Non-Political Events. Any of the following events which prevent the Affected Party from performing any of its obligations for a continuous period of not less than 7 (seven) Days from the date of its occurrence, shall constitute a Non-Political Event:
(a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Project Site and by reasons not attributable to the Concessionaire or the Contractor or any of the employees or agents of the Concessionaire or the Contractor);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them), and not being an Other Event set forth in Article 14.4, labour disruptions or any other industrial disturbances not arising on account of the acts or omissions of the Concessionaire or the Contractor;
(c) any failure or delay of a Contractor caused by any of the Non-Political Events, for which no offsetting compensation is payable to the Concessionaire or on behalf of the Contractor;
(d) the discovery of geological conditions, toxic contamination or archeological remains on the Project Site that could not reasonably have been expected to be discovered through a site inspection; or
(e) any event or circumstance of a nature analogous to any of the foregoing.
Non-Political Events. A Non-Political Event shall mean one or more of the following acts or events:
a. act of God, epidemic, earthquake, flood, chemical or radioactive contamination or ionizing radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Project Facilities);
b. strikes or boycotts (other than those involving Operator, or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 7 (seven) days and an aggregate period exceeding 14 (fourteen) days in an Accounting Year, and not being a Political Event set forth in Clause 20.3;
c. any judgment or order, any court of competent jurisdiction or statutory authority made against the Operator in any proceedings for reasons other than (i) failure of the Operator to comply with any Applicable Law or Applicable Permit, or (ii) on account of breach of any Applicable Law or Applicable Permit or of any contract, or (iii) enforcement of this Contract, or (iv) exercise of any of its rights under this Contract by the Authority;
d. the discovery of geological conditions, toxic contamination or archaeological remains on the Project Facilities that could not reasonably have been expected to be discovered through a site inspection; or
e. any event or circumstances of a nature analogous to any of the foregoing Non-Political Events.
Non-Political Events. Any of the following events which prevent the Affected Party from performing any of its obligations for a continuous period of not less than 7 (seven) Days from the date of its occurrence, shall constitute a Non-Political Event:
a. Act of God, epidemic, earthquake, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Project Site and by reasons not attributable to the SPV or the Contractor or any of the employees or agents of the SPV or the Contractor);
b. Strikes or boycotts (other than those involving the SPV, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them), and not being an Other Event set forth in Article 14.4, labour disruptions or any other industrial disturbances not arising on account of the acts or omissions of the SPV or the Contractor;
c. Any failure or delay of a Contractor caused by any of the Non-Political Events, for which no offsetting compensation is payable to the SPV or on behalf of the Contractor;
d. The discovery of geological conditions, toxic contamination or archeological remains on the Project Site that could not reasonably have been expected to be discovered through a site inspection; or
e. Any event or circumstance of a nature analogous to any of the foregoing.
Non-Political Events. Any of the following events which prevent the Affected Party from performing any of its obligations for a continuous period of not less than 7 (seven) Days from the date of its occurrence, shall constitute a Non-Political Event:
a) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Project Site and by reasons not attributable to the Developer or the Contractor or any of the employees or agents of the Developer or the Contractor);
b) strikes or boycotts (other than those involving the Developer, Contractors or their respective employees/representatives, or attributable to any act or omission of any of them), and not being an Other Event set forth in Clause 18.1.3, labour disruptions or any other industrial disturbances not arising on account of the acts or omissions of the Developer or the Contractor;
c) any failure or delay of a Contractor caused by any of the Non-Political Events, for which no offsetting compensation is payable to the Developer or on behalf of the Contractor;
Non-Political Events. (i) Acts of God or natural disasters beyond the reasonable control of the Affected Party which could not reasonably have been expected to occur, including but not limited to storm, cyclone, typhoon, hurricane, flood, landslide, drought, lightning, earthquakes, volcanic eruption, fire or exceptionally adverse weather conditions affecting the implementation of the Project.
(ii) Radioactive contamination, ionizing radiation.
(iii) Epidemic, famine.
(iv) An act of war (whether declared or undeclared), invasion, armed conflict or act of foreign enemy, blockade, embargo, revolution, riot, insurrection, terrorist or military action, nuclear blast / explosion, sabotage or civil commotion.
