CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby.
13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition.
13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and
13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph
13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State.
13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal.
13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the
Location of Work The Executive shall be based in the United States in West Orange, New Jersey. However, the Executive agrees to undertake whatever domestic and worldwide travel is required by the Company. The Executive shall not be required or permitted to relocate without the mutual, written consent of the Executive and the Company.
Period of Work Work under this Agreement shall begin no sooner than the date on which this Agreement has been fully executed by the parties and approved by the Controller and the State Purchases Review Committee. Unless terminated earlier, this Agreement shall expire on the date set out on the first page of this Agreement, or at the completion and acceptance of all specified tasks, and delivery of all contracted products and services as defined in this Agreement, including performance of any warranty and/or maintenance agreements, whichever is the later date.
ARTICLE HOURS OF WORK The following provision designating regular hours on a daily tour and regular daily tours over the nursing schedule determined by the Hospital shall not be construed to be a guarantee of the hours of work to be performed on each tour or during each tour schedule. Subject to Article below:
Normal Hours of Work 10A.01 The normal work day is defined as the twenty-four (24) hour period beginning at 12:00 Midnight.
10A.02 The employer has the option of working either five (5) eight (8) hour days or four (4) ten
Standard of Work All work to be performed by or for Tenant pursuant hereto shall be performed diligently and in a first class, workmanlike manner, and in compliance with all applicable laws, ordinances, regulations and rules of any public authority having jurisdiction over the Premises and/or Tenant and Landlord’s insurance carriers. Landlord shall have the right, but not the obligation, to inspect periodically the work on the Premises, and Landlord may require changes in the method or quality of the work.
OF WORK The normal hours of work for an employee are not a guarantee of work per day or per week, or a guarantee of days of work per week. The normal hours of work shall be seven and one-half (7%) hours per day, and seventy-five (75) hours in any period. The normal daily tour shall consist of seven and one-half hours, exclusive of a one-half hour unpaid meal period. Employees shall be entitled to a fifteen (15) minute paid break during each half of the normal daily tour, at a time designated by the Employer. Employees required for reporting purposes shall remain at work for a period of up to fifteen (15) minutes which shall be unpaid. Should the reporting time extend beyond fifteen ( I 5) minutes however, the entire period shall be considered for the purposes of payment. Requests for change in posted work schedules must be submitted in writing and by the employee willing to exchange days off or shifts and are subject to the discretion of the Administrator or her designate. In any event, it is understood that such a change initiated by the employee and approved by the Employer shall not result in overtime compensation or payment or any other claims on the Employer by an employee under the terms of this t Where there is a change to Daylight Savings from Standard Time or vice-versa, an employee who is scheduled and works a full shift shall be paid for a seven and one-half (7.5) hour tour rather than the actual hours worked. The Employer will endeavour to accommodate requests by employees for specific days off and also requests for changes in posted time schedules once the schedule has been posted. Shift schedules shall be posted two (2) weeks in advance and shall cover a minimum of a four (4) week period. The following shall apply to full-time employees: During each pay period, two (2) consecutive days off will be scheduled. Schedules may provide for more than (5) consecutive days of work, but not more than seven (7) consecutive days of work without days off, as long as four (4) days off are scheduled in each fourteen (14) day period. Except as outlined below, meal time of one-half hour shall be scheduled away from the floor during the employee's shift whether day, evening or night. Where there is only one registered employee on duty, it is recognized that this is not possible. Should an employee be recalled to duty during meal time, additional time shall be provided later in the shift.
UNCOVERING OF WORK 13.1.1 If any portion of the Work should be covered contrary to the request of the Architect or to requirements specifically expressed in the Contract Documents, it must, if required in writing by the Architect, be uncovered for his or her observation and shall be replaced at the Contractor's expense.
13.1.2 If any other portion of the Work has been covered which the Architect has not specifically requested to observe prior to being covered, the Architect may request to see such Work and it shall be uncovered by the Contractor. If such Work is found in accordance with the Contract Documents, the cost of uncovering and replacement shall, by appropriate Change Order, be charged to the State. If such Work is found not to be in accordance with the Contract Documents, the Contractor shall pay such costs unless it is found that this condition was caused by the State or a separate contractor as provided in Article 6 of these General Conditions, in which event the State shall be responsible for the payment of such costs.
Payment Does Not Imply Acceptance of Work The granting of any payment by City, or the receipt thereof by Contractor, shall in no way lessen the liability of Contractor to replace unsatisfactory work, equipment, or materials, although the unsatisfactory character of such work, equipment or materials may not have been apparent or detected at the time such payment was made. Materials, equipment, components, or workmanship that do not conform to the requirements of this Agreement may be rejected by City and in such case must be replaced by Contractor without delay.
Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.
