Assessment of Monetary Damages Sample Clauses

Assessment of Monetary Damages. (A) The City may assess against Grantee monetary damages (i) up to five hundred dollars ($500.00) per day for general construction delays, violations of PEG obligations or payment obligations, (ii) up to two hundred fifty dollars ($250.00) per day for any other material breaches, or (iii) up to one hundred dollars ($100.00) per day for defaults, and withdraw the assessment from the letter of credit or collect the assessment as specified in this Franchise. Damages pursuant to this Section shall accrue for a period not to exceed one hundred twenty (120) days per violation proceeding. To assess any amount from the letter of credit, City shall follow the procedures for withdrawals from the letter of credit set forth in the letter of credit and in this Franchise. Such damages shall accrue beginning thirty (30) days following Grantee’s receipt of the notice required by subsection 13.1(A), or such later date if approved by the City in its sole discretion, but may not be assessed until after the procedures in subsection 13.1 have been completed.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Assessment of Monetary Damages. (A) Upon completion of the procedures set forth above, and from the date of said violation pursuant to the procedures specified in this Franchise, Grantor may assess against and collect from Grantee monetary damages in amounts of up to five hundred dollars ($500.00) per day or the City’s actual damages, whichever is greater, for general construction delays, and up to two hundred dollars ($200.00) per day for any other material breaches for a maximum of ninety (90) days or until said breaches have been cured. Grantor may collect the assessment as specified in this Franchise.
Sample 1
Assessment of Monetary Damages. (A) Subject to the terms of this Franchise, Grantor may assess against Grantee monetary damages (i) up to five hundred dollars ($500.00) per day for general construction delays,
Sample 1
Assessment of Monetary Damages. (A) The Grantor may assess against Grantee monetary damages (i) up to five hundred dollars ($500.00) per day for general construction delays or payment obligations, (ii) up to two hundred fifty dollars ($250.00) per day for any other material breaches, or (iii) up to one hundred dollars ($100.00) per day for defaults, and withdraw the assessment from the letter of credit or collect the assessment as specified in this Franchise. Damages pursuant to this Section shall accrue for a period not to exceed one hundred twenty (120) days per violation proceeding. To assess any amount from the letter of credit, Grantor shall follow the procedures for withdrawals from the letter of credit set forth in the letter of credit and in this Franchise. Such damages shall accrue beginning thirty (30) days following Xxxxxxx’s receipt of the notice required by subsection 13.1(A), or such later date if approved by the Grantor in its sole discretion, but may not be assessed until after the procedures in subsection 13.1 have been completed.
Sample 1
Assessment of Monetary Damages. Upon completion of the procedures set forth in subsection 13.1, and from the date of said completion, the Town may assess against Grantee monetary damages up to two hundred dollars ($200.00) per day for any material breaches, or up to one hundred dollars ($100.00) per day for other defaults, and withdraw the assessment from the letter of credit or collect the assessment as specified in this Franchise. To assess any amount from the letter of credit, the Town shall follow the procedures for withdrawals from the letter of credit set forth in the letter of credit and in this Franchise. The assessment does not constitute a waiver by Town of any other right or remedy it may have under the Franchise or applicable law, including its right to recover from Grantee any additional damages, losses, costs and expenses that are incurred by Town by reason of the breach of this Franchise.
Sample 1
Assessment of Monetary Damages. (A) The Grantor may assess against Grantee monetary damages of (i) up to five hundred dollars ($500.00) per day for any general construction delays, (ii) up to two hundred fifty dollars ($250.00) for failure to provide EG Channels, or (iii) up to one hundred dollars ($100.00) per day for any other material breaches. Damages pursuant to this Section shall accrue for a period not to exceed one hundred twenty (120) days per violation proceeding. Such damages shall accrue beginning thirty (30) days following Grantee’s receipt of the notice required by subsection 13.1(A), or such later date if approved by the Grantor in its sole discretion, but may not be assessed until after the procedures in subsection 13.1 have been completed.
Sample 1
Assessment of Monetary Damages. 15.2 Revocation .................................................................................................................
Sample 1
AutoNDA by SimpleDocs
Assessment of Monetary Damages. (A) Upon completion of the procedures set forth above and after all appeals have been exhausted, and from the date of said violation pursuant to the procedures specified in this Franchise, the City may assess against and collect from Grantee monetary damages in amounts as set forth below:
Sample 1

