Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.
NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
STOP WORK NOTICE The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice.
Notice of Force Majeure If performance is delayed as a result of Force Majeure, the affected party shall provide prompt Notice to the other party and shall be excused from default or delay in performance while such circumstances prevail so long as such party continues to use commercially reasonable efforts to recommence performance as soon as possible.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Notice of Force Majeure Event 14.2.1. As soon as practicable and in any case within 3 days of the date of occurrence of a Force Majeure Event or the date of knowledge thereof, the Party which is rendered wholly or partially unable to perform any of its obligations under this Agreement because of a Force Majeure Event (the “Affected Party”) shall notify the other party of the same, setting out, inter alia, the following in reasonable detail:
a) The nature and extent of the Force Majeure Event ;
b) The estimated period for which the Force Majeure Event is expected to last;
c) The nature of and the extent to which, performance of any of its obligations under this Agreement is affected by the Force Majeure Event;
d) The measures which the Affected Party has taken or proposes to take to alleviate/mitigate the impact of the Force Majeure Event and to resume performance of such of its obligations affected thereby; and
e) Any other relevant information concerning the Force Majeure Event, and /or the rights and obligations of the Parties under this Agreement.
Notice of Decision If the Plan Administrator denies part or all of the claim, the Plan Administrator shall notify the claimant in writing of such denial. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:
(a) The specific reasons for the denial;
(b) A reference to the specific provisions of the Agreement on which the denial is based;
(c) A description of any additional information or material necessary for the claimant to perfect the claim and an explanation of why it is needed;
(d) An explanation of the Agreement’s review procedures and the time limits applicable to such procedures; and
(e) A statement of the claimant’s right to bring a civil action under ERISA Section 502(a) following an adverse benefit determination on review.
CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.
Notice to Landlord (1) If Tenant shall, on one or more occasions, mortgage Tenant’s Leasehold Estate and if the holder of such Permitted Leasehold Mortgage shall provide Landlord with written notice of such Permitted Leasehold Mortgage together with a true copy of such Permitted Leasehold Mortgage and the name and address of the Permitted Leasehold Mortgagee, Landlord and Tenant agree that, following receipt of such written notice by Landlord, the provisions of this Section 17.1 shall apply in respect to each such Permitted Leasehold Mortgage.
(2) In the event of any assignment of a Permitted Leasehold Mortgage or in the event of a change of address of a Permitted Leasehold Mortgagee or of an assignee of such Mortgage, written notice of the new name and address shall be provided to Landlord.
(ii) Landlord shall promptly upon receipt of a communication purporting to constitute the notice provided for by subsection (b)(i) above acknowledge by an executed and notarized instrument receipt of such communication as constituting the notice provided for by subsection (b)(i) above and confirming the status of the Permitted Leasehold Mortgagee as such or, in the alternative, notify the Tenant and the Permitted Leasehold Mortgagee of the rejection of such communication as not conforming with the provisions of this Section 17.1 and specify the specific basis of such rejection.
(iii) After Landlord has received the notice provided for by subsection (b)(i) above, the Tenant, upon being requested to do so by Landlord, shall with reasonable promptness provide Landlord with copies of the note or other obligation secured by such Permitted Leasehold Mortgage and of any other documents pertinent to the Permitted Leasehold Mortgage as specified by the Landlord. If requested to do so by Landlord, Tenant shall thereafter also provide the Landlord from time to time with a copy of each amendment or other modification or supplement to such instruments. All recorded documents shall be accompanied by the appropriate recording stamp or other certification of the custodian of the relevant recording office as to their authenticity as true and correct copies of official records and all nonrecorded documents shall be accompanied by a certification by Tenant that such documents are true and correct copies of the originals. From time to time upon being requested to do so by Landlord, Tenant shall also notify Landlord of the date and place of recording and other pertinent recording data with respect to such instruments as have been recorded.
Force Majeure Notice In relation to any Relevant Force Majeure Event:
(a) as soon as reasonably practicable after the Affected Party becomes aware, or ought reasonably to have become aware, that such Force Majeure Event qualifies for relief under this Clause 17 (and, in any event, within 72 hours of becoming aware of such circumstances), the Affected Party shall give a Force Majeure Notice; and
(b) the Force Majeure Notice shall include detailed particulars (to the extent available) of the Relevant Force Majeure Event and its consequences, its effects on the Affected Party, the Relevant Obligations, the likely duration of such consequences and effects and the remedial measures proposed by the Affected Party to avoid or remove the Relevant Force Majeure Event or to mitigate its consequences and effects.
