Applicable Law and Applicable Codes and Standards Sample Clauses

Applicable Law and Applicable Codes and Standards. Contractor has investigated to its satisfaction Applicable Law in existence as of May 15, 2011 and Applicable Codes and Standards set forth or listed in any document or Drawing listed in Attachment A, and warrants that it can perform the Work at the Contract Price and within the Project Schedule in accordance with such Applicable Law and such Applicable Codes and Standards. Contractor shall perform the Work in accordance with Applicable Law and such Applicable Codes and Standards; provided, however, Contractor shall be entitled to a Change Order for any Change in Law to the extent allowed under Section 6.2A.1. Contractor shall advise Owner of any change in Applicable Codes and Standards which does not constitute a Change in Law and, upon such advisement, Owner may elect, at its sole option, to implement a change in accordance with Section 6.1D.
Sample 1Sample 2Sample 3See All (19)
AutoNDA by SimpleDocs
Applicable Law and Applicable Codes and Standards. Contractor has investigated to its satisfaction Applicable Law and Applicable Codes and Standards, (excluding environmental codes, regulations, and air permit as related to Equipment), and warrants that it can perform the Work in accordance with Applicable Law and Applicable Codes and Standards. Contractor shall perform the Work in accordance with Applicable Law and Applicable Codes and Standards, whether or not such Applicable Law or Applicable Codes and Standards came into effect before the Effective Date or during the performance of the Work; provided, however, Contractor shall be entitled to a Change Order for Changes in Law to the extent allowed under Section 6.2.1.1, provided that Contractor complies with the notice and Change Order request requirements set forth in Sections 6.2 and 6.5, and, with respect to claims for costs for delay or schedule relief for delay, satisfies the requirements of Section 6.8.
Sample 1Sample 2
Applicable Law and Applicable Codes and Standards. Contractor has investigated to its satisfaction Applicable Law and Applicable Codes and Standards and warrants that it can perform the Work at the Contract Price and within the Key Dates in accordance with Applicable Law and Applicable Codes and Standards. Contractor shall perform the Work in accordance with Applicable Law and Applicable Codes and Standards, whether or not such Applicable Law or Applicable Codes and Standards came into effect before the Effective Date or during the performance of the Work; provided, however, Contractor shall be entitled to a Change Order for Changes in Law to the extent allowed under Section 6.2A.6. Except for any Changes in Law for which Contractor is entitled to a Change Order under Section 6.2A.6, Contractor hereby waives any right to make any claim for adjustment of the Contract Price or the Key Dates in relation to any change in Applicable Law or Applicable Codes and Standards. Notwithstanding anything provided in this Agreement, the Parties agree that Contractor’s sole and exclusive remedy for any change in tariffs, quotas, or duties is set forth in Attachment FF.
Sample 1Sample 2
Applicable Law and Applicable Codes and Standards. 1. Subject to Section 2.5C.2. Contractor has investigated to its satisfaction Applicable Law and Applicable Codes and Standards and warrants that it can perform the Work at the Contract Price and within the Key Milestone Schedule, Guaranteed Substantial Completion Date and Required Final Completion Date in accordance with Applicable Law and Applicable Codes and Standards. 2. If a Change in Law occurs, Contractor shall perform the Work in accordance with such Change in Law and shall be entitled to a Change Order for such Change in Law to the extent allowed under Section 6.2A.1.
Sample 1Sample 2
