Force Majeure and Termination Sample Clauses

Force Majeure and Termination. Except with respect to the performance of a Carrier's payment obligations under this Agreement, neither Carrier shall be liable for delays or failure in its performance hereunder to the extent that such delay or failure of performance (a) is caused by any act of God, war, terrorism, natural disaster, strike, lockout, labor dispute, work stoppage, fire, serious accident, epidemic, quarantine restriction, act of government, or any other cause, whether similar or dissimilar, beyond the control of that Carrier, and (b) is not the result of that Carrier's lack of reasonable diligence (an "Excusable Delay"). In the event an Excusable Delay continues for sixty (60) days or longer, the non-delayed Carrier shall have the right, at its option, to terminate this Agreement by giving the delayed Carrier at least thirty (30) days prior written notice of such election to terminate.
AutoNDA by SimpleDocs
Force Majeure and Termination. If the performance of the Contractor and the obligations under this engagement are delayed, hindered or prevented by an event or events beyond reasonable control of the Contractor and for which reasonable precautions could not be implemented, the Contractor shall immediately notify NRI in writing, specifying the nature of the force majeure incident and the anticipated delay in carrying out the duties under this engagement.
Force Majeure and Termination. (A) If, at any time prior to 5:00 p.m. on the Sale Completion Date: (i) there shall develop, occur, exist or come into effect: (a) any change in, or any event or series of events resulting or likely to result in any change in Hong Kong, the PRC or the US national or international financial, currency, political, military, industrial, economic or market conditions (and for the purpose of construing the foregoing any normal market fluctuations shall not be construed as events or series of events affecting market conditions referred to above); or (b) any material and adverse change in the conditions of Hong Kong, the PRC, the US or international equity securities or other financial markets; or (c) the imposition of any moratorium, suspension or material restriction on trading in securities generally on the US stock exchanges due to exceptional financial circumstances or otherwise; or (d) any change or development occurs involving a prospective change in taxation or exchange control (or the implementation of any exchange control) in Hong Kong, Bermuda or the PRC or the US or elsewhere; which, in the opinion of the Purchaser makes it inadvisable or inexpedient to proceed with the Placing; or (ii) it comes to the notice of the Purchaser any matter or event rendering any of the Vendor’s representations and warranties in any material respect to be untrue, inaccurate or misleading or as having been breached (“Breached Warranty”) and if the Purchaser considers that the Breached Warranty to have a materially prejudicial effect on the Placing, then the Purchaser may give written notice to the Vendor to terminate this Agreement with immediate effect. (B) Upon the termination of this Agreement pursuant to the provisions of sub-clause (A) above, each of the Parties shall cease to have any rights or obligations under this Agreement, save in respect of the provisions of this Clause and Clauses, 8, 11 and 13, and any antecedent breaches of this Agreement or any rights or obligations which may have accrued under this Agreement prior to such termination.
Force Majeure and Termination. 12.1. In this terms and conditions, force majeure on the side of Prodim Int. BV refers to war, threat of war, natural disasters, an excessive temporary increase in demand, disturbances, transportation barriers, government regulations, weather conditions, failure in or a delayed delivery, or not fully delivered to Prodim Int. BV of goods or services ordered by third parties, strikes, company obstacles, punctuality actions, breakdown at Prodim Int. BV, the presence of EMC pollution on the supply network of the other party, nuclear reactions, molestations, as well as any circumstances beyond the control of Prodim Int. BV – irrespective of the fact whether this was foreseeable at the time of the conclusion of the agreement – that prevents the performance of the agreement temporarily or permanently or makes it considerably more difficult or more expensive. 12.2. If Prodim Int. BV is, as a result of force majeure, not able to meet its obligations, the company shall be entitled to postpone the supply of goods or the performance of operations, without being in default, until the force majeure situation has ended. 12.3. in the event of force majeure, Prodim Int. BV has the right to terminate the agreement, without being liable for damages resulting thereof. Prodim Int. BV, cannot be settled by deduction from and / or withholding from the invoiced amount, but should be demanded separately.
Force Majeure and Termination. 7.9.1 In the event the Project or mine site is destroyed by fire, the elements or any other cause whatsoever and the Project is not rebuilt, or in the event that in the sole discretion of DDMI it is no longer feasible to operate the Project and it permanently closes, DDMI shall be released from all covenants and obligations under the Agreement. 7.9.2 DDMI may curtail, suspend or interrupt Operations as it sees fit and during such period of curtailment, suspension or interruption DDMI shall be relieved of its obligations hereunder to the extent reasonable in the circumstances. 7.9.3 All of the time limits contained herein shall be extended in the event of any delay caused by an act of God, Her Majesty’s enemies, quarantine, riots, strikes, perils of navigation or extraordinary weather conditions or any other conditions beyond the reasonable control of the Parties, the extension being for the period of such delay.
Force Majeure and Termination xxx.xx. 02.-07..2016 Package -1 Highway Project
Force Majeure and Termination. Neither of the Parties shall be considered responsible in the event of a failure to perform or a delay in the performance of its contractual obligations in the event in which such non-performance or delay is attributable to causes of force majeure.
AutoNDA by SimpleDocs
Force Majeure and Termination. The performance of this Agreement by either party is subject to acts of God, war, terrorism, government regulation, disaster, fire, strikes, civil disorder, curtailment of transportation facilities preventing or unreasonably delaying at least 25% of attendees and guests from appearing at UTC’s conference, or other similar cause beyond the control of the parties making it impracticable, illegal, inadvisable or impossible to hold the conference or provide the facility. This Agreement may be terminated without penalty for any one or more of such reasons by written notice from one party to the other. In addition to the foregoing, should there be any acts of terrorism in North America within 30 days prior to the arrival of the first members of the group which affect transportation facilities and which prohibit 25% or more of UTC’s representatives from attending the Conference, this Contract may be terminated by written notice from one party to the other. In addition, this Agreement may be terminated upon the breach of any material term of this Agreement, provided written notice of such termination is given and another party has been given a reasonable opportunity, under the circumstances, to cure the default, if possible.
Force Majeure and Termination 

