Notice of Delay 12.1. When anything delays or threatens to delay the timely performance of the Purchase Order, Supplier must immediately provide written notice to Buyer in writing of all relevant information, including but not limited to the reasons for the potential delay and Supplier’s short-term and long-term mitigation actions.
NOTICE OF DELAYS Except as otherwise provided under this Contract, when either party has knowledge that any actual or potential situation is delaying or threatens to delay the timely performance of this Contract, that party shall, within one (1) business day, give notice thereof, including all relevant information with respect thereto, to the other party.
Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.
Notice of Force Majeure If performance is delayed as a result of Force Majeure, the affected party shall provide prompt Notice to the other party and shall be excused from default or delay in performance while such circumstances prevail so long as such party continues to use commercially reasonable efforts to recommence performance as soon as possible.
STOP WORK NOTICE The City may issue an immediate Stop Work Notice in the event the Contractor is observed performing in a manner that is in violation of Federal, State, or local guidelines, or in a manner that is determined by the City to be unsafe to either life or property. Upon notification, the Contractor will cease all work until notified by the City that the violation or unsafe condition has been corrected. The Contractor shall be liable for all costs incurred by the City as a result of the issuance of such Stop Work Notice.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Notice of Developments Each Party will give prompt written notice to the other of any material adverse development causing a breach of any of its own representations and warranties in Section 3 and Section 4 above. No disclosure by any Party pursuant to this Section 5(f), however, shall be deemed to amend or supplement the Disclosure Schedule or to prevent or cure any misrepresentation, breach of warranty, or breach of covenant.
Providing Notice of Breaches 8.1 If Covered Entity determines that an impermissible acquisition, access, use or disclosure of PHI for which one of Business Associate’s employees or agents was responsible constitutes a Breach as defined in 45 CFR § 164.402, and if requested by Covered Entity, Business Associate shall provide notice to the individual(s) whose PHI has been the subject of the Breach. When requested to provide notice, Business Associate shall consult with Covered Entity about the timeliness, content and method of notice, and shall receive Covered Entity’s approval concerning these elements. The cost of notice and related remedies shall be borne by Business Associate.
8.2 If Covered Entity or Business Associate determines that an impermissible acquisition, access, use or disclosure of PHI by a Subcontractor of Business Associate constitutes a Breach as defined in 45 CFR § 164.402, and if requested by Covered Entity or Business Associate, Subcontractor shall provide notice to the individual(s) whose PHI has been the subject of the Breach. When Covered Entity requests that Business Associate or its Subcontractor provide notice, Business Associate shall either 1) consult with Covered Entity about the specifics of the notice as set forth in section 8.1, above, or 2) require, by contract, its Subcontractor to consult with Covered Entity about the specifics of the notice as set forth in section 8.1
8.3 The notice to affected individuals shall be provided as soon as reasonably possible and in no case later than 60 calendar days after Business Associate reported the Breach to Covered Entity.
8.4 The notice to affected individuals shall be written in plain language and shall include, to the extent possible, 1) a brief description of what happened, 2) a description of the types of Unsecured PHI that were involved in the Breach, 3) any steps individuals can take to protect themselves from potential harm resulting from the Breach, 4) a brief description of what the Business Associate is doing to investigate the Breach, to mitigate harm to individuals and to protect against further Breaches, and 5) contact procedures for individuals to ask questions or obtain additional information, as set forth in 45 CFR § 164.404(c).
8.5 Business Associate shall notify individuals of Breaches as specified in 45 CFR § 164.404(d) (methods of individual notice). In addition, when a Breach involves more than 500 residents of Vermont, Business Associate shall, if requested by Covered Entity, notify prominent media outlets serving Vermont, following the requirements set forth in 45 CFR § 164.406.
Notice of Force Majeure Event 14.2.1. As soon as practicable and in any case within 3 days of the date of occurrence of a Force Majeure Event or the date of knowledge thereof, the Party which is rendered wholly or partially unable to perform any of its obligations under this Agreement because of a Force Majeure Event (the “Affected Party”) shall notify the other party of the same, setting out, inter alia, the following in reasonable detail:
a) The nature and extent of the Force Majeure Event ;
b) The estimated period for which the Force Majeure Event is expected to last;
c) The nature of and the extent to which, performance of any of its obligations under this Agreement is affected by the Force Majeure Event;
d) The measures which the Affected Party has taken or proposes to take to alleviate/mitigate the impact of the Force Majeure Event and to resume performance of such of its obligations affected thereby; and
e) Any other relevant information concerning the Force Majeure Event, and /or the rights and obligations of the Parties under this Agreement.
CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.
