Conditions for Advance and Conditions to Closing Section 7.1.
Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Buyer’s Conditions for Closing Unless otherwise waived in writing, and without prejudice to Buyer’s right to terminate this Contract during the Review Period, the duties and obligations of Buyer to proceed to Closing under the terms and provisions of this Contract are and shall be expressly subject to strict compliance with, and satisfaction or waiver of, each of the conditions and contingencies set forth in this Section 9.1, each of which shall be deemed material to this Contract. In the event of the failure of any of the conditions set forth in this Section 9.1 or of any other condition to Buyer’s obligations provided for in this Contract, which condition is not waived in writing by Buyer, Buyer shall have the right at its option to terminate this Contract, in which case the Xxxxxxx Money Deposit shall be immediately returned to Buyer and each of the parties shall be relieved from further liability to the other, except as otherwise expressly provided herein, with respect to this Contract.
(a) All of Seller’s representations and warranties contained in or made pursuant to this Contract shall be true and correct in all material respects as if made again on the Closing Date.
(b) Buyer shall have received all of the instruments and conveyances listed in Section 10.2.
(c) Seller shall have performed, observed and complied in all material respects with all of the covenants, agreements, closing requirements and conditions required by this Contract to be performed, observed and complied with by Seller, as and when required hereunder.
(d) Third Party Consents in form and substance reasonably satisfactory to Buyer shall have been obtained and furnished to Buyer.
(e) The Existing Franchise Agreement shall have been terminated.
(f) The Existing Management Agreement shall have been terminated and Buyer and the Manager shall have executed and delivered the New Management Agreement consistent with the form attached hereto as Exhibit E.
(g) Buyer and Franchisor shall have executed (or Franchisor has unconditionally committed to execute) the New Franchise Agreement.
(h) Seller shall have complied, in all material respects, with its obligations under the thirteen (13) other purchase contracts (“Other Contracts”), each of even date herewith and all of which are more particularly described on Exhibit K hereto; and Seller shall be unconditionally prepared to close on the sale of the hotel properties described in the Other Contracts (“Other Properties”) simultaneously with Closing on the Property.
Conditions for Closing The Lender shall not be obligated to disburse the Bridge Loan until the Borrower shall have fulfilled and/or furnished to the Lender, at the Borrower’s own cost and expense, the following conditions (unless waived in writing by Lender):
(a) The Loan Documents duly executed by the Borrower and each Guarantor (as applicable) along with evidence that all financing statements and other filings contemplated thereby have been made and the Security Documents to be placed of record or filed shall have been duly executed and recorded and filed in all appropriate offices and shall constitute a first and prior Lien on the Collateral, subject only to those matters set forth in Section 6.01 of this Agreement and all taxes, fees and charges in connection therewith shall have been paid.
(b) Evidence, in form and substance satisfactory to the Lender, that the Aircraft, business and all assets of the Borrower are adequately insured as required by Section 5.04.
(c) Payment of the Origination Fee and all reimbursable costs and expenses pursuant to the Loan Documents, together with evidence of payment to other parties of all fees and costs which Borrower is required under the Loan Documents to pay by the Closing Date.
(d) Lien searches (including Uniform Commercial Code, judgments, bankruptcy and taxes) with respect to the Borrower and each Guarantor (at the state and county level) from the jurisdiction of its organization and each other jurisdiction in which it maintains an office, including the home airport of the Aircraft, (i) showing no existing Liens on the Collateral pledged by such Persons except as permitted hereunder or (ii) accompanied by necessary termination statements, release statements and any other types of release in connection with any impermissible Liens disclosed by such searches that have been filed or for which satisfactory arrangements have been made for such filing on the Closing Date.
(e) With respect to the Aircraft, (i) an FAA and International Registry lien and title search acceptable to the Lender, (ii) a copy of Aircraft Registration Certificate, (iii) lien and title searches of the applicable Canadian government authorities, including without limitation under the Personal Property Security Act, in form acceptable to the Lender, (iv) evidence that the Borrower has become a Transaction User Entity (as defined in the International Registry) and appointed an administrator and a professional registry user entity, in form and substance satisfactory to the Lender, (v) reasonable evidence that the Aircraft is eligible for prompt issuance of a U.S. Certificate of Airworthiness following the Aircraft’s transfer of title to Borrower, (vi) Completed Customs and Border Protection Forms 7501 and 3461 evidencing importation into the U.S., and (vii) a copy of the airframe, engine, and avionics maintenance programs.
(f) Copies of all of the Aircraft Contracts in effect as of the Closing Date, in form and substance reasonably acceptable to the Lender.
(g) A copy of the Borrower’s and each Guarantor’s organizational documents, in form and substance satisfactory to the Lender.
(h) A certificate of existence, authorization, good standing certificate, or its equivalent of each of the Borrower and the Guarantor from the Secretary of State of such Person’s jurisdiction of incorporation/formation/organization and the Secretary of State of each other jurisdiction in which such Person is qualified to do business as a foreign corporation/company/partnership, if any.
