Proposed Change Orders Clause Samples

Proposed Change Orders. (“PCO’s”). Subject to the provisions of ¶ VIII(C), upon Design-Builder’s receipt of an ITC, ASK, UGAA-issued PCO, an answer to an RFI, any modification or other direction by UGAA that could be perceived by Design-Builder as a change, or when Design-Builder discovers (or should with diligence discover) any other event, force majeure occurrence, circumstance, or differing site condition that will, or is likely to, in Design-Builder’s judgment, result in a change of Scope of Work (or change in Scope of Design Services) that materially increases Design-Builder’s costs or time to perform, or will otherwise impact GMP, Contract Time, or the Project Schedule (“triggering event”), Design-Builder shall, before performing the changed Work or Design Services involved, and in no case more than seven days after the triggering event, deliver to the ADR a detailed PCO (in substantially the same form as the Change Order supplied in Supplement B2, or in another form acceptable to the ADR, with content as required therein). Design-Builder’s timely satisfaction of the foregoing requirement to provide a detailed PCO is a condition precedent to any obligation of UGAA to pay for changed Work or Services. Absence of timely submittal of a PCO shall indicate that Design-Builder waives compensation and claims related to or arising out of the subject of the triggering event; and, thereafter, Design-Builder shall perform the Work according to those ITC’s (where signed by the ADR), ASK’s, UGAA-issued PCO, and answers to RFI’s, with subsequent Project and Completion Schedules modified accordingly. Mere receipt of a PCO shall not be construed as approval by UGAA of contents or assertions contained in the PCO – or any agreement on the part of UGAA that the proposal in any way justifies a Change Order.
View SourceView Similar (5)
Proposed Change Orders. The Design Professional, with approval of the University, shall issue to the Contractor a cost request Bulletin for a proposed change order describing the intended change and shall require the Contractor to indicate thereon a proposed amount to be added to or subtracted from the Contract Sum due to the change supported by a detailed estimate of cost. Upon request by the University, the Contractor shall permit inspection of the original Contract estimate, Trade Contract agreements, or purchase orders relating to the change. Any request for adjustment in Contract Time which is directly attributable to the changed Work shall be included with substantiating detailed explanation by the Contractor in its response to the cost request bulletin. Failure by Contractor to request adjustment of Contract Time on the response to the cost request Bulletin shall waive any right to subsequently claim an adjustment of the Contract Time based on the changed Work. The Contractor shall submit the response to the cost request Bulletin with detailed estimates and any time extension request thereon to the Design Professional within ten (10) days after issuance of the cost request Bulletin. Upon its submission, the Design Professional will review it and advise the University who will make the decision regarding the request. The University retains sole discretion to accept, reject, or modify the proposed change. If the Contractor fails to submit the response within the required ten (10) days, and the Contractor has not obtained the Design Professional’s and the University’s permission for a delay in submission, the University may order the Contractor in writing to begin the Work immediately, and the Contract Sum shall be adjusted in accordance with the University’s estimate of cost. In that event, the Contractor, within fifteen days following completion of the changed Work, may present information to the University that the University’s estimate was in error; the University, in its sole discretion, may adjust the Contract Sum. The Contractor must keep and submit to the University time and materials records verified by the University to substantiate its costs. The University may require the Contractor to proceed immediately with the changed Work in accordance with section 6.01.4, “Failure to Agree as to Cost” or section 6.02 “Emergency Changes.” When the University and the Contractor agree on the amount to be added to or deducted from the Contract Sum and the time to be added to or ...
View SourceView Similar (4)
Proposed Change Orders. The Trustees shall issue to the Licensee a cost request bulletin via the Construction Administrator, or a field instruction via the Project Manager/Construction Inspector, hereinafter called the cost request bulletin, for a proposed change order describing the intended change, and shall require the Licensee to respond with a proposed amount to be the Contract Price or, in the case of sequential Change Orders added to or subtracted from the Contract price due to the change supported by a detailed estimate of cost (hereinafter called a change order request). Upon request by the Trustees, Licensee shall permit inspection of the original Contract estimate, subcontract agreements, or purchase orders relating to the change. Any request for adjustment in time of final completion of the Project which is directly attributable to the changed Work shall also be included, with substantiating detailed explanation, by the Licensee in its response to the cost request bulletin. Licensee’s failure to request adjustment of time on the change order request shall waive any right to subsequently claim an adjustment of the time for final completion based on the changed Work. Licensee shall submit the change order request with detailed estimates and any time extension request thereon to the Trustees and to the Project Manager/Construction Inspector within fifteen (15) Days after issuance of the cost request bulletin. If not submitted within the required fifteen (15) Days, and the Licensee has not obtained the Trustees’ permission for a delay in submission, the Trustees may order the Licensee in writing to begin the Work immediately in accordance with Articles 38.01-c or 38.02, and the Contract price shall be adjusted in accordance with the Trustees’ estimate of cost, unless the Licensee within fifteen days following completion of the changed Work presents proof convincing to the Trustees that the Trustees’ estimate was in error. For any amount to be included in or added to a Contract price for the changed Work, the Trustees shall determine payment will be made in one of the following three ways: a lump sum amount, time and materials with a guaranteed maximum price, or time and materials with no guaranteed maximum price. If either of the latter two methods is agreed upon, Licensee shall keep and submit time and materials records verified daily by the Construction Inspector to substantiate its costs and to furnish such proof. When the Trustees and the Licensee agree on the amount ...
View SourceView Similar (3)
Proposed Change Orders 
View SourceView Similar (4)

Related to Proposed Change Orders

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

  • Change Order The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.

  • SCOPE CHANGES The Commissioner reserves the right to require, by written order, changes to the scope of the Contract, by altering, adding to or deducting from the Bid Specifications, such changes to be within the general scope of the Contract. If any such change causes an increase or decrease in the cost of, or the time required for, performance of any part of the work under the Contract, whether or not changed by the order, the Commissioner shall, upon notice from Contractor as hereafter stated, make an equitable adjustment in the Contract price, the delivery schedule or both and shall modify the Contract. The Contractor must assert its right to an adjustment under this clause within thirty days from the date of receipt of the written order. However, if the Commissioner decides that the facts justify it, the Commissioner may provide an adjustment without receipt of a proposal. Failure to agree to any adjustment shall be a dispute under the Disputes clause, provided, however, that nothing in this clause shall excuse the Contractor from proceeding with the Contract as changed.

  • Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.

  • Execution of Change Orders Change Orders shall be signed by the Contractor, ordinarily certified by the Design Professional, and approved by the Owner in accordance with the form of Change Order prescribed by the Owner. No request for payment by the Contractor for a Change Order shall be due, nor shall any such request appear on an Application for Payment, until the Change Order is executed by the Owner. In the event of emergency (see Article