Change to Scope Sample Clauses

Change to Scope. Any change to the Scope of Services shall be accomplished only by a written amendment signed by the parties. If Artist determines that a proposed change will require a change in the costs or the schedule, Artist shall advise County in writing within ten (10) calendar days of such determination. Artist shall furnish County with an itemized estimate of any adjustments to the costs or the schedule resulting from the proposed change. Artist must receive the written approval of Contract Administrator prior to Artist taking any action on a proposed change. During negotiations for a proposed change, Artist shall continue performance of this Agreement other than the terms and conditions to be addressed in the proposed change amendment, unless otherwise directed by County.
Sample 1Sample 2
AutoNDA by SimpleDocs
Change to Scope. Any minor change to the Scope of Services that does not increase the total cost to County (excluding the Contingency Reserve) under this Agreement or the timeline for Final Acceptance of the Artwork may be approved in writing by the Contract Administrator. Any other change to the Agreement or Scope of Services (including any change that would include payment from the Contingency Reserve) must be accomplished by a written amendment signed by the Parties. If Artist determines that a proposed change will require a change in the costs or the schedule, Artist must advise County in writing within ten (10) days following receipt of notice from the Contract Administrator of the proposed change, and Artist must promptly furnish County with an itemized estimate of any adjustments to the costs or the schedule resulting from the proposed change. Artist must receive the written approval of the Contract Administrator or County pursuant to this section prior to taking any action on a proposed change. During negotiations for a proposed change, Artist must continue performance in compliance with all then-current terms and conditions of this Agreement other than the item subject to the proposed change, unless otherwise directed by County.
Sample 1

Related to Change to Scope

  • Changes to Scope of Work The City of Nashua may, at any time, by written order, make changes to the general scope, character, or cost of this contract and in the services or work to be performed, either increasing or decreasing the scope, character, or cost of Independent Contractor's performance under the contract. Independent Contractor shall provide to the City of Nashua within 10 calendar days, a written proposal for accomplishing the change. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. If the change causes an increase or a decrease in Independent Contractor's cost or time required for performance of the contract as a whole, an equitable adjustment shall be made and the contract accordingly modified in writing. Any claim of Independent Contractor for adjustment under this clause shall be asserted in writing within 30 days of the date the City of Nashua notified Independent Contractor of the change. When Independent Contractor seeks changes, Independent Contractor shall, before any work commences, estimate their effect on the cost of the contract and on its schedule and notify the City of Nashua in writing of the estimate. The proposal for a change shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua will then determine in writing if Independent Contractor should proceed with any or all of the proposed change. Except as provided in this paragraph, Independent Contractor shall implement no change unless the City of Nashua in writing approves the change. Unless otherwise agreed to in writing, the provisions of this contract shall apply to all changes. The City of Nashua may provide verbal approval of a change when the City of Nashua, in its sole discretion, determines that time is critical or public health and safety are of concern. Any verbal approval shall be confirmed in writing as soon as practicable. Any change undertaken without prior City of Nashua approval shall not be compensated and is, at the City of Nashua's election, sufficient reason for contract termination.

  • Service Scope Business Services apply to a single corresponding registered Covered Product. Purchasers of Business Services receive a 2 year limited business warranty (see VIVE Enterprise Business Limited Warranty here for details), starting from the original purchase date of your Covered Product. Business Services include expedited usage technical support, expedited customer care services and VIVE online resources as set forth in these Terms and Conditions and (xxx.xxxx.xxx/xxxxxxx).

  • STATE’S ABILITY TO MODIFY SCOPE OF MASTER CONTRACT Subject to mutual agreement between the parties, Enterprise Services reserves the right to modify the goods and/or services included in this Master Contract; Provided, however, that any such modification shall be effective only upon thirty (30) days advance written notice; and Provided further, that any such modification must be within the scope of this Master Contract.

  • Change of Scope 16.1.1 The Authority may, notwithstanding anything to the contrary contained in this Agreement, require the provision of additional works and services which are not included in the Scope of the Project as contemplated by this Agreement (the “Change of Scope”). Any such Change of Scope shall be made in accordance with the provisions of this Article 16 and the costs thereof shall be expended by the Concessionaire and reimbursed to it by the Authority in accordance with Clause 16.3.

  • CHANGES IN SCOPE OF SERVICES Only the Xxxxxx County Board of Supervisors has the authority to agree to any extension of time, change order, change in the scope of work, change in the contract price, or other term or condition affecting either Contractor's or County's duties set forth herein. Adjustments in compensation, if any, shall be determined through negotiation between the parties to the Agreement and are subject to approval by the Board of Supervisors. Contractor acknowledges that no County staff person or County officer other than the Board of Supervisors has the power to amend the terms and conditions of this Agreement. Any change not so authorized in advance in writing by the Board of Supervisors shall be null and void.

  • Attachment A, Scope of Services The scope of services is amended as follows:

  • APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.

  • CHANGE OF T-PIN The Account Holder may change his T-PIN from time to time in accordance with the Bank’s prescribed procedure then prevailing. The Bank shall be entitled, in its reasonable discretion but without liability and without giving any reason, to reject any selection made by the Account Holder as his substituted T-PIN; if the Bank so approves, such substituted T-PIN, shall take effect from the time of receipt by the Bank of such instructions from the Account Holder. The Account Holder shall take all steps not to select such numbers as a substitute T-PIN which may easily be ascertained or otherwise facilitate fraud or forgery.

  • Change in Scope of Work Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.

  • Restrictions on Change of Scope (i) No Change of Scope shall be executed unless the Authority has issued the Change of Scope Order save and except any Works necessary for meeting any Emergency.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!