Applicable Law and Applicable Codes and Standards. Contractor has investigated to its satisfaction Applicable Law and Applicable Codes and Standards, warrants and represents that the Estimated Total Contractor’s Compensation is a comprehensive, complete, and reasonable estimate to procure, construct, pre-commission, commission, start-up and test the Work, and warrants and represents that it can perform the Work within the Project Schedule in accordance with Applicable Law and Applicable Codes and Standards. Contractor shall perform the Work in accordance with Applicable Law and Applicable Codes and Standards, whether or not such Applicable Law or Applicable Codes and Standards came into effect before the Agreement Date or during the performance of the Work; provided, however, Contractor shall be entitled to a Change Order for Changes in Law to the extent allowed under Section 6.8A. Except for any Changes in Law for which Contractor is entitled to a Change Order under Section 6.8A, Contractor hereby waives any right to make any claim for adjustment of the Estimated Total Contractor’s Compensation or the Project Schedule in relation to any change in law.
Sample 1
Applicable Law and Applicable Codes and Standards. Contractor has investigated to its satisfaction Applicable Law in existence as of February 28, 2017December 2, 2021, and Applicable Codes and Standards set forth or listed in any document or Drawing listed in Attachment 1, and warrants that it can perform the Work at the Contract Price and within the Project Schedule in accordance with such Applicable Law and such Applicable Codes and Standards. Contractor shall perform the Work in accordance with Applicable Law and such Applicable Codes and Standards; provided, however, Contractor shall be entitled to a Change Order for any Change in Law to the extent allowed under Section 6.2A.1. Contractor shall advise Owner of any change in Applicable Codes and Standards which does not constitute a Change in Law and, upon such advisement, Owner may elect, at its sole option, to implement a change in accordance with Section 6.1D. The Parties agree that the below excerpts of Section 5.2C and D of the Phase 1 EPC Agreement are modified or added, as applicable, (blue text are additions and red text are deletions) as follows:
Sample 1
Applicable Law and Applicable Codes and Standards. Contractor has investigated to its satisfaction Applicable Law and Applicable Codes and Standards and warrants that it can perform the Work at the Contract Price and within the Guaranteed Dates in accordance with such Applicable Law and Applicable Codes and Standards, provided however that for Applicable Codes and Standards that are not set forth in Applicable Law, Contractor shall perform the Work in accordance with the Applicable Codes and Standards in effect as of June 23, 2017. Contractor shall perform the Work in accordance with Applicable Law and Applicable Codes and Standards, whether or not such Applicable Law or Applicable Codes and Standards came into effect before the Agreement Date or during the performance of the Work; provided, however, Contractor shall be entitled to a Change Order for Changes in Law to the extent allowed under Section 6.2A.7. Except for any Changes in Law for which Contractor is entitled to a Change Order under Section 6.2A.7 or any Changes in U.S. Duties and Tariffs under Section 6.2A.10 or any Changes in Non-U.S. Duties and Tariffs under Section 6.2A.13, Contractor hereby waives any right to make any claim for adjustment to the Changed Criteria in relation to any change in Applicable Law or Applicable Codes and Standards, including any changes in duties or tariffs.
Sample 1
AutoNDA by SimpleDocs
Applicable Law and Applicable Codes and Standards. Contractor has investigated to its satisfaction Applicable Law and Applicable Codes and Standards and warrants that it can perform the Work at the Estimated Total Contractor’s Compensation and within the Project Schedule in accordance with Applicable Law and Applicable Codes and Standards. Contractor shall perform the Work in accordance with Applicable Law and Applicable Codes and Standards, whether or not such Applicable Law or Applicable Codes and Standards came into effect before the Agreement Date or during the performance of the Work; provided, however, Contractor shall be entitled to a Change Order for Changes in Law to the extent allowed under Section 6.8A. Except for any Changes in Law for which Contractor is entitled to a Change Order under Section 6.8A, Contractor hereby waives any right to make any claim for adjustment of the Estimated Total Contractor’s Compensation or the Project Schedule in relation to any Changes in Law.
Sample 1