Related to Force Majeure and Termination

  • COMMENCEMENT AND TERMINATION 10.1 This Agreement shall be effective as of the date hereof and shall continue in force until terminated in accordance with the provisions herein. 10.2 This Agreement shall terminate without penalty: a. As to any Participating Fund, at the option of Insurance Company or the Participating Fund at any time from the date hereof upon 180 days' notice, unless a shorter time is agreed to by the respective Participating Fund and Insurance Company; b. As to any Participating Fund, at the option of Insurance Company, if shares of that Participating Fund are not reasonably available to meet the requirements of the Contracts as determined by Insurance Company. Prompt notice of election to terminate shall be furnished by Insurance Company, said termination to be effective ten days after receipt of notice unless the Participating Fund makes available a sufficient number of shares to meet the requirements of the Contracts within said ten-day period; c. As to a Participating Fund, at the option of Insurance Company, upon the institution of formal proceedings against that Participating Fund by the Commission, National Association of Securities Dealers or any other regulatory body, the expected or anticipated ruling, judgment or outcome of which would, in Insurance Company's reasonable judgment, materially impair that Participating Fund's ability to meet and perform the Participating Fund's obligations and duties hereunder. Prompt notice of election to terminate shall be furnished by Insurance Company with said termination to be effective upon receipt of notice; d. As to a Participating Fund, at the option of each Participating Fund, upon the institution of formal proceedings against Insurance Company by the Commission, National Association of Securities Dealers or any other regulatory body, the expected or anticipated ruling, judgment or outcome of which would, in the Participating Fund's reasonable judgment, materially impair Insurance Company's ability to meet and perform Insurance Company's obligations and duties hereunder. Prompt notice of election to terminate shall be furnished by such Participating Fund with said termination to be effective upon receipt of notice; e. As to a Participating Fund, at the option of that Participating Fund, if the Participating Fund shall determine, in its sole judgment reasonably exercised in good faith, that Insurance Company has suffered a material adverse change in its business or financial condition or is the subject of material adverse publicity and such material adverse change or material adverse publicity is likely to have a material adverse impact upon the business and operation of that Participating Fund or Dreyfus, such Participating Fund shall notify Insurance Company in writing of such determination and its intent to terminate this Agreement, and after considering the actions taken by Insurance Company and any other changes in circumstances since the giving of such notice, such determination of the Participating Fund shall continue to apply on the sixtieth (60th) day following the giving of such notice, which sixtieth day shall be the effective date of termination; f. As to a Participating Fund, upon termination of the Investment Advisory Agreement between that Participating Fund and Dreyfus or its successors unless Insurance Company specifically approves the selection of a new Participating Fund investment adviser. Such Participating Fund shall promptly furnish notice of such termination to Insurance Company; g. As to a Participating Fund, in the event that Participating Fund's shares are not registered, issued or sold in accordance with applicable federal law, or such law precludes the use of such shares as the underlying investment medium of Contracts issued or to be issued by Insurance Company. Termination shall be effective immediately as to that Participating Fund only upon such occurrence without notice; h. At the option of a Participating Fund upon a determination by its Board in good faith that it is no longer advisable and in the best interests of shareholders of that Participating Fund to continue to operate pursuant to this Agreement. Termination pursuant to this Subsection (h) shall be effective upon notice by such Participating Fund to Insurance Company of such termination; i. At the option of a Participating Fund if the Contracts cease to qualify as annuity contracts or life insurance policies, as applicable, under the Code, or if such Participating Fund reasonably believes that the Contracts may fail to so qualify; j. At the option of any party to this Agreement, upon another party's breach of any material provision of this Agreement; k. At the option of a Participating Fund, if the Contracts are not registered, issued or sold in accordance with applicable federal and/or state law; or l. Upon assignment of this Agreement, unless made with the written consent of every other non-assigning party. Any such termination pursuant to Section 10.2a, 10.2d, 10.2e, 10.2f or 10.2k herein shall not affect the operation of Article V of this Agreement. Any termination of this Agreement shall not affect the operation of Article IX of this Agreement. 10.3 Notwithstanding any termination of this Agreement pursuant to Section 10.2 hereof, each Participating Fund and Dreyfus may, at the option of the Participating Fund, continue to make available additional shares of that Participating Fund for as long as the Participating Fund desires pursuant to the terms and conditions of this Agreement as provided below, for all Contracts in effect on the effective date of termination of this Agreement (hereinafter referred to as "Existing Contracts"). Specifically, without limitation, if that Participating Fund and Dreyfus so elect to make additional Participating Fund shares available, the owners of the Existing Contracts or Insurance Company, whichever shall have legal authority to do so, shall be permitted to reallocate investments in that Participating Fund, redeem investments in that Participating Fund and/or invest in that Participating Fund upon the making of additional purchase payments under the Existing Contracts. In the event of a termination of this Agreement pursuant to Section 10.2 hereof, such Participating Fund and Dreyfus, as promptly as is practicable under the circumstances, shall notify Insurance Company whether Dreyfus and that Participating Fund will continue to make that Participating Fund's shares available after such termination. If such Participating Fund shares continue to be made available after such termination, the provisions of this Agreement shall remain in effect and thereafter either of that Participating Fund or Insurance Company may terminate the Agreement as to that Participating Fund, as so continued pursuant to this Section 10.3, upon prior written notice to the other party, such notice to be for a period that is reasonable under the circumstances but, if given by the Participating Fund, need not be for more than six months. 10.4 Termination of this Agreement as to any one Participating Fund shall not be deemed a termination as to any other Participating Fund unless Insurance Company or such other Participating Fund, as the case may be, terminates this Agreement as to such other Participating Fund in accordance with this Article X.

