Letter of Understanding New Certifications If a participating Employer is newly certified by ONA at one of its owned Homes for its registered nurses, the existing standard non-monetary provisions in the central ONA/RN agreements will automatically apply to the nurses effective nine (9) months after the Employer receives notice to bargain from the Union or a Memorandum of Agreement or Interest Arbitration Award is received, whichever is earlier. These provisions include: Article 1 Article 2.03 Articles 2.05, 2.07 through 2.12 Articles 3 through 8 Articles 9.01 (d) only, 9.03 through 9.13, 9.15, 9.16, 9.17 Article 10
Letter of Understanding Grievance Commissioner System This is to confirm the discussion of the parties during collective bargaining that they are committed to encouraging early discussion and resolution of labour relations issues at the local level and seek to resolve grievances in a timely and cost-efficient manner. To that end, this is to confirm that pursuant to Article 8, the parties agree that the Employer and Union at individual Homes may agree to utilize the following process in order to resolve a particular grievance through the utilization of a joint mediation-arbitration procedure:
LETTER OF UNDERSTANDING NO 8 LETTER OF UNDERSTANDING NO. 9
Letter of Understanding Re Grievance Administration The central parties agree to develop a pilot project to assist the local parties with innovative and creative solutions to enhance grievance administration, such project could include regional review of grievances, regional mediation and/or regional panels of arbitrators. The parties will canvass their respective parties to elicit interest in participation in the project. The central parties agree to develop communication and promotional strategies regarding the best practices for professional development including identifying success stories; writing articles; and web-site application. To accomplish this objective, information will be acquired through a survey of practices of the Hospitals. The parties agree that from time to time they will endorse best practices that demonstrate creative joint quality of worklife initiatives.
Letter of Understanding Professional Responsibility For the life of this Collective Agreement, the parties agree as follows: The parties acknowledge and agree that professional responsibility concerns are most appropriately resolved expeditiously between them in the workplace. The parties commit to exhausting all reasonable efforts, which may include third party mediation, before an IAC hearing is conducted. The parties agree that resident care is enhanced if concerns relating to professional practice and workload are resolved in a timely and effective manner. The parties acknowledge that in most cases they will be able to find a resolution to these concerns. In exceptional circumstances, where concerns are not resolved, either party may proceed to an IAC hearing as they are entitled to under Article 19.01 of the Collective Agreement. Where the local parties enter into these agreements, the agreement may include one or more of the following principles:
Data Protection Impact Assessment and Prior Consultation Processor shall provide reasonable assistance to the Company with any data protection impact assessments, and prior consultations with Supervising Authorities or other competent data privacy authorities, which Company reasonably considers to be required by article 35 or 36 of the GDPR or equivalent provisions of any other Data Protection Law, in each case solely in relation to Processing of Company Personal Data by, and taking into account the nature of the Processing and information available to, the Contracted Processors.
LETTER OF UNDERSTANDING Between: And:
Acceptable Use Policy Agreement I understand that I must use school IT systems in a responsible way, to ensure that there is no risk to my safety or to the safety and security of the IT systems and other users. • I understand that the school will monitor my use of the IT systems, email and other digital communications. • I will treat my username and password like my toothbrush – I will not share it, nor will I try to use any other person’s username and password. • I will be aware of “stranger danger”, when I am communicating on-line. • I will not disclose or share personal information about myself or others when on-line. • If I arrange to meet people off-line that I have communicated with on-line, I will do so in a public place and take an adult with me. • I will immediately report any unpleasant or inappropriate material or messages or anything that makes me feel uncomfortable when I see it on-line. • I understand that the school IT systems are primarily intended for educational use and that I will not use the systems for personal or recreational use unless I have permission to do so. • I will not try (unless I have permission) to make large downloads or uploads that might take up internet capacity and prevent other users from being able to carry out their work. • I will not use the school IT systems for on-line gaming, on-line gambling, internet shopping, file sharing, or video broadcasting (e.g. YouTube), unless I have permission of a member of staff to do so. • I will respect others’ work and property and will not access, copy, remove or otherwise alter any other user’s files, without the owner’s knowledge and permission. • I will be polite and responsible when I communicate with others, I will not use strong, aggressive or inappropriate language and I appreciate that others may have different opinions. • I will not take or distribute images of anyone without their permission. • I will only use my personal hand held / external devices (mobile phones / USB devices etc) in school if I have permission. I understand that, if I do use my own devices in school, I will follow the rules set out in this agreement, in the same way as if I was using school equipment. • I understand the risks and will not try to upload, download or access any materials which are illegal or inappropriate or may cause harm or distress to others, nor will I try to use any programmes or software that might allow me to bypass the filtering / security systems in place to prevent access to such materials.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
240104 Vendor Agreement If responding to Part 1 the Vendor Agreement Signature Form (Part 1) must be downloaded from the “Attachments” section of the IonWave eBid System, reviewed, properly completed, and uploaded to this location. If Vendor has proposed deviations to the Vendor Agreement (Part 1), Vendor may leave the signature line of this page blank and assert so in the Attribute Questions and those shall be addressed during evaluation. Vendor must upload their current IRS Tax Form W-9. The legal name, EIN, and d/b/a's listed should match the information provided herein exactly. This form will be utilized by TIPS to properly identify your entity. Claim Form.pdf