(v) Industry wide or state wide or India wide strikes or industrial action or disturbances which has a Material Adverse Effect on the Project and which are not on account of acts of the Developer, its Subcontractors or persons claiming through or under it;
(vi) Any judgment or order of any court of competent jurisdiction or statutory authority in India made against the Developer in any proceedings (which are non collusive and duly prosecuted by the Developer) for reasons other than failure of the Developer or of any Person claiming through or under it to comply with any Applicable Law or terms of Clearances or on account of breach thereof, or of any contract, or enforcement of this Agreement or exercise of any of its rights under this Agreement by DMA;
(vii) any failure of another service provider to the extent caused by any of the Force Majeure Event mentioned above affecting the performance of the Agreement ; or
(viii) Any event or circumstances of a nature analogous to any of the foregoing.
Non-Political Events. Any of the following events which prevent the Affected Party from performing any of its obligations for a continuous period of not less than 7 (seven) Days from the date of its occurrence, shall constitute a Non-Political Event:
Non-Political Events act of God, including earthquake, flood, inundation, landslide, exceptionally adverse weather conditions, xxxxx, xxxxxxx, hurricane, cyclone, lightning, thunder, volcanic eruption, fire or other extreme atmospheric conditions;
Non-Political Events. A Non-Political Events shall mean one or more of the following acts or events:
(a) acts of God, epidemic or plague, extremely adverse weather conditions, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionising radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion originating from a source external to the Site);
(b) strikes or boycotts (other than those involving the Concessionaire, Contractors or their respective employees / representatives, or attributable to any act or omission of any of them) interrupting supplies and services to the Project for a continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being an Indirect Political Event set forth in Clause 28.3;
(c) any failure or delay of a Contractor but only to the extent caused by another Non- Political Event and which does not result in any offsetting compensation being payable to the Concessionaire by or on behalf of such Contractor;
(d) any judgment or order of any court of competent jurisdiction or statutory authority made against the Concessionaire in any proceedings for reasons other than (i) failure of the Concessionaire to comply with any Applicable Law or Applicable Permits or (ii) on account of breach of any Applicable Law or Applicable Permits or of any contract, or (iii) enforcement of this Agreement, or (iv) exercise of any of its rights under this Agreement by the Authority / SSNNL / FED; or
(e) the discovery of geological conditions (beyond 50 m depth), toxic contamination or archaeological remains on the Site that could not reasonably have been expected to be discovered through a Site inspection.
Non-Political Events. (I) act of God, epidemic, extremely adverse weather conditions, lightning, earthquake, landslide, cyclone, flood, volcanic eruption, chemical or radioactive contamination or ionizing radiation, fire or explosion (to the extent of contamination or radiation or fire or explosion not attributable to the Operator);
(II) strikes or boycotts (other than those involving the Operator, its sub-contractor, vendors or their respective employees/representatives, or attributable to any act or omission of any of them) interrupting for the continuous period of 24 (twenty four) hours and an aggregate period exceeding 7 (seven) days in an Accounting Year, and not being a Political Event set forth in this Agreement;
(III) any failure or delay of a Operator but only to the extent caused by another Non- Political Event and which does not result in any offsetting compensation being payable to the Operator;
(IV) any judgment or order of any court of competent jurisdiction or statutory authority made against the Operator in any proceedings for reasons other than ( i) failure of the Operator to comply with any applicable Law or applicable permits, or (ii) on account of breach of any applicable law or applicable permits or of any contract, or
Non-Political Events. (a) Act of God, including earthquake, flood, inundation, landslide, exceptionally adverse weather conditions, xxxxx, xxxxxxx, hurricane, cyclone, lightning, thunder, volcanic eruption, fire or other extreme atmospheric conditions;
(b) Radioactive contamination or ionizing radiation or biological contamination except as may be attributable to the use of radiation or radio-activity or biologically contaminating material;
(c) Strikes, lockouts, boycotts, as the case may be not arising on account of the acts or omissions of the TP and which affect the timely implementation and continued operation as mandated in this agreement; or
(d) Any Pandemic like COVID