  • Renewal and Termination A. This Agreement shall become effective on the date written below and shall continue in effect for one (1) year thereafter, unless sooner terminated as hereinafter provided and shall continue in effect thereafter for periods not exceeding one (1) year so long as such continuation is approved at least annually (i) by a vote of a majority of the outstanding voting securities of the Fund or by a vote of the Board of Trustees of the Trust, and (ii) by a vote of a majority of the Trustees of the Trust who are not parties to the Agreement (other than as Trustees of the Trust) or “interested persons” of any such party, cast in person at a meeting called for the purpose of voting on the Agreement. B. This Agreement: (i) may at any time be terminated without the payment of any penalty either by vote of the Board of Trustees of the Trust or by vote of a majority of the outstanding voting securities of the Fund on sixty (60) days’ written notice to the Adviser; (ii) shall immediately terminate with respect to the Fund in the event of its assignment; and (iii) may be terminated by the Adviser on sixty (60) days’ written notice to the Fund. C. As used in this Paragraph the terms “assignment,” “interested person” and “vote of a majority of the outstanding voting securities” shall have the meanings set forth for such terms in the 1940 Act. D. Any notice under this Agreement shall be given in writing addressed and delivered, or mailed post-paid, to the other party at any office of such party.

  • Suspension of Work and Termination 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 60 consecutive days by written notice to Contractor and Engineer. Such notice will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be entitled to an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension.

  • Entry into force and termination This Agreement and its amendments shall enter into force 60 days after the date the Parties exchange written notifications certifying that they have completed their respective legal requirements for its entry into force or after such other period as the Parties may agree in written notification. Except as otherwise provided in this Agreement, it does not apply retroactively.

  • Expiration and Termination This Agreement is for one academic year (August 1, 2018 through July 31, 2019) and will automatically renew for the following academic year unless terminated as indicated below by either party. a. Any party may terminate this Agreement by written notice to the other at any time if that other party: (i.) commits a breach of this Agreement and, has not yet remedied the breach within 14 days of being notified of the facts and circumstances giving rise to the breach; or

  • Entry Into Force, Duration and Termination 1. The Contracting Parties shall notify each other when the constitutional requirements for entry into force of this Agreement have been fulfilled. The Agreement shall enter into force on the first day of the second month following the date of receipt of the last notification. 2. This Agreement shall remain in effect for a period of 20 years. Hereinafter, it shall remain in effect until the expiration of 12 months from the date on which any of the Contracting Parties gives written notice to the other Contracting Party of its decision to terminate this Agreement. 3. In respect of investments made prior to the date when the notice of termination of this Agreement becomes effective, the provisions of Articles 1 to 12 shall remain in force for the further period of twenty years from that date.

