Loss or Damage Lessee hereby assumes and shall bear the entire risk of any loss, theft, damage to, or destruction of, any unit of Equipment from any cause whatsoever from the time the Equipment is shipped to Lessee.
Responsibility For Damages Or Injury The County its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) shall not be answerable or accountable in any manner: for any loss or damage that may happen to the Project or any part thereof; for any loss or damage to any of the materials or other things used or employed in performing the Project; for injury to or death of any person either workers or the public; or for damage to property from any cause which might have been prevented by the Contractor, or his workers, or anyone employed by him. The Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects or obstructions or from any cause whatsoever during the progress of the Project or at any time before its completion and final acceptance. The Contractor shall indemnify, defend with counsel approved in writing by County and save harmless the County Indemnitees from all claims, suits or actions of every name, kind and description, brought for, or on account of, injuries to or death of any person or damage to property resulting from the construction of the Project or by or in consequence of any negligence in guarding the Project; use of improper materials in construction of the Project; or by or on account of any act or omission by the Contractor or his agents during the progress of the Work or at any time before the completion and final acceptance of the Project. In addition to any remedy authorized by law, so much of the money due the Contractor under and by virtue of the Contract as shall be considered necessary by the County may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County and County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither Party shall request a jury apportionment. Notwithstanding anything stated above, nothing contained herein shall relieve Contractor of any insurance requirements of obligations created elsewhere in this Contract.
Indemnity Consequential Damages and Insurance 18.1 Indemnity 18.1.1 Indemnified Party 18.1.2 Indemnifying Party 18.1.3 Indemnity Procedures 18.2 Consequential Damages 18.3 Insurance 18.3.1 18.3.2 18.3.3 18.3.4 18.3.5 18.3.6 18.3.7 18.3.8 18.3.9 18.3.10 18.3.11
No Floor Damage not keep any heavy articles or things that are likely to damage the floors or install and operate any machine or equipment save usual home appliances.
Compensation for Damages or Losses When investments by investors of either Contracting Party suffer damages or losses owing to war, armed conflict, a state of national emergency, revolt, insurrection, riot or other similar events in the territory of the other Contracting Party, they shall be accorded by the latter Contracting Party a treatment, as regards compensation or other settlement, not less favourable than that accorded to its own investors or to investors of any Third State.
Consequential Damages Neither party to this Agreement shall be liable to the other party for special, indirect or consequential damages under any provision of this Agreement or for any special, indirect or consequential damages arising out of any act or failure to act hereunder.
Consequential Damages Waiver NEITHER PARTY SHALL HAVE ANY LIABILITY ARISING OUT OF OR RELATED TO THIS AGREEMENT FOR ANY LOSS OF USE, LOST DATA, LOST PROFITS, FAILURE OF SECURITY MECHANISMS, INTERRUPTION OF BUSINESS, LOSS CAUSED BY THE INTERRUPTION, TERMINATION OR DELAYED OPERATION OF THE INTERNET, THIRD-PARTY TELECOMMUNICATION SERVICES OR THIRD-PARTY SECURITY FEATURES OR SYSTEMS, EXCEPT AS REQUIRED BY LAW. EXCEPT FOR CUSTOMER’S BREACH OF SECTION 1.4 (USE RESTRICTIONS) OR EITHER PARTY’S UNLAWFUL OR WILLFUL MISCONDUCT OR GROSS NEGLIGENCE, NEITHER PARTY SHALL BE LIABLE FOR ANY INDIRECT, SPECIAL, INCIDENTAL, EXEMPLARY, PUNITIVE, RELIANCE, OR CONSEQUENTIAL DAMAGES OF ANY KIND, EVEN IF INFORMED OF THE POSSIBILITY IN ADVANCE, SUFFERED BY ANY PARTY OR ANY PARTY CLAIMING ON BEHALF OF OR THROUGH THE OTHER PARTY, OR ANY OTHER THIRD PARTY RESULTING FROM OR ARISING OUT OF OR RELATED TO THIS AGREEMENT OR THE PERFORMANCE OR BREACH THEREOF.
Damages and Costs You agree to pay for damages, lost property or extraordinary service or administrative costs you, your designated roommate or your guests cause to University residence facilities whether through accident, neglect or intent. See Appendix II for more information about assessments. All residents of a floor or unit may be assessed for cleaning, damages, lost property or extraordinary service costs where the person(s) responsible cannot be ascertained by the University but where the damages, lost property, or excessive mess were reasonably believed by Student Housing and Hospitality Services to be caused by one or more residents of a floor or unit. Where charges and costs have not been paid by the specified date, a late fee will be added. Failure to pay assessments may result in the relocation of you or other resident(s) to another floor or unit, denial of future residence assignment or eviction from residence. To appeal an assessment you must follow the written appeal procedure outlined on the assessment form. Appeals will only be considered if you are not in arrears for any other fees, charges or amounts owed to Student Housing and Hospitality Services.
No Consequential Damages Other than the Liquidated Damages heretofore described and the indemnity obligations set forth in Article 18.1, in no event shall any Party be liable under any provision of this Agreement for any losses, damages, costs or expenses for any special, indirect, incidental, consequential, or punitive damages, including but not limited to loss of profit or revenue, loss of the use of equipment, cost of capital, cost of temporary equipment or services, whether based in whole or in part in contract, in tort, including negligence, strict liability, or any other theory of liability; provided, however, that damages for which a Party may be liable to another Party under separate agreement will not be considered to be special, indirect, incidental, or consequential damages hereunder.
Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.