Related to Applicable Law and Applicable Codes and Standards

  • Compliance with Applicable Laws, Rules and Regulations The Dealer Manager represents to the Company that (a) it is a member of FINRA in good standing, and (b) it and its employees and representatives who will perform services hereunder have all required licenses and registrations to act under this Agreement. With respect to its participation and the participation by each Participating Dealer in the offer and sale of the Offered Shares (including, without limitation, any resales and transfers of Offered Shares), the Dealer Manager agrees, and, by virtue of entering into the Participating Dealer Agreement, each Participating Dealer shall have agreed, to comply with any applicable requirements of the Securities Act and the Exchange Act, applicable state securities or blue sky laws, and, specifically including, but not in any way limited to, NASD Conduct Rules 2340 and 2420, and FINRA Conduct Rules 2310, 5130 and 5141.

  • Compliance with Applicable Laws and Governing Documents In the performance of its services under this Agreement, the Subadviser shall act in conformity with the Prospectus, SAI and the Trust’s Agreement and Declaration of Trust and By-Laws as currently in effect and, as soon as practical after the Trust, the Fund or the Adviser notifies the Subadviser thereof, as supplemented, amended and/or restated from time to time (referred to hereinafter as the “Declaration of Trust” and “By-Laws,” respectively) and with the instructions and directions received in writing from the Adviser or the Trustees of the Trust and will conform to, and comply with, the requirements of the 1940 Act, the Internal Revenue Code of 1986, as amended (the “Code”), and all other applicable federal and state laws and regulations. Without limiting the preceding sentence, the Adviser promptly shall notify the Subadviser as to any act or omission of the Subadviser hereunder that the Adviser reasonably deems to constitute or to be the basis of any noncompliance or nonconformance with any of the Trust’s Declaration of Trust and By-Laws, the Prospectus and the SAI, the instructions and directions received in writing from the Adviser or the Trustees of the Trust, the 1940 Act, the Code, and all other applicable federal and state laws and regulations. Notwithstanding the foregoing, the Adviser shall remain responsible for ensuring the Fund’s and the Trust’s overall compliance with the 1940 Act, the Code and all other applicable federal and state laws and regulations and the Subadviser is only obligated to comply with this subsection (b) with respect to the Subadviser Assets. The Adviser timely will provide the Subadviser with a copy of the minutes of the meetings of the Board of Trustees of the Trust to the extent they may affect the Fund or the services of the Subadviser, copies of any financial statements or reports made by the Fund to its shareholders, and any further materials or information which the Subadviser may reasonably request to enable it to perform its functions under this Agreement. The Adviser shall perform quarterly and annual tax compliance tests to ensure that the Fund is in compliance with Subchapter M of the Code. In this regard, the Adviser acknowledges that the Subadviser shall rely completely upon the Adviser’s determination of whether and to what extent the Fund is in compliance with Subchapter M of the Code and that the Subadviser has no separate and independent responsibility to test the Fund for such compliance. In connection with such compliance tests, the Adviser shall inform the Subadviser at least ten (10) business days prior to a calendar quarter end if the Subadviser Assets are out of compliance with the diversification requirements under Subchapter M. If the Adviser notifies the Subadviser that the Subadviser Assets are not in compliance with such requirements noted above, the Subadviser will take prompt action to bring the Subadviser Assets back into compliance within the time permitted under the Code thereunder. The Adviser will provide the Subadviser with reasonable advance notice of any change in the Fund’s investment objectives, policies and restrictions as stated in the Prospectus and SAI, and the Subadviser shall, in the performance of its duties and obligations under this Agreement, manage the Subadviser Assets consistent with such changes, provided that the Subadviser has received prompt notice of the effectiveness of such changes from the Trust or the Adviser. In addition to such notice, the Adviser shall provide to the Subadviser a copy of a modified Prospectus and SAI reflecting such changes. The Adviser acknowledges and will ensure that the Prospectus and SAI will at all times be in compliance with all disclosure requirements under all applicable federal and state laws and regulations relating to the Trust or the Fund, including, without limitation, the 1940 Act, and the rules and regulations thereunder, and that the Subadviser shall have no liability in connection therewith, except as to the accuracy of material information furnished in writing by the Subadviser to the Trust or to the Adviser specifically for inclusion in the Prospectus and SAI. The Subadviser hereby agrees to provide to the Adviser in a timely manner such information relating to the Subadviser and its relationship to, and actions for, the Trust as may be required to be contained in the Prospectus, SAI or in the Trust’s Registration Statement on Form N-1A and any amendments thereto.

