Guaranteed Maximum Price (GMP) Review and Approval Sample Clauses

Guaranteed Maximum Price (GMP) Review and Approval. A. The CM/GC will meet with the CITY and Project Designer to review any GMP Proposal(s) and review the written statement of its basis. In the event the CITY or Project Designer discovers inconsistencies or inaccuracies in the information presented, the CM/GC will make adjustments as necessary to the GMP Proposal, its basis, or both. B. Upon receipt of any GMP proposal from the CM/GC, the CITY may submit the same documents that were used by the CM/GC in developing its GMP to an independent third party or to the Project Designer for review and verification. The third party or Project Designer will develop an independent estimate of the Cost of the Work and review the Project Schedule for the associated scope of the GMP Proposals. If the CM/GC GMP Proposal is greater than that of the independent third party or Project Designer’s estimate, the CITY may require the CM/GC to reconfirm its GMP Proposal. The CM/GC will accept the independent third party’s or Project Designer’s estimate for the Cost of Work as part of its GMP Proposal or present a report identifying, explaining and substantiating the differences within seven days of the CITY’s request. C. If design changes are required during the review and negotiation of GMP Proposals, the CITY will authorize and cause the Project Designer to revise the Construction Documents to the extent necessary to reflect the agreed-upon assumptions and clarifications contained in the final approved GMP Proposal. Such revised Construction Documents will be furnished to the CM/GC. The CM/GC will promptly notify the Project Designer and CITY in writing if any such revised Construction Documents are inconsistent with the agreed-upon assumptions and clarifications. D. The CM/GC guarantees to complete the Project at a Cost that shall not exceed the final approved GMP Proposal amount, and the CM/GC assumes the responsibility for paying any difference between the actual Cost of the Work and that amount. E. The CM/GC may then be requested to, or at its own discretion, submit a revised GMP Proposal for consideration by the CITY. At that time the CITY may do one of the following: 1. Accept the CM/GC original or revised GMP Proposal, if within the CITY’s budget, without comment. 2. Accept the CM/GC original or revised GMP Proposal that exceeds the CITY’s budget, and indicate in writing to the CM/GC that the Project Budget has been increased to fund the differences. 3. Reject the CM/GC’s original or revised GMP Proposal in which event, t...
AutoNDA by SimpleDocs

Related to Guaranteed Maximum Price (GMP) Review and Approval

  • Guaranteed Maximum Price (GMP Construction Manager guarantees that it shall not exceed a Guaranteed Maximum Price (GMP) of One Million, Twenty-One Thousand, One Hundred Twenty- Four Dollars and Ninety-Seven Cents ($1,021,124.97) for the identified Sub-Project.

  • GUARANTEED MAXIMUM PRICE PROPOSAL 7.1 At the conclusion of the Design Development phase the Contractor shall prepare and submit a Guaranteed Maximum Price Proposal to Owner based on the Design Development phase documents and review comments. The GMP shall be delivered to the Owner within three (3) weeks of the Design Development review meeting or a date established by the Owner. The GMP Proposal must be prepared in accordance with the guidelines established by Owner and delivered in the format specified by Owner in Exhibit “E” attached to this Agreement. Owner, at its sole option and discretion, may specify different requirements for the GMP Proposal. Contractor shall not withdraw its Guaranteed Maximum Price Proposal for ninety (90) days following submission to Owner. 7.2 In developing the GMP Proposal, Contractor shall coordinate efforts with A/E to identify qualifications, clarifications, assumptions, exclusions, value engineering and any other factors relevant to establishment of a GMP. Contractor shall review development of the GMP Proposal with Owner on an ongoing basis to address clarifications of scope and pricing, distribution of contingencies, schedule, assumptions, exclusions, and other matters relevant to the establishment of a GMP. 7.3 The GMP Proposal must include a written description of how it was derived that specifically identifies the clarifications and assumptions made by Contractor in the GMP and the monetary amounts attributable to them. The GMP Proposal shall include, without limitation, a breakdown of Contractor’s estimated General Conditions Costs and estimated Cost of the Work organized by trade and Masterformat 2004; contingency amounts; the Construction Phase Fee; and the proposed Contract Time, including dates for Notice to Proceed, Substantial Completion and Final Completion. Notwithstanding the breakdown of Contractor’s estimated costs, there are no line item guaranteed maximum amounts except for general conditions. 7.4 The Guaranteed Maximum Price Proposal shall allow for reasonably expected changes and refinements in the Drawings and Specifications through completion of the Construction Documents, except for material changes in scope. 7.5 The GMP Proposal shall include a Contractor’s Contingency amount. 7.6 Included with its GMP Proposal, Contractor shall provide three complete, bound sets of the drawings, specifications, plans, sketches, instructions, requirements, materials, equipment specifications and other information or documents that fully describe the Project as developed at the time of the GMP Proposal and that are relevant to the establishment of the GMP. The bound supporting documents shall be referenced in and incorporated into the GMP Proposal. 7.7 The GMP Proposal and all supporting documents shall identify and describe all items, assumptions, costs, contingencies, schedules and other matters necessary and relevant for proper execution and completion of the Work and for establishment of the GMP. The GMP Proposal and the supporting documents are complementary and, in the event of an irreconcilable conflict between or among them, the interpretation that provides for the higher quality or quantity of material and/or workmanship shall prevail over all other interpretations. 7.8 In submitting the GMP Proposal, Contractor represents that it will provide every item, system or element of performance that is identified, shown or specified in the GMP Proposal or the supporting documents, along with those necessary or ancillary materials that are reasonably inferable and equipment for their complete operating installation, unless specifically accepted in writing by Owner. Upon Owner’s written acceptance of the GMP Proposal, Contractor shall not be entitled to any increase in the GMP due to the continued refinement of the Construction Documents or the absence or addition of any detail or specification that may be required in order to complete the construction of the Project as described in and reasonably inferable from the GMP Proposal or the supporting documents used to establish the GMP. 7.9 The GMP Proposal shall adopt and incorporate all of the terms and conditions of this Agreement and all attachments to this Agreement. Any proposed deviation from the terms and conditions of this Agreement must be clearly and conspicuously identified to Owner in writing and specifically accepted in writing by Owner. In the event of a conflict between any term of the GMP Proposal that was not clearly and conspicuously identified and approved by Owner and the terms of this Agreement and its attachments, the terms of the Agreement and its attachments shall control. 7.10 Owner may accept or reject the Guaranteed Maximum Price Proposal or attempt to negotiate its terms with Contractor. Upon acceptance by Owner of the GMP Proposal in writing, both parties shall execute the GMP Proposal which shall become part of this Agreement. If Owner rejects the GMP Proposal or the parties are unable or unwilling to agree on a GMP, Owner may terminate this Agreement. 7.11 Following Owner’s acceptance of the GMP Proposal, Contractor shall continue to monitor the development of the Construction Documents so that, when complete, the Construction Documents adequately incorporate and resolve all qualifications, assumptions, clarifications, exclusions and value engineering issues identified in the GMP Proposal. During the Construction Documents stage, Contractor and A/E shall jointly deliver a monthly written status report to Owner describing the progress on the incorporation of all qualifications, assumptions, clarifications, exclusions, value engineering issues and all other matters relevant to the establishment of the GMP into the Construction Documents. 7.12 Contractor shall be entitled to an equitable adjustment of the GMP if it is required to pay or bear the burden of any new federal, state, or local tax, or any rate increase of an existing tax, except taxes on income, adopted through statute, court decision, written ruling, or regulation taking effect after acceptance of the GMP Proposal. This equitable adjustment does not apply to tax increases borne solely by Subcontractors. 7.13 The parties may agree to convert the GMP to a lump sum contract amount at any time after Contractor has received bids or proposals from trade Contractors or Subcontractors for the performance of all major elements of the Project. In proposing a lump sum amount, Contractor shall consider the buyout savings, any unused contingency amounts and the trade package contracts that have not been finalized. In preparing a lump sum conversion proposal, Contractor must provide the following information: 7.13.1 The stage of completion of the Project; 7.13.2 The trade packages that have been completely bought out; 7.13.3 The trade packages remaining that have not been bought out; 7.13.4 A complete line item breakdown of the calculations used to establish a lump sum amount based on the GMP Schedule of Values; 7.13.5 An accounting of all savings amounts that are to be returned to Owner as part of the lump sum calculation; and 7.13.6 Any other Project information requested by Owner. 7.14 Contractor shall document the actual Cost of the Project at buyout as compared to the Guaranteed Maximum Price Proposal and shall report this information to Owner monthly and with Contractor’s recommendation for selection of a bid/proposal for each subcontracting package. 7.15 Notwithstanding anything to the contrary herein, Contractor shall have no liability for delay or liquidated damages if the parties are unable to reach an agreement on the GMP.

