiries.
6.3 The vendor warrants that the vendor:
(a) has, or by the due date for settlement will have, the right to sell the land; and
(b) is under no legal disability; and
(c) is in possession of the land, either personally or through a tenant; and
(d) has not previously sold or granted any option to purchase, agreed to lease or granted a pre-emptive right which is current over the land and which gives another party rights which have priority over the interest of the purchaser; and
(e) will at settlement be the holder of an unencumbered estate in fee simple in the land; and
(f) will at settlement be the unencumbered owner of any improvements, fixtures, fittings and goods sold with the land.
6.4 The vendor further warrants that the vendor has no knowledge of any of the following:
(a) public rights of way over the land;
(b) easements over the land;
(c) lease or other possessory agreement affecting the land;
(d) notice or order directly or indirectly affecting the land which will not be dealt with at settlement, other than the usual rate notices and any land tax notices;
(e) legal proceedings which would render the sale of the land void or voidable or capable of being set aside.
6.5 The warranties in general conditions 6.3 and 6.4 are subject to any contrary provisions in this contract and disclosures in the section 32 statement.
6.6 If sections 137B and 137C of the Building Act 1993 apply to this contract, the vendor warrants that:
(a) all domestic building work carried out in relation to the construction by or on behalf of the vendor of the home was carried out in a proper and workmanlike manner; and
(b) all materials used in that domestic building work were good and suitable for the purpose for which they were used and that, unless otherwise stated in the contract, those materials were new; and
(c) domestic building work was carried out in accordance with all laws and legal requirements, including, without limiting the generality of this warranty, the Building Act 1993 and regulations made under the Building Act 1993.
6.7 Words and phrases used in general condition 6.6 which are defined in the Building Act 1993 have the same meaning in general condition 6.6.
SUPPLIER’S WARRANTIES 16.1 The Supplier represents, warrants and undertakes to the Authority that:
16.1.1 the Supplier has the full right, power and authority to enter into and perform this Agreement and to grant all of the Authority Rights to the Authority and for the Authority to use and exploit the same as contemplated in this Agreement;
16.1.2 all information, representations, warranties and other matters of fact contained in the Supplier’s tender submission as part of the competitive tender process referred to in the recitals to this Agreement are true, complete and accurate in all respects and the Supplier agrees to be bound by the obligations and statements made in such tender submission as if the same were set out in this Agreement, save where there is any inconsistency between the terms of this Agreement and such tender submission the terms of this Agreement shall prevail;
16.1.3 save in respect of any Third Party Content, no Deliverable has and no Deliverable will have been broadcast, released or otherwise exploited in any Broadcast Media anywhere in the world prior to the relevant Delivery Date;
16.1.4 there is no contract or arrangement to which the Supplier is a party and the Supplier will not enter into any contract or arrangement and there is and will be no other encumbrance or restriction which could in any way interfere with or inhibit the full exercise or exploitation of any and all of the Authority Rights by the Authority;
16.1.5 the Supplier has paid and shall promptly pay all sums due to any person who is or may be entitled to any payment in respect of services or facilities rendered or goods supplied or rights granted in connection with the Deliverables or on the exercise by the Authority of any of the Authority Rights or in respect of any tax, duty, levy, national insurance or any similar payment in connection with the Deliverables required to be made by the Supplier;
16.1.6 the Supplier will have, by and as at the relevant Delivery Date, obtained all necessary consents, grants, clearances and rights (including any rights in musical compositions contained within the Deliverables (if any) which are controlled by the Performing Right Society or its affiliated bodies) to enable it to produce and deliver the Deliverables and to grant to and enable the Authority to exercise the Authority Rights free from any liens, claims and encumbrances;
16.1.7 to the extent any musical compositions are contained in the Deliverables:
16.1.7.1 all recording synchronisation and dubbing licences have been obtained and licence fees have been paid; and
16.1.7.2 the performing rights in such compositions shall throughout the Term be controlled (i) by the Performing Right Society or its affiliated bodies; or (ii) by the Supplier; or (iii) are in the public domain, in all cases to the extent required for the purposes of the Authority's full exercise of its rights as contemplated by this Agreement;
16.1.8 no claim or litigation is pending or threatened in respect of the Deliverables or any the Authority Rights;
16.1.9 the Deliverables will be produced in accordance with all Laws (including with respect to health and safety);
16.1.10 the Deliverables will be free from all Viruses;
16.1.11 the Deliverables will not contain anything which is in contravention of the Codes and Guidelines or any Laws or which is obscene, blasphemous, seditious, racially inflammatory, defamatory or which infringes the rights of any person, including rights of copyright or trade marks or service marks, privacy, publicity or confidentiality or any other civil or common law or statutory right whatsoever or breaches any contract or is in contempt of court;
16.1.12 the Supplier has not entered and will not enter into any co-production, co-financing, pre-sale or other arrangement or agreement which involves the surrender by the Supplier of any control of the Deliverables;
16.1.13 all information, records and data provided to the Authority and with respect to the Deliverables and the production process will be accurate in all respects, full and up to date;
16.1.14 the Supplier is not insolvent nor unable to pay its debts as they fall due and no steps have been taken with a view to the winding-up or administration of the Supplier or the making of any composition or arrangement with any creditors of the Supplier; and
16.1.15 the Supplier will not at any time do or say anything which is or may be considered by the Authority (acting reasonably) to be detrimental or prejudicial to or to affect adversely the name, image, reputation or business of the Authority or otherwise to bring the Authority or any member of the Authority Group into disrepute.
16.2 The Supplier's warranties shall be deemed repeated on each Delivery Date (or, if any Deliverables are delivered to the Authority after the scheduled Delivery Date and the Authority has not exercised any right under this Agreement to treat such delay as an Event of Default under clause 27.1, within ten Working Days of the date of actual delivery) and on every occasion when the Authority exercises its Authority Rights.
Service Warranties Contractor warrants that: (i) the Services will be rendered with promptness and diligence and will be executed in a workmanlike manner, in accordance with the practices and professional standards used in well-managed operations performing services similar to the Services; and (ii) Contractor will perform the Services in the most cost-effective manner consistent with the required level of quality and performance. Contractor warrants that each Deliverable will conform to and perform in accordance with the requirements of this Agreement and all applicable specifications and documentation. For each such Deliverable, the foregoing warranty shall commence for such Deliverable upon the JBE’s acceptance of such Deliverable, and shall continue for a period of one (1) year following acceptance. In the event any Deliverable does not to conform to the foregoing warranty, Contractor shall promptly correct all nonconformities to the satisfaction of the JBE.
