Contracting Overview Sample Clauses

Contracting Overview. Pursuant to AMS 0.0.0.0: Support Services Contracting, performance-based contracting techniques will be applied to contracts or task orders issued under this MOA to the maximum extent practicable. Requirements may be simple or complex. All contract work must be initiated by the end user (requiring/program office). The MOA holder may only pursue contract or task order opportunitities for work under its qualified FA(s). For other FAs, the MOA holder may wish to team with another MOA holder with a broader portfolio of FA(s). The Government reserves the right to request and audit cost build-up data for proposed labor rates.
Sample 1Sample 2Sample 3See All (11)
AutoNDA by SimpleDocs
Contracting Overview. Pursuant to AMS 3.8.2.4, performance-based contracting techniques will be applied to contracts or task orders issued under this MOA to the maximum extent practicable. Requirements may be simple or complex. All contract work must be initiated by the end user (requiring/program office). The MOA holder may only propose for work under its specific qualified FA(s). To participate in another area, it may wish to team with another MOA holder with a broader portfolio of FA(s). The MOA holder’s labor rates, by virtue of the competitive award process, will have already been determined to be fair and reasonable. However, the Contracting Officer reserves the right to request cost build-up data for proposed labor rates. The MOA holder’s cost build-up data is subject to audit by the Government.
Sample 1Sample 2Sample 3See All (4)

Related to Contracting Overview

  • Project Overview Project Title [Drafting note: ARENA to complete. Insert full long name in accordance with ARENA’s naming convention] i.e. [GMS Number] [Powerworks, voltage control on the Pacific Islands Study] [GMS Number] [study/ project/ fellowship/ scholarship/ R&D Project] Contract Number [Drafting note: ARENA to complete – to be obtained from ARENA’s GMS] Recipient [Drafting note: Recipient to insert full legal name and ABN] Guidelines and policies Advancing Renewables Program – Program Guidelines, 2020 (xxxxx://xxxxx.xxx.xx/xxxxxx/0000/00/XXXXX_XXX_Xxxxxxxxxx_XX_Xxxxxx_Xxxxx_XXXXX.xxx) ARENA Variation Policy (xxxxx://xxxxx.xxx.xx/xxxxxx/0000/00/xxxxx-xxxxxxx-xxxxxxxxx-xxxxxxxxx-xxxxxx.xxx) ARENA Report Writing Guidelines (xxxxx://xxxxx.xxx.xx/xxxxxx/0000/00/xxxxx-xxxxxx-xxxxxxx-xxxxxxxxxx.xxx)

  • Program Overview Microsoft extends to eligible partners the opportunity to participate in the Program referenced above subject to these Program Terms & Conditions (“Program Terms”). Each entity participating in the Program is hereinafter referred to as a “Participant.” Participation in the Program is voluntary. The Program is governed by the Program Terms, which incorporate by reference the Microsoft Partner Network Agreement (as in effect between Microsoft and Participant, the “MPN Agreement”). Capitalized terms used but not defined in these Program Terms have the meanings assigned to them in the MPN Agreement. These Program Terms are subject to local requirements and may vary by jurisdiction, and Participant retains sole discretion to set pricing for sales of applicable products.

  • HUB Subcontracting Plan The Owner has adopted Exhibit H, Policy on Utilization of Historically Underutilized Business ("Policy"), which is incorporated herein by reference. Contractor, as a provision of the Agreement must comply with the requirements of the Policy and adhere to the HUB Subcontracting Plan submitted with Contractor's Proposal and attached as Exhibit I. No changes to the HUB Subcontracting Plan can be made by the Contractor without the prior written approval of the Owner in accordance with the Policy.

  • Contracting Parties The Government customer (Licensee) is the “Ordering Activity”, “defined as an entity authorized to order under GSA contracts as set forth in GSA ORDER 4800.2G ADM, as may be revised from time to time. The Licensee cannot be an individual because any implication of individual licensing triggers the requirements for legal review by Federal Employee unions. Conversely, because of competition rules, the contractor must be defined as a single entity even if the contractor is part of a corporate group. The Government cannot contract with the group, or in the alternative with a set of contracting parties.

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Access Toll Connecting Trunk Group Architecture 9.2.1 If ECI chooses to subtend a Verizon access Tandem, ECI’s NPA/NXX must be assigned by ECI to subtend the same Verizon access Tandem that a Verizon NPA/NXX serving the same Rate Center Area subtends as identified in the LERG. 9.2.2 ECI shall establish Access Toll Connecting Trunks pursuant to applicable access Tariffs by which it will provide Switched Exchange Access Services to Interexchange Carriers to enable such Interexchange Carriers to originate and terminate traffic to and from ECI’s Customers. 9.2.3 The Access Toll Connecting Trunks shall be two-way trunks. Such trunks shall connect the End Office ECI utilizes to provide Telephone Exchange Service and Switched Exchange Access to its Customers in a given LATA to the access Tandem(s) Verizon utilizes to provide Exchange Access in such LATA. 9.2.4 Access Toll Connecting Trunks shall be used solely for the transmission and routing of Exchange Access to allow ECI’s Customers to connect to or be connected to the interexchange trunks of any Interexchange Carrier which is connected to a Verizon access Tandem.

  • Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.

  • Contracting In Further to Article 9.08(d)(i)(1) the parties agree that the Redeployment Committee will immediately undertake a review of any existing sub-contract work which would otherwise be bargaining unit work and which may be subject to expiry and open for renegotiation within six (6) months with a view to assessing the practicality and cost-effectiveness of having such work performed within the Hospital by members of the bargaining unit."

  • Contractor Licensing, etc. Notwithstanding Section 14.c, District may terminate this Contract immediately by written notice to Contractor upon denial, suspension, revocation, or non-renewal of any license, permit, or certificate that Contractor must hold to provide services under this Contract.

  • Contracting Information Requirements Contractor represents and warrants that it will comply with the requirements of Section 552.372(a) of the Texas Government Code. Except as provided by Section 552.374(c) of the Texas Government Code, the requirements of Subchapter J (Additional Provisions Related to Contracting Information), Chapter 552 of the Government Code, may apply to the Contract and the Contractor agrees that the Contract can be terminated if the Contractor knowingly or intentionally fails to comply with a requirement of that subchapter.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!