Service Delivery Grantee shall:
1. Adhere to the Priority Populations for Treatment Programs as stated in the SUD UM Guidelines.
2. Maintain Daily Capacity Management Report in CMBHS as required in the SUD UM Guidelines.
3. Maintain a Waiting List to track all eligible individuals who have been screened but cannot be admitted to SUD treatment immediately.
i. Grantee that has an individual identified as a federal and state priority population on the waiting list shall confirm this in the Daily Capacity Management Report.
ii. Grantee shall arrange for appropriate services in another treatment facility or provide access to interim services as indicated within 48 hours when efforts to refer to other appropriate services are exhausted.
iii. Grantee shall offer directly or through referral interim services to wait-listed individuals.
iv. Establish a wait list that includes priority populations and interim services while awaiting admission to treatment services.
v. Develop a mechanism to maintain contact with individuals awaiting admission.
4. If unable to provide admissions to individuals within Priority Populations for Treatment Programs according to SUD UM Guidelines:
i. Implement written procedures that address maintaining weekly contact with individuals waiting for admissions as well as what referrals are made when a client cannot be admitted for services immediately.
ii. When Grantee cannot admit a client, who is at risk for dangerous for withdrawal, Grantee shall ensure that an emergency medical care provider is notified.
iii. Coordinate with an alternate provider for immediate admission.
iv. Notify Substance Use Disorder (Xxxxxxxxx_Xxx_Xxxxxxxx@xxxx.xxxxx.xx.xx) so that assistance can be provided that ensures immediate admission to other appropriate services and proper coordination when appropriate.
v. Provide pre-admission service coordination to reduce barriers to treatment, enhance motivation, stabilize life situations, and facilitate engagement in treatment.
vi. Adhere to Informed Consent Document for Opioid Use Disorder applicable to the individual as stated in the SUD UM Guidelines.
vii. When an individual is placed on the Wait List, Grantee shall document interim services as referrals that provides applicable testing, counseling, and treatment for Human Immunodeficiency Virus (HIV), tuberculosis (TB) and sexually transmitted infections (STIs).
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract. Delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor, unless otherwise agreed to by the Authorized User and the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of a Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
SERVICE DELIVERABLES You will receive service on the Covered Product as described below: Carry-In: Unless otherwise provided in this Agreement, the Covered Product must be shipped or delivered and retrieved by You at Our authorized service center during normal business hours. In-Home/On-Site: Service will be performed in Your home or on-site as indicated on the Declarations Page of this Agreement, or on Your sales receipt or invoice provided You have fulfilled the following requirements: (1) provide Our authorized technician with accessibility to the Covered Product; (2) provide a non-threatening and safe environment for Our authorized technician; and (3) an adult over the age of 18 must be present for the period of time Our authorized technician is scheduled to provide service and while Our authorized technician is on Your property servicing the Covered Product. In-Home Service will be provided by Our authorized service provider during regular business hours, local time, Monday through Friday, except holidays. Our authorized service center may opt to remove the Covered Product to perform service in-shop. The Covered Product will be returned upon completion. Additional time and mileage charges for in-home repairs outside of twenty-five (25) contiguous land miles or the normal service radius of Our authorized service center are not covered by this Agreement, and are Your responsibility.
PRICE/DELIVERY Price(s) bid must be the price(s) for new goods, unless otherwise specified. Any bids containing modifying or “escalator” clauses will not be considered unless specifically requested in the bid specifications.
Project Delivery Contractor shall construct the Project in accordance with the Contract Documents, and Contractor shall deliver the Project completed in accordance with the Contract Documents, substantially free from defects, and within the Contract Time.
Share Delivery Delivery of any shares in connection with settlement of the Award will be by book-entry credit to an account in the Grantee’s name established by the Company with the Company’s transfer agent, or upon written request from the Grantee (or his personal representative, beneficiary or estate, as the case may be), in certificates in the name of the Grantee (or his personal representative, beneficiary or estate).
Late Delivery Supplier shall give DXC prompt notice of any prospective failure to ship Products or provide Services on the delivery date specified by DXC (the “Delivery Date”).
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining, and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000- 000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent National Wood Flooring Association inspector (“NWFA Inspector”) to verify the Warranty Holder’s warranty claims. The determination of the NWFA Inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s Odyssey Engineered flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and
Non Delivery C15.1 Where the Goods, having been placed in transit, fail to be delivered to the Authority on the due date for delivery, the Authority shall, (provided that the Authority has been advised in writing of the dispatch of the Goods), within ten (10) Working Days of the notified date of delivery, give notice to the Contractor that the Goods have not been delivered and may request the Contractor free of charge to deliver substitute Goods within the timescales specified by the Authority or terminate the Contract in accordance with clause C13.4 (Delivery).
