Contract Work Breakdown Structure Sample Clauses

Contract Work Breakdown Structure. 3.2.1.1 The contractor shall extend the government supplied Proposed Contract Work Breakdown Structure (attachment 4 to section J ) to the work package and planning package level. The contractor shall develop the CWBS to meet the of AMC-P 715-5 Cost/Schedule Control Systems Criteria Joint Implemention Guide. 3.2.1.2 The SCT shall use the CWBS for the contractual scheduling, budgeting, planning and accumulation of actual costs and measurement of accomplishment for reporting the status of costs and schedules to the government. 3.2.1.3 The CWBS Dictionary, which specifically delineates work to be accomplished, shall be maintained and updated by the contractor during the execution of the contract. The SCT shall identify to the Contracting Officer any additional work definition that is to be accomplished and may propose alternatives or improvements to the CWBS subject to written approval by the Contracting Officer. CDRL A002 Work Breakdown Structure
Sample 1
AutoNDA by SimpleDocs
Contract Work Breakdown Structure vC.5.3.4
Sample 1
Contract Work Breakdown Structure. The Contractor must develop and maintain the Contract Work Breakdown Structure (CWBS) and CWBS Dictionary using its format. The CWBS provides the basis for further extension by the Contractor to lower levels during the performance of the contract. The Contractor uses the CWBS as the primary framework for contract planning, budgeting, and reporting of the cost, schedule, and technical performance status to the Government. The Contractor, if necessary, updates the CWBS during the execution of the contract. Changes to the CWBS or associated definitions, at any reporting level, require approval of the Government.
Sample 1
Contract Work Breakdown Structure. The Contractor shall provide, as part of the Program Management Plan, a Contract Work Breakdown Structure (CWBS), without cost or price data, which systematically defines the total program in such a way that all elements have the proper relation to each other and that all elements are incorporated. The CWBS shall include all the deliverable (and non-deliverable but critical) end items called out in this Contract, including flight equipment (from unit level up), ground support/test equipment, facilities, services, manuals, reports, etc. It shall also include the major functional tasks that must be performed to conceive, design, fabricate, assemble, test and deliver the end items. Each CWBS element shall have a unique identification number which also reflects its logical relationship to other CWBS elements, and as such can be the basis for the production of specification and drawing “trees”. The reference numbers of deliverable data shall include references to the corresponding CWBS numbers.
Sample 1
Contract Work Breakdown Structure. The Contractor shall develop, deliver and update a Contract Work Breakdown Structure (CWBS) in accordance with Schedule 23 (Earned Value Management Templates) Annex B (DID-PC-002) that meets both the Authority reporting requirements
Sample 1
Contract Work Breakdown Structure. The contractor shall develop, provide, and maintain a contract Work Breakdown Structure (WBS) Dictionary, in accordance with DRD C-PC-04, Work Breakdown Structure (WBS) and Dictionary. The contract WBS shall serve as the framework for contract planning, budgeting, cost reporting, schedule resource loading, and schedule status reporting to the ISS Program. The WBS map shall show mapping of the contractor WBS to SSP 50659, ISS Program WBS, at the lowest level of the ISS Program WBS. Elements of work provided by subcontractors with a total value of $1M or more shall be identified in the contract WBS.
Sample 1

Related to Contract Work Breakdown Structure

  • Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.

  • Contract Work Contract work means capital project work within existing plant facilities, major maintenance and/or revamp work, plant modifications and/or shutdown work, minor maintenance and/or repair work, breakdown maintenance.

  • Contract Database Metadata Elements Title: Great Neck Union Free School District and Great Neck Paraprofessionals Association (2011) Employer Name: Great Neck Union Free School District Union: Great Neck Paraprofessionals Association Local: Effective Date: 07/01/2011 Expiration Date: 06/30/2015 PERB ID Number: 5132 Unit Size: Number of Pages: 28 For additional research information and assistance, please visit the Research page of the Catherwood website - xxxx://xxx.xxx.xxxxxxx.xxx/library/research/ For additional information on the ILR School - xxxx://xxx.xxx.xxxxxxx.xxx/ ARTICLE# TITLE PAGE# Preamble 2 Article 1 Association Rights 2 Article 2 Board-Administration-Association Relationship and Procedures 4 Article 3 Exchange of Proposals 6 Article 4 Professionals Duties and Responsibilities of Paraprofessionals 7 Article 5 Work Assignments 8 Article 6 Annual Appointment 10 Article 7 Selection and Promotion 10 Article 8 Evaluations and Standards 11 Article 9 Procedures for Termination of Employment 11 Article 10 Conferences 12 Article 11 Human Resource File 12 Article 12 Professional Growth 13 Article 13 Sick Leave 14 Article 14 Personal Leave 16 Article 15 Other Leaves 17 Article 16 Grievance Procedures 18 Article 17 Legal Assistance 19 Article 18 Conformity to Law 19 Article 19 Health Insurance 20 Article 20 Retirement Plan 20 Article 21 Salary Schedule 21 Article 22 Seniority Policy 23 Article 23 Compensation for Financial Loss 24 Article 24 Duration of Agreement 25 Appendix A Determination of Negotiating Unit 25 Appendix B Payroll Deduction Authorization 26 Appendix C Bus Aides 26 Appendix D Salary Schedules 27

  • Contract Changes Changes may not be made in the terms and conditions of this contract without the agreement and written permission of the Director of Residence Life or the Director’s designee.

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.

  • Contract Schedule The information set forth in the Contract Schedule is true and correct.

  • Technical Specifications The Technical Specifications furnished on the CD are intended to establish the standards for quality, performance and technical requirements for all labor, workmanship, material, methods and equipment necessary to complete the Work. When specifications and drawings are provided or referenced by the County, these are to be considered part of the Scope of Work, and to be specifically documented in the Detailed Scope of Work. For convenience, the County supplied specifications, if any, and the Technical Specifications furnished on the CD.

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.

  • General specifications For the purpose of this Regulation, the vehicle shall fulfil the following requirements:

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!