  • Compliance with Applicable Laws and Regulations (a) To the best of Borrower’s knowledge after due inquiry and investigation, each of the following is true: (i) All Improvements and the use of the Mortgaged Property comply with all applicable statutes, rules and regulations, including all applicable statutes, rules and regulations pertaining to requirements for equal opportunity, anti-discrimination, fair housing, environmental protection, zoning and land use (“legal, non-conforming” status with respect to uses or structures will be considered to comply with zoning and land use requirements for the purposes of this representation). (ii) The Improvements comply with applicable health, fire, and building codes. (iii) There is no evidence of any illegal activities relating to controlled substances on the Mortgaged Property. (b) Reserved.

  • Applicable Laws and Regulations All duly promulgated applicable federal, state and local laws, regulations, rules, ordinances, codes, decrees, judgments, directives, or judicial or administrative orders, permits and other duly authorized actions of any Governmental Authority having jurisdiction over the relevant parties, their respective facilities, and/or the respective services they provide.

  • Applicable Law, Etc This Agreement shall be interpreted, construed, applied and enforced in accordance with the laws of the State applicable to contracts between residents of the State which are to be performed entirely within the State, regardless of (i) where this Agreement is executed or delivered; or (ii) where any payment or other performance required by this Agreement is made or required to be made; or (iii) where any breach of any provision of this Agreement occurs, or any cause of action otherwise accrues; or (iv) where any action or other proceeding is instituted or pending; or (v) the nationality, citizenship, domicile, principal place of business, or jurisdiction of organization or domestication of any party; or (vi) whether the laws of the forum jurisdiction otherwise would apply the laws of a jurisdiction other than the State; or (vii) any combination of the foregoing. To the maximum extent permitted by applicable law, any action to enforce, arising out of, or relating in any way to, any of the provisions of this Agreement may be brought and prosecuted in such court or courts located in the State as is provided by law; and the parties consent to the jurisdiction of said court or courts located in the State and to service of process by registered mail, return receipt requested, or by any other manner provided by law.

  • Applicable Standards The requirements and guidelines of NERC, the Applicable Regional Entity, and the Control Area in which the Customer Facility is electrically located; the PJM Manuals; and Applicable Technical Requirements and Standards.

  • Compliance with all Applicable Laws and Regulations Grantee must comply with all applicable federal, state and local laws, rules, regulations, and ordinances in administering CRF under this Agreement. Grantee acknowledges that this requirement includes, but is not limited to, compliance with all applicable federal, state, and local health and safety rules and regulations. Grantee’s failure to comply with any part of this provision is material and must be grounds for termination of this Agreement for cause by Florida Housing.

  • Functional Requirements Applications must implement controls that protect against known vulnerabilities and threats, including Open Web Application Security Project (OWASP) Top 10 Risks and denial of service (DDOS) attacks.

  • Legal Requirements All applicable Federal and State laws and County ordinances that in any manner affect the items covered herein apply. Lack of knowledge by the Bidder shall in no way be a cause for relief from responsibility. A. Contractors doing business with the County are prohibited from discriminating against any employees, applicant, or client because of race, religion, color, disability, national origin, gender, or age with regard to but not limited to the following: employment practices, rates of pay or other compensation methods, and training selection. B. Businesses wishing to participate in the County procurement process as an Orange County Certified M/WBE firm are required to complete a certification application to attain recognition as such. You may contact the Procurement Division or the Business Development Division for information and assistance.

  • Federal Requirements In the event this Contract is paid in whole or in part from any federal government agency or source, the specific terms, regulations and requirements governing the disbursement of these funds shall be specified herein and become a part of this clause.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!