Department’s Right to Suspend the TTMS Work Sample Clauses

Department’s Right to Suspend the TTMS Work. Contractor acknowledges and agrees that under the Comprehensive Agreement the Department has the right and authority, without liability to Concessionaire or Contractor, to suspend any affected portion of the TTMS Work by written order to Concessionaire to comply with any court order or judgment, to protect against a risk to the public health, safety or welfare (as more particularly set forth in the Comprehensive Agreement and Section 15.1.2.2 hereof), including to workers, other personnel or the general public from unsafe or dangerous conditions, or upon the occurrence of the events described in the Comprehensive Agreement. In accordance with the Comprehensive Agreement, the Department is to lift the suspension order promptly after it is permitted by the terms of the court order or judgment, after the dangerous or unsafe condition is rectified, or after Contractor (acting on behalf of Concessionaire) fully cures and corrects the applicable breach or failure to perform. Contractor may request Concessionaire to dispute the Department’s suspension order by written notice to Concessionaire, which notice will provide supporting information for Contractor’s position. Unless directed otherwise by Concessionaire after receipt of such notice, Contractor will carry out the TTMS Work required by the Department. If it is determined in accordance with the dispute resolution procedures in the Comprehensive Agreement that Contractor was in compliance with its obligations under this Agreement, then the suspension order and any additional TTMS Work required by the Department under the Comprehensive Agreement will be treated as a Department Change and Contractor shall be entitled to a corresponding Scope Change Order hereunder. The Parties acknowledge that the Department under Section 24.04(b) of the Comprehensive Agreement may require Concessionaire to suspend any TTMS Work or other activities related to the TTMS Project, which, in the sole discretion of the Department, presents a risk to the public health, safety or welfare, and to take such other actions as the Department may require to prevent such risk; provided, that if it is determined in accordance with the dispute resolution procedures in the Comprehensive Agreement that Contractor was in compliance with its obligations under this Agreement, then the suspension order will be treated as a Department Change and Contractor shall be entitled to a corresponding Scope Change Order hereunder. If the TTMS Work is so suspen...
Sample 1Sample 2
AutoNDA by SimpleDocs
Department’s Right to Suspend the TTMS Work. 15.1.2.1 Contractor acknowledges and agrees that under the Comprehensive Agreement the Department has the right and authority, without liability to Concessionaire or Contractor, to suspend any affected portion of the TTMS Work by written order to Concessionaire to comply with any court order or judgment, to protect against a risk to the public health, safety or welfare (as more particularly set forth in the Comprehensive Agreement and Section 15.1.2.2 hereof), including to workers, other personnel or the general public from unsafe or dangerous conditions, or upon the occurrence of the events described in the Comprehensive Agreement. In accordance with the Comprehensive Agreement, the Department is to lift the suspension order promptly after it is permitted by the terms of the court order or judgment, after the dangerous or unsafe condition is rectified, or after Contractor (acting on behalf of Concessionaire) fully cures and corrects the applicable breach or failure to perform. Contractor may request Concessionaire to dispute the Department’s suspension order by written notice to Concessionaire, which notice will provide supporting information for Contractor’s position. Unless directed otherwise by Concessionaire after receipt of such notice, Contractor will carry out the TTMS Work required by the Department. If it is determined in accordance with the dispute resolution procedures in the Comprehensive Agreement that Contractor was in compliance with its obligations under this Agreement, then the suspension order and any additional TTMS Work required by the Department under the Comprehensive Agreement will be treated as a Department Change and Contractor shall be entitled to a corresponding Scope Change Order hereunder.
Sample 1

Related to Department’s Right to Suspend the TTMS Work

  • STATE's Right to Suspend the Operations The STATE and/or the STATE's Authorized Representative has the authority to suspend portions or all of the operations due to causes including, but not limited to:

  • Owner’s Right to Suspend Work The Owner reserves the right, with or without the concurrence of the Design Professional, to suspend the Work at any time or from time to time at the Owner's sole discretion, upon giving Contractor five days advanced written notice thereof. If the Owner exercises this right and then resumes the Work covered hereby, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the suspension and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's suspension, to include compensation based upon the rate for Time Dependent Overhead Costs. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • City’s Right to Suspend for Convenience City may suspend all or any portion of Contractor’s performance under this Contract at its sole option and for its convenience for a reasonable period of time not to exceed six (6) months. City must first give ten (10) days’ written notice to Contractor of such suspension. City will pay to Contractor a sum equivalent to the reasonable value of the goods and/or services satisfactorily provided up to the date of suspension. City may rescind the suspension prior to or at six (6) months by providing Contractor with written notice of the rescission, at which time Contractor would be required to resume performance in compliance with the terms and provisions of this Contract. Contractor will be entitled to an extension of time to complete performance under the Contract equal to the length of the suspension unless otherwise agreed to in writing by the Parties.

  • OWNER’S RIGHT TO STOP THE WORK If the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as required by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner may issue a written order to the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity.

  • Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.

  • Right to suspend 2.1.1 Network Rail may serve a Suspension Notice where a Train Operator Event of Default has occurred and is continuing.

  • STATE'S RIGHT TO STOP THE WORK 3.3.1 If the Contractor fails to correct defective Work as required by Paragraph 13.2 or persistently fails to carry out the Work in accordance with the Contract Documents, the State, by a written order signed personally or by an agent specifically so empowered by the State in writing, may order the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of the State to the stop the Work shall not give rise to any duty on the part the State to exercise this right for the benefit of the Contractor or any other person or entity, except to the extent required by Subparagraph 6.1.3.

  • Right to Stop Work If Contractor fails to correct any defective Work or repeatedly fails to perform the Work in accordance with the Contract Documents, Owner shall have the right to order Contractor to stop performing the Work, or any portion thereof, until the cause for such order is eliminated.

  • Right to Refuse Unsafe Work Employees have the right to refuse to perform unsafe work pursuant to the Occupational Health and Safety Regulations of the Workers Compensation Act.

  • OWNER’S RIGHT TO CLEAN UP If a dispute arises among the Design-Builder, separate contractors and the Owner as to the responsibility under their respective contracts for maintaining the premises and surrounding area free from waste materials and rubbish, the Owner may clean up and will allocate the cost among those responsible.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!