  • Duration and Termination This Agreement shall become effective with respect to each Fund as of the corresponding effective date indicated in Appendix A and, unless sooner terminated with respect to a Fund as provided herein, shall continue in effect for a period of two years as to such Fund. Thereafter, if not terminated, this Agreement shall continue in effect with respect to the Fund for successive periods of 12 months, provided such continuance is specifically approved at least annually by both (a) the vote of a majority of the Trust’s Board of Trustees or the vote of a majority of the outstanding voting securities of the Fund at the time outstanding and entitled to vote, and (b) the vote of a majority of the Trustees who are not parties to this Agreement or interested persons of any party to this Agreement, cast in person at a meeting called for the purpose of voting on such approval. Notwithstanding the foregoing, this Agreement may be terminated by the Trust at any time as to a Fund, without the payment of any penalty, upon giving the Advisor 60 days’ notice (which notice may be waived by the Advisor), provided that such termination by the Trust shall be directed or approved (x) by the vote of a majority of the Trustees of the Trust in office at the time or by the vote of the holders of a majority of the voting securities of the Fund at the time outstanding and entitled to vote, or (y) by the Advisor on 60 days’ written notice (which notice may be waived by the Trust). This Agreement will also immediately terminate in the event of its assignment. (As used in this Agreement, the terms “majority of the outstanding voting securities,” “interested person” and “assignment” shall have the same meanings of such terms in the 1940 Act.)

  • Suspension and Termination Schedule 6 shall have effect.

  • Release and Termination (a) Upon any sale, transfer or other disposition or removal from the Designated Pool of any Pool Aircraft (or Owner Subsidiary or Intermediate Lessee) or other item of Collateral in accordance with the terms of the Loan Documents, including the Pledged Equity Interest in each Owner Subsidiary or Intermediate Lessee that owns or leases such Pool Aircraft, or if applicable, Irish Subsidiary Holdco or CA Subsidiary Holdco (in each case, upon a removal of such Transaction Party in accordance with Sections 2.10 or 5.04 of the Credit Agreement), such Collateral will be deemed released from the Lien hereof (and related guarantees will be deemed released in accordance with Section 7.11 of the Credit Agreement), and the Collateral Agent will, at the relevant Grantor’s expense, execute and deliver to the Grantor of such item of Collateral such documents as such Grantor shall reasonably request and provide to the Collateral Agent to evidence the release of such item of Collateral from the assignment and security interest granted hereby and to evidence the release of any related guaranty, and to the extent that (A) the Collateral Agent’s consent is required for any deregistration of the interests in such released Collateral from the International Registry or any other registry or (B) the Collateral Agent is required to initiate any such deregistration, the Collateral Agent shall ensure that such consent or such initiation of such deregistration is effected. Any amounts released from the Collateral Account by the Collateral Agent in accordance with the terms of the Loan Documents shall be deemed released from the Lien hereof. (b) Upon the payment in full in cash of the Secured Obligations then outstanding, the pledge, assignment and security interest granted by Section 2.01 hereof shall terminate, the Collateral Agent shall cease to be a party to this agreement, and all provisions of this Agreement (except for this Section 8.06(b)) relating to the Secured Obligations, the Secured Parties or the Collateral Agent shall cease to be of any effect insofar as they relate to the Secured Obligations, the Secured Parties or the Collateral Agent. Upon any such termination, the Collateral Agent will, at the relevant Grantor’s expense, execute and deliver to each relevant Grantor such documents as such Grantor shall prepare and reasonably request to evidence such termination. (c) If, prior to the termination of this Agreement, the Collateral Agent ceases to be the Collateral Agent in accordance with the definition of “Collateral Agent” in Section 1.01, all certificates, instruments or other documents being held by the Collateral Agent at such time shall, within five (5) Business Days from the date on which it ceases to be the Collateral Agent, be delivered to the successor Collateral Agent.

  • Term Renewal and Termination 14.1. This Agreement shall, with respect to the Portfolio, become effective as of the date first above written and shall remain in force for two years thereafter, and for successive annual periods thereafter but only so long as each such continuance is specifically approved at least annually by (1) a majority of the Directors of the Company who are not parties to this Agreement or interested persons of any such parties (other than as Directors of the Company), by vote cast in person at a meeting called for the purpose of voting on such approval; or

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!