Design-Build Firm Parties Sample Clauses

Design-Build Firm Parties. All Design-Build Firm Parties performing Services under this Agreement shall at all times be under Design-Build Firm s’ exclusive direction and control and Design-Build Firm shall be responsible for proper supervision and examination of the performance of the Services and Work by the Design-Build Firm Parties consistent with the requirements of this Agreement. Design-Build Firm Parties assigned to the Projects shall possess sufficient skills and professional expertise as required to satisfactorily meet all obligations and requirements of this Agreement. Owner retains the right to reject or require Design- Build Firm to remove any Design-Build Firm Parties who Owner determines in its sole judgment and discretion to fail to meet the standards for qualifications and performance established for performance of the Services hereunder. Owner hereby approves of the key positions listed on Design-Build Firm s’ Staffing Plan (Exhibit 5) as the key positions to be occupied by Design-Build Firm Parties, and Design- Build Firm s’ assignments to such positions as shown thereon. Owner reserves the right to participate in the interview process and review resumes of all other Design- Build Firm Parties who are being considered by Design-Build Firm for assignment to such key positions in the performance of Services hereunder. Design-Build Firm agrees that it will obtain the written consent of Owner and Program Manager prior to the assignment of any individual to such key positions for the performance of Services under this Agreement. Individuals of Design-Build Firm or Design-Build Firm Parties assigned to such key positions shall not, without Owner s’ prior written consent, be removed from their positions or reassigned except in the case of an employee s’ voluntary or involuntary termination of employment, or due to serious illness, death, or a bona fide family emergency. Upon Design-Build Firm becoming aware of an individual s’ imminent or actual vacancy from the Project for one of the foregoing reasons, Design-Build Firm shall notify Owner and Program Manager within three (3) Days of learning thereof.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Design-Build Firm Parties

  • Design-Builder The person or entity responsible for the proper completion of the activities described in the Contract Documents and who executes the Contract.

  • Project Representatives The Contractor designates the following individual as project representative for all matters concerning this Agreement: Xxxxx Xxxxxxx Financial Management Services Manager 0000 Xxxxx Xxxx Xx. Xxxxxxxx Xxxx, XX 00000 Phone: 000-000-0000 Email: xxxxxxxx@xxxxx.xxx The Authority designates the following individual as Contract Administrator/project representative to be the initial point of contact for all matters concerning this Agreement: Xxxx Xxxxxxxxxxxxx Authority Buyer 000 Xxxx Xxxxxxxx Xxxxxx Xxxxxxx, XX 00000 Email: XxxxxxxxxxxxxX0@xxxxxxxx.xxx The Contractor shall contact only the designated Contract Administrator with any Authority-related questions, work requests, etc., as described in this Agreement, as well as any Authority-related questions, work requests, etc., falling outside the scope of this Agreement. Except for changes to the performance schedule (not including the project’s completion date), the designated project representatives shall have no authority to make promises or binding obligations on behalf of the Authority, as such authority rests with the duly authorized persons executing this Agreement.

  • Design Development Phase Services 3.3.1 Based on the Owner’s approval of the Schematic Design Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Design Development Documents for the Owner’s approval. The Design Development Documents shall illustrate and describe the development of the approved Schematic Design Documents and shall consist of drawings and other documents including plans, sections, elevations, typical construction details, and diagrammatic layouts of building systems to fix and describe the size and character of the Project as to architectural, structural, mechanical and electrical systems, and other appropriate elements. The Design Development Documents shall also include outline specifications that identify major materials and systems and establish, in general, their quality levels.

  • Design Phase Services § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services.

  • Architect/Engineer (A/E) means a person registered as an architect pursuant to Tex. Occ. Code Xxx., Chapter 1051, as a landscape architect pursuant to Tex. Occ. Code Xxx., Chapter 1052, a person licensed as a professional engineer pursuant to Tex. Occ. Code Xxx., Chapter 1001 and/or a firm employed by Owner or a design-build contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • Project Representative City shall designate a Project Manager to represent City in coordinating this Project with Consulting Engineer/Architect, with authority to transmit instructions and define policies and decisions of City.

  • Building Commissioning Services The Owner may provide as a part of its testing services the Building Commissioning services involving the project’s HVAC and exhaust systems, temperature control systems, fire detection and alarm systems, emergency power and lighting system, fire suppression system, security locks and security locking control systems, food service equipment (if applicable), and laundry equipment (if applicable). In the event the Using Agency’s Program specifies additional commissioning services, the Owner shall procure such services as well. The Owner, through its Executive Administrator, may engage an independent Commissioning Authority. It is the intent of this Article that the Commissioning Authority enforce the requirements mentioned herein and certify that the systems and equipment listed all function properly prior to the initiation of each final inspection.

  • SCOPE OF ARCHITECT’S BASIC SERVICES 3.1 The Architect’s Basic Services consist of those described in this Article 3 and include usual and customary structural, mechanical, and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services.

  • Laboratory Services Covered Services include prescribed diagnostic clinical and anatomic pathological laboratory services and materials when authorized by a Member's PCP and HPN’s Managed Care Program.

  • Contractor Project Manager The Contractor Project Manager shall serve, from the Effective Date, as the Contractor project manager and primary Contractor representative under this Agreement. The Contractor Project Manager shall (i) have overall responsibility for managing and coordinating the performance of Contractor’s obligations under this Agreement, including the performance of all Subcontractors; and (ii) be authorized to act for and bind Contractor and Subcontractors in connection with all aspects of this Agreement. The Contractor Project Manager shall respond promptly and fully to all inquiries from the JBE Project Manager.

Time is Money Join Law Insider Premium to draft better contracts faster.