DISPUTES/CLAIMS. Public Contract Code § 9204. Claims between the District and the Contractor shall be resolved in accordance with the procedures established in Public Contract Code
DISPUTES/CLAIMS. Public Contract Code § 9204. Claims between the District and the Contractor shall be resolved in accordance with the procedures established in Public Contract Code § 9204.
(1) An extension of the Contract Time, including relief from damages or penalties assessed by the District for delay;
(2) Payment of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment that is not otherwise expressly provided for in the Contract Documents or to which the Contractor is not otherwise entitled; or
(3) Payment of an amount that is disputed by the District. Submission of Claim. A Claim arises upon the District’s rejection of a request by the Contractor for a Change Order. The Contractor shall submit the Claim by registered mail or certified mail with return receipt requested to the District’s Director of construction and Modernization, with a copy to the Project Manager/Construction Manager. The Contractor shall submit its Claim in writing, together with all Supporting Documentation no later than the earlier of either: (1) thirty
DISPUTES/CLAIMS. A. EXCLUSIVE REMEDY Any demand or assertion by CONSULTANT seeking any additional compensation and/or time extension, or other relief, for any reason whatsoever (hereafter collectively “Claim”), must be in strict compliance with the requirements of this Article. For purposes of this Article, any and all work relating to any such demand or assertion shall be referred to as “Disputed Work”, regardless of whether the basis of the demand or assertion arises from an interpretation of the Contract, an action or inaction of CONSULTANT or COUNTY, or any other event, issue, or circumstance. If the Disputed Work relates to any work performed by any subconsultants hired by CONSULTANT in compliance with the provisions of this Contract, any such Claims must also be processed by CONSULTANT in accordance with the provisions of this Article. The administration of a Claim as provided in this Article, including CONSULTANT’s performance of its duties and obligations specified in this Article is CONSULTANT’s sole and exclusive remedy for disputes of all types pertaining to the payment of money, extension of time, the adjustment or interpretation of the Contract, or other contractual or tort relief arising from this Contract. Compliance with the procedures described in this Article is a condition precedent to the right to file a Government Code Claim, commence litigation, or commence any other legal action. CONSULTANT waives the right to pursue or submit any Claims not processed in accordance with this Article.
DISPUTES/CLAIMS. All claims arising under or related to this Agreement shall be referred to the management of each party prior to recourse to any action at law or in equity. Management of each party shall mean an officer of a party occupying a position of vice president or higher. Any claim by Xxxxxx shall be made in writing and submitted to Buyer for a decision within thirty (30) days after the writing is delivered to Buyer. Seller must include the following in its statement of claim:
(i) A representation that supporting data are accurate and complete to the best of Seller’s knowledge and belief; and
(ii) A representation that the amount requested accurately reflects the adjustment for which Seller agrees Buyer is liable. Any claim presented by Xxxxxx must be signed by a senior official of Seller. Seller shall proceed diligently with the performance of work under this Agreement pending final resolution of any claim for relief, dispute between the parties or any action arising under this Agreement. Seller’s performance under this Agreement during the pendency of the dispute shall be in accordance with Xxxxx’s instructions. In the event the parties are unable to fully resolve the claim, then either party may pursue recourse in accordance with Article 23.
DISPUTES/CLAIMS. Any contractual claims shall be submitted in accordance with the Procedure for Resolution of Contractual Claims of the University included by reference here in.
DISPUTES/CLAIMS. 18.1. We are permitted, but not obliged, to monitor any content or information provided or uploaded, posted or disclosed via our site, but we are not responsible for monitoring any such content. You are responsible for reporting to us material on our site to which you object in accordance with the following procedures:
DISPUTES/CLAIMS. Any claims or disputes arising during the course of this Agreement that can not be resolved between the two parties shall be adjudicated or settled in accordance with the provisions of the Uniform Commercial Code as adopted by the U.N. Convention for the International Sale of Goods. Any disagreement or dispute, which may rise from interpretation, application, or execution of this Agreement, shall be settled by final & binding arbitration in accordance with the Arbitration Rules of the American Arbitration Association. Any arbitration shall be held in the State of New Jersey, U.S.A.
DISPUTES/CLAIMS. 16.1. The Customer agrees that should a dispute arise regarding Goods or Services provided, the dispute must be addressed with the Supplier within seven days of issuance of tax invoice for those services provided or goods supplied.
16.2. Failure to address any issues arising from delivery of goods with the Supplier within seven days of delivery forfeits any rights the Customer may have against the Supplier.
DISPUTES/CLAIMS. Any contractual claims shall be submitted in accordance with the Procedure for Resolution of Contractual Claims of the University of Virginia, included by reference herein.
DISPUTES/CLAIMS. Any contractual claims shall be submitted in accordance with the Procedure for Resolution of Contractual Claims of the University of Virginia, included by reference herein. In witness whereof the undersigned have executed this Contract on the dates set forth beside their respective signatures. by:_______________________________ (signature in ink) (date) Name: ____________________________ Title: _____________________________ ATTEST:__________________________ (signature) (date) University of Virginia by:________________________________ (date) ATTEST:___________________________ (signature) (date) Attachments: Service Order #1
