Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
MFMP Transaction Fee Reports The Contractor shall submit complete monthly MFMP Transaction Fee Reports to the Department. Reports are due 15 calendar days after the end of each month. Information on how to submit MFMP Transaction Fee Reports online can be located at xxxxx://xxx.xxx.xxxxxxxxx.xxx/business_operations/state_ purchasing/myfloridamarketplace/mfmp_vendors/transaction_fee_and_reporting. Assistance with transaction fee reporting is also available by email at xxxxxxxxxxxxx@xxxxxxxxxxxxxxxxxxxx.xxx or telephone at 866-FLA-EPRO (866-352- 3776) from 8:00 a.m. to 6:00 p.m. Eastern Time.
Forecasting Requirements for Trunk Provisioning Within ninety (90) days of executing this Agreement, Reconex shall provide Verizon a two (2) year traffic forecast. This initial forecast will provide the amount of traffic to be delivered to and from Verizon over each of the Local Interconnection Trunk groups over the next eight (8) quarters. The forecast shall be updated and provided to Verizon on an as-needed basis but no less frequently than semiannually. All forecasts shall comply with the Verizon CLEC Interconnection Trunking Forecast Guide and shall include, at a minimum, Access Carrier Terminal Location (“ACTL”), traffic type (Local Traffic/Toll Traffic, Operator Services, 911, etc.), code (identifies trunk group), A location/Z location (CLLI codes for Reconex-IPs and Verizon-IPs), interface type (e.g., DS1), and trunks in service each year (cumulative).
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Related Provisions in Bidding Documents and Works Contracts 10. The Borrower shall ensure that all bidding documents and contracts for Works contain provisions that require contractors to:
END USER AGREEMENTS (“EUA H-GAC acknowledges that the END USER may choose to enter into an End User Agreement (“EUA) with the Contractor through this Agreement, and that the term of the EUA may exceed the term of the current H-GAC Agreement. H-GAC’s acknowledgement is not an endorsement or approval of the End User Agreement’s terms and conditions. Contractor agrees not to offer, agree to or accept from the END USER, any terms or conditions that conflict with those in Contractor’s Agreement with H-GAC. Contractor affirms that termination of its Agreement with H-GAC for any reason shall not result in the termination of any underlying EUA, which shall in each instance, continue pursuant to the EUA’s stated terms and duration. Pursuant to the terms of this Agreement, termination of this Agreement will disallow the Contractor from entering into any new EUA with END USERS. Applicable H-GAC order processing charges will be due and payable to H-GAC
Written Evaluation The Superintendent in consultation with the Board shall review and assess the Administrator’s performance on or before February 1 of each year. The Administrator shall be formally evaluated in writing annually by the Superintendent on or before February 1 of each year. The evaluation shall include a description of the Administrator’s duties and responsibilities and the standards to which the Administrator is to perform. It shall consider the Administrator’s specific duties, responsibilities, management and competence as an Administrator; specify the Administrator’s strengths and weaknesses with supporting reasons; align with research based standards established by the Illinois State Board of Education and use data and indicators on student growth as a significant factor in rating performance. The evaluation shall also consist of a review of the Administrator’s progress toward meeting established professional, student performance and academic goals set forth in Appendix A and a review of the Administrator’s leadership and management performance relative to his current assignment. The written evaluation shall be signed by both the Superintendent and the Administrator. The Administrator may respond to the evaluation in writing and such response shall be attached to and included in the Administrator’s personnel file.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
EDD Independent Contractor Reporting Requirements Effective January 1, 2001, the County of Orange is required to file in accordance with subdivision (a) of Section 6041A of the Internal Revenue Code for services received from a “service provider” to whom the County pays $600 or more or with whom the County enters into a contract for $600 or more within a single calendar year. The purpose of this reporting requirement is to increase child support collection by helping to locate parents who are delinquent in their child support obligations. The term “service provider” is defined in California Unemployment Insurance Code Section 1088.8, subparagraph B.2 as “an individual who is not an employee of the service recipient for California purposes and who received compensation or executes a contract for services performed for that service recipient within or without the state.” The term is further defined by the California Employment Development Department to refer specifically to independent Contractors. An independent Contractor is defined as “an individual who is not an employee of the ... government entity for California purposes and who receives compensation or executes a contract for services performed for that ... government entity either in or outside of California.” The reporting requirement does not apply to corporations, general partnerships, limited liability partnerships, and limited liability companies. Additional information on this reporting requirement can be found at the California Employment Development Department web site located at xxxx://xxx.xxx.xx.xxx/Employer_Services.htm
Flow Down Provisions Grantee must include any applicable provisions of the Contract in all subcontracts based on the scope and magnitude of work to be performed by such Subcontractor. Any necessary terms will be modified appropriately to preserve the State's rights under the Contract.