(i) A certificate in form and substance satisfactory to Lender from the Borrower and each Guarantor, dated the Closing Date and signed on behalf of such Person by an authorized member/manager/officer of such Person certifying as to (i) true copies of the organizational documents of such Person and any amendments thereto, (ii) the resolutions of the directors/managers and/or shareholders/members (as the case may be) of such Person authorizing the execution and delivery of this Agreement and the other Loan Documents to which it is a party and (iii) the names, true signatures and incumbency of the members/managers/officers of such Person authorized to execute and deliver the Loan Documents to which it is a party. The Lender may conclusively rely on such certification unless and until a later certificate revising the prior certificate has been furnished to the Lender.
(j) A certification regarding the beneficial ownership of the Borrower, as required by the Bank Secrecy Act (31 C.F.R. §1010.230 et. seq.), as amended from time to time, the regulations promulgated thereunder, and any successor statute, in form and substance satisfactory to the Lender.
(k) Evidence, in form and substance acceptable to the Lender, that the Borrower has a tangible balance sheet equity of at least twenty percent (20%) on the Closing Date.
(l) An opinion of counsel on behalf of the Borrower and the Guarantor, dated the Closing Date, in form and substance satisfactory to the Lender in absolute discretion.
(m) An opinion of special FAA counsel, including an International Registry Priority Search Certificate, each dated the Closing Date, in form and substance satisfactory to the Lender in absolute discretion.
(n) Listing of furniture, fixtures and equipment owned by the Borrower or a certification that the Borrower does not own any, satisfactory in form and content to the Lender, indicating that the estimated value of such furniture, fixtures and equipment.
(o) An inventory of all Warranties (including copies all documentation with respect thereto) relating to the Aircraft.
(p) The Borrower shall have executed and delivered all forms, documentation and information necessary for the establishment of the Cash Collateral Account at Lender, and shall have funded the Cash Collateral into the Cash Collateral Account (either prior to the Closing Date or contemporaneously therewith).
(q) Such other instruments, documents, certificates, assurances and opinions as may be set forth in the preliminary closing checklist delivered to the Borrower in connection with this Agreement or as the Lender shall reasonably require to evidence and secure the Loan, to comply with the provisions hereof and the requirements of regulatory authorities to which the Lender is subject, all of which, including those referred to above in this Section 4.01 shall be satisfactory in form, content and substance to the Lender.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Delivery Conditions (a) The Delivery Conditions are as follows:
(i) At Seller’s expense, Seller shall have secured all Governmental and grid operations approvals as are necessary for the safe and lawful operation and maintenance of the Project and to enable Seller to deliver Distribution Services at the Initial Contract Capacity to Buyer.
(ii) Seller shall have posted collateral as required by Section 10.4(a)(ii).
(iii) Seller shall have submitted for Buyer’s review a Project Safety Plan incorporating the elements described in Appendix XII, which must demonstrate Seller’s ability to comply with the Safety Requirements on the IDD and for the Delivery Term.
(iv) Seller shall have delivered to Buyer the Safety Attestation in accordance with Section 2(a) of Appendix XIV.
(v) As of the IDD, no Seller’s Event of Default shall have occurred and remain uncured.
(vi) At Seller’s expense, Seller or Contractor shall have constructed or caused to be constructed the Project as of the IDD and submitted the Certification for Commercial Operation in Appendix VII-A to enable (A) Seller to satisfy the obligations of the Seller herein and (B) the Project to deliver Distribution Services at the Contract Capacity to Buyer.
(vii) At Seller’s expense, Seller shall have installed any necessary metering to deliver the applicable Distribution Services in accordance with Section 4.1 and any applicable tariffs of the Utility Distribution Company.
(viii) Seller shall have met each Critical Milestone set forth in Appendix VI pursuant to Section 2.3.
Seller’s Conditions Notwithstanding any other provision of this Agreement, the obligation of Seller to consummate the Transactions shall be subject to and conditioned upon the following:
(i) Buyer’s representations and warranties being true and correct in all material respects as of the Closing and Buyer shall have delivered all documents required to be delivered by Buyer pursuant to Paragraph 5(b) below.
(ii) The satisfaction of the [REDACTED] Waiver Condition. In the event the [REDACTED] Waiver Condition is not satisfied at or prior to Closing, then Seller may elect to either (a) terminate this Agreement with respect to the Commerce Property (but not the other Properties), in which event the Purchase Price shall be reduced by the Allocated Purchase Price for the Commerce Property, neither party shall have any further liability or obligation under this Agreement with respect to the Commerce Property (except for the provisions of this Agreement which recite that they survive termination), and the Closing shall proceed with respect to all other Properties, or (b) elect to continue this Agreement in full force and effect with respect to the Commerce Property. If any condition to Seller’s obligation to proceed with the Closing hereunder has not been satisfied as of the Closing Date or other applicable date (other than the condition to Closing set forth in Paragraph 3(g)(ii) for which Seller’s rights for such failure of the condition to Closing are set forth therein), Seller shall have the right to (i) nevertheless proceed to Closing, notwithstanding the non-satisfaction of such condition, in which event Seller shall be conclusively deemed to have waived any such condition, or (ii) terminate this Agreement upon written notice to Buyer prior to Closing, in which case the provisions of Paragraph 3(f) shall apply.