  • Guaranteed Maximum Price The total monies payable to Developer under the terms and conditions of the Contract Documents.

  • Review and Approval The Supplier confirms and agrees that it shall apply to receive ISR's written consent, wherever ISR's consent, explicitly or implied, is required according to this Agreement. This requirement and the provision of ISR consent, shall not derogate in any way from Supplier's responsibilities and liabilities under this Agreement, and ISR shall bear no responsibility or liability whatsoever in connection with the review (whether or not there are objections) and/or with any approval given to, or denied from, Supplier, with respect to any matter and/or document, including but without limitation, drawings, designs (at all phases), plans, tests or otherwise.

  • Milestone Schedule Please state the status and progress of each Milestone and identify any completed Milestone(s) for the previous calendar quarter.

  • C1 Contract Price In consideration of the Contractor’s performance of its obligations under the Contract, the Authority shall pay the Contract Price in accordance with clause C2 (Payment and VAT).

  • Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.

  • Project Review A. Programmatic Allowances 1. If FEMA determines that the entire scope of an Undertaking conforms to one or more allowances in Appendix B of this Agreement, with determinations for Tier II Allowances being made by SOI-qualified staff, FEMA shall complete the Section 106 review process by documenting this determination in the project file, without SHPO review or notification. 2. If the Undertaking involves a National Historic Landmark (NHL), FEMA shall notify the SHPO, participating Tribe(s), and the NPS NHL Program Manager of the NPS Midwest Regional Office that the Undertaking conforms to one or more allowances. FEMA shall provide information about the proposed scope of work for the Undertaking and the allowance(s) enabling FEMA’s determination. 3. If FEMA determines any portion of an Undertaking’s scope of work does not conform to one or more allowances listed in Appendix B, FEMA shall conduct expedited or standard Section 106 review, as appropriate, for the entire Undertaking in accordance with Stipulation II.B, Expedited Review for Emergency Undertakings, or Stipulation II.C, Standard Project Review. 4. Allowances may be revised and new allowances may be added to this Agreement in accordance with Stipulation IV.A.3, Amendments. B. Expedited Review for Emergency Undertakings

  • Contract Price 3.1 For full and complete performance, OWNER agrees to pay CONTRACTOR the sum of $15,165.00 payable in accordance with the terms hereof and to the satisfaction of the OWNER.

  • Agreement Review If, pursuant to section 25.10 (Review of Agreement) of the Bilateral Agreement, the Bilateral Agreement is reviewed after three or five years, or both, of the effective date of the Bilateral Agreement, and any changes to the Bilateral Agreement are required as a result, the Parties agree to amend the Agreement as necessary and in a manner that is consistent with such changes.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!