Related to Assessment of Monetary Damages

  • Payment of Money to Province The Recipient will pay any money owing to the Province by cheque payable to the “Ontario Minister of Finance” and delivered to the Province as provided for in Schedule “B".

  • Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.

  • Remedy Damages The Contractor shall promptly remedy damages and loss to property at the Site caused by the Contractor, by any Subcontractor, by anyone directly or indirectly employed by the Contractor or any such Subcontractor, or by anyone for whose acts the Contractor or any such Subcontractor may be liable. Should the Contractor cause damage to any Separate Contractor‘s work, the Contractor agrees, upon due notice, to settle with the Separate Contractor.

  • Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.

  • Property Damages The User’s guests are required to respect all University property. • Guests may not remodel, alter, tamper with or move furniture, electrical or mechanical fixtures, or other University property. • The User agrees to refrain from the use of adhesives, nails, or items that may damage the premises. No decorations or temporary fixtures may be affixed to plants, trees, woodwork, buildings or any architectural feature with nails, tacks, staples, or any application that will cause irreversible damage to landscaping or structures. Duct tape and white masking tape are not permitted on any building, hardscape or lighting fixtures. Neither lights nor decorations may be placed on trees or plants. • Any outdoor signage must be reviewed and approved by University prior to installation. Stakes may not be placed deeper than 5 inches into the grass in order to protect sprinklers and other underground pipes. • Charges will be assessed on the Final Invoice for damages to buildings, furniture, lawns and/or equipment. The University will, to the best of its ability, try to document the names of guests when damages occur but cannot always obtain such information.

  • Claims for Consequential Damages The Owner retains its right to claim for consequential damages in the event the Design Professional fails to perform under this Contract.

  • Damages Should the registration or the effectiveness thereof required by Sections 5.1 and 5.2 hereof be delayed by the Company or the Company otherwise fails to comply with such provisions, the Holder(s) shall, in addition to any other legal or other relief available to the Holder(s), be entitled to obtain specific performance or other equitable (including injunctive) relief against the threatened breach of such provisions or the continuation of any such breach, without the necessity of proving actual damages and without the necessity of posting bond or other security.

  • CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.

  • Payment of Monies Any other monies payable under this Agreement, unless otherwise specified in this Agreement, shall be paid by wire transfer.

  • Judgments To the extent permitted by applicable law, if any judgment or order expressed in a currency other than the Contractual Currency is rendered (i) for the payment of any amount owing in respect of this Agreement, (ii) for the payment of any amount relating to any early termination in respect of this Agreement or (iii) in respect of a judgment or order of another court for the payment of any amount described in (i) or (ii) above, the party seeking recovery, after recovery in full of the aggregate amount to which such party is entitled pursuant to the judgment or order, will be entitled to receive immediately from the other party the amount of any shortfall of the Contractual Currency received by such party as a consequence of sums paid in such other currency and will refund promptly to the other party any excess of the Contractual Currency received by such party as a consequence of sums paid in such other currency if such shortfall or such excess arises or results from any variation between the rate of exchange at which the Contractual Currency is converted into the currency of the judgment or order for the purposes of such judgment or order and the rate of exchange at which such party is able, acting in a reasonable manner and in good faith in converting the currency received into the Contractual Currency, to purchase the Contractual Currency with the amount of the currency of the judgment or order actually received by such party. The term "rate of exchange" includes, without limitation, any premiums and costs of exchange payable in connection with the purchase of or conversion into the Contractual Currency.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!