Change Order Administration Sample Clauses

Change Order Administration. 8.1.4.1.1 Review all Contractor proposals for change orders and supporting schedules for time extension requests. For change orders in excess of $100.000, prepare independent cost estimate analysis with associated schedule impact.
Sample 1Sample 2See All (5)
AutoNDA by SimpleDocs
Change Order Administration. 8.1.4.1.1 Review all Contractor proposals for change orders and supporting schedules for time extension requests.
Sample 1
Change Order Administration. The OPM shall:
Sample 1
Change Order Administration. 8.1.4.1.1 Review all CM at Risk proposals for change orders and supporting schedules for time extension requests. For change orders in excess of $100,000, prepare independent cost estimate analysis with associated schedule impact.
Sample 1

Related to Change Order Administration

  • Construction Administration Redeveloper shall be responsible for all components of the Redeveloper Improvements constructed by Redeveloper including construction management, coordination of contractors and regulatory permitting and other requirements. Redeveloper and its contractor(s) shall reasonably cooperate with City contractors performing work in the vicinity of the Redevelopment Project Area including, but not limited to, Redeveloper's scheduling of its work to provide for a smooth sequence of operations. The Redeveloper will be solely responsible for payment of all construction costs for the Redeveloper Improvements as set forth in this Redevelopment Agreement.

  • Purchase Order Flip via Ariba Network (AN) The online process allows suppliers to submit invoices via the AN for catalog and non- catalog goods and services. Contractors have the ability to create an invoice directly from their Inbox in their AN account by simply “flipping” the purchase order into an invoice. This option does not require any special software or technical capabilities. For the purposes of this section, the Contractor warrants and represents that it is authorized and empowered to and hereby grants the State and the third-party provider of MFMP the right and license to use, reproduce, transmit, distribute, and publicly display within the system the information outlined above. In addition, the Contractor warrants and represents that it is authorized and empowered to and hereby grants the State and the third-party provider the right and license to reproduce and display within the system the Contractor’s trademarks, system marks, logos, trade dress, or other branding designation that identifies the products made available by the Contractor under the Contract.

  • Settlement Administration The Settlement Administrator will conduct a skip trace for the address of all former employee Class Members. The Settlement Administrator will mail the Notice by first class U.S. mail to all Class Members at the address Defendants have on file for those Class Members and to all former employee Class Members at the address resulting from the skip trace. The Notice will inform Class Members that they have until the Response Deadline to either object to the Settlement or to opt-out of the Settlement. Any Class Member who does not receive Notice after the steps outlined above have been taken will still be bound by the Settlement and/or judgment.

Time is Money Join Law Insider Premium to draft better contracts faster.