DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion.
b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination.
c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease.
d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
Restoration of Premises Lessee shall conduct all operations on the Leased Premises in such a manner as not to unreasonably damage the portion of the Leased Premises where there will be no mining operations. Lessee shall conduct all operations in such a manner as to observe and comply with all Laws applicable to the Leased Premises and all Laws applicable to the conduct of Lessee’s operations. Lessee expressly agrees to dispose of all tailings and other mining wastes in accordance with all applicable Laws and shall reclaim all of disturbed perimeter portions of any lakes created by mining such that those perimeter portions shall be left at a slope no steeper than four feet horizontal to one foot vertical within three (3) months of termination of the Lease Agreement. By the expiration or earlier termination of the term of this Lease Agreement, Lessee shall grade that portion of the Leased Premises which has been excavated by Lessee or on which Lessee has conducted operations so as to eliminate all unreasonable irregularities therein and so that such portion of the Leased Premises which has been excavated by Lessee conforms to the drawing set forth on Exhibit C attached hereto. Upon completion of the required grading, Lessee shall cover such area with sand, clay, or topsoil, or a mixture of any of the foregoing, from the resources then existing on the Leased Premises, and shall thereafter reseed the surface with a seed mixture approved by Lessor. Notwithstanding the foregoing, in no event shall Lessee be required to import any Materials, including but not limited to, sand, clay, or topsoil from off-site for purposes of complying with its restoration obligations in this Section 15. Should this obligation not be met by the end of the term of this Lease Agreement, it shall nevertheless survive and continue beyond the term of this Lease Agreement and shall be an obligation owed by Lessee to Lessor. This obligation is owed by Lessee in addition to any other obligation imposed upon Lessee by this Lease Agreement.
DESTRUCTION OF PREMISES (A) If, during the term of this Lease, the Leased Premises are totally or partially destroyed by fire or the elements, so as to render the premises wholly unfit for occupancy, or make it impossible in the opinion of a licensed third party arbitrator knowledgeable in the child care business reasonably acceptable to Lessee and Lessor, for Lessee to conduct its business therein, then either Lessor or Lessee shall have the right to terminate this Lease from the date of such damage or destruction by giving written notice. The parties agree to use reasonable promptness to obtain the opinion of such licensed third party arbitrator. Upon the giving of such notice, Lessee shall immediately surrender the Leased Premises and all interest therein to Lessor, and in case of any such termination, Lessor may re-enter and repossess the Leased Premises and may dispossess all parties then in possession thereof. If not otherwise terminated, in the event the Leased Premises shall be repaired, restored, and rebuilt by Lessee with the use of insurance proceeds (which Lessor shall cooperate to make available), but otherwise at its own sole cost and expense, within one hundred eighty (180) days from the date of destruction (subject to force majuere as set forth in paragraph C hereof, then all rents payable by Lessee shall be abated during the period of repair and restoration to the extent Lessor shall be compensated by the proceeds of rents loss insurance. In no event shall Lessor be required to provide its own money for the repair or restoration of the Leased Premises other than the net proceeds of moneys received by it from any insurance policy or policies covering such loss or damages. Lessee shall be liable for repair of the Leased Premises with all reasonable speed, and the rents shall recommence on the date that the repairs are completed. Lessee shall be under no obligation to so repair during the last five (5) years of the term of the Lease, or as extended, but if Lessee shall desire to rebuild during the last 12 months of the Lease term, Lessor will make insurance proceeds available to rebuild the Leased Premises conditioned upon Lessee then exercising its next renewal option under the Lease. Lessor will make insurance proceeds available to rebuild the Leased Premises in the event Lessee rebuilds, except as stated above.
(B) If the damage does not, in the opinion of a licensed third party arbitrator reasonably acceptable to Lessee and Lessor, render the Leased Premises unfit for occupancy, then Lessor agrees that the damage shall be repaired as soon as practicable and in that case, Lessee shall pay full rent during the repair period. All repairs shall be paid for by Lessee out of any insurance proceeds received (which Lessor shall cooperate to make available), but if the insurance proceeds are insufficient to rebuild or repair the Leased Premises according to the original plans and specifications, whether repair or restoration is commenced pursuant to paragraph A or B hereof, then Lessee agrees to pay all additional amounts that are required to rebuild the building in accordance with the original plans and specifications. All improvements or betterments placed by Lessee on the demised premises shall, however, in any event, be repaired and replaced by Lessee at its own expense and not at the expense of Lessor. The purpose of this Article is to require Lessee to carry insurance coverage on the Leased Premises sufficient to rebuild the improvements in the event of damage or destruction. Lessee shall be under no obligation to so rebuild during the last five (5) years of the term, as extended, as the case may be, but if Lessee shall desire to rebuild during the last 12 months of the Lease term, Lessor will make insurance proceeds available to rebuild the Leased Premises conditioned upon Lessee then exercising its next renewal option under the Lease. Lessor will make insurance proceeds available to rebuild the Leased Premises in the event Lessee rebuilds, except as stated above. Risk that the insurance company shall be insolvent or shall refuse to make insurance proceeds available shall be with Lessee. The Leased Premises shall be so restored or rebuilt so as to be of at least equal value and substantially the same character as prior to such damage or destruction. If the insurance proceeds are less than $100,000 they shall be paid to Lessee for such repair and restoration. If the insurance proceeds are greater than or equal to $100,000 they shall be deposited by Lessee and Lessor into a customary construction escrow at a nationally recognized title insurance company, or at Lessee's option, with Lessor ("Escrowee") and shall be made available from time to time to Lessee for such repair and restoration. Such proceeds shall be disbursed in conformity with the terms and conditions of a commercially reasonable construction loan agreement. Lessee shall, in either instance, deliver to Lessor or Escrowee (as the case may be) satisfactory evidence of the estimated cost of completion together with such architect's certificates, waivers of lien, contractor's sworn statements and other evidence of cost and of payments as the Lessor or Escrowee may reasonably require and approve. If the estimated cost of the work exceeds One Hundred Thousand Dollars ($100,000), all plans and specifications for such rebuilding or restoration shall be subject to the reasonable approval of Lessor.
(C) Lessee shall comply with the time period stated above for restoration of the Leased Premises as set forth in this Article; provided, however, that said period of time shall be extended for a period or periods of time equal to any period or periods of delay caused by strikes, lockouts, fire, or other casualty, the elements, acts of God, delay by or refusal or failure of governmental authorities to grant necessary permits and approvals for the reconstruction of the Leased Premises (Lessee agreeing to use reasonable diligence to procure the same), or other causes other than financial, beyond Lessee's reasonable control or the reasonable control of Lessee's contractor.
DAMAGE TO LEASED PREMISES In the event the building housing the Premises shall be destroyed or damaged as a result of any fire or other casualty which is not the result of the intentional acts or neglect of Lessee and which precludes or adversely affects the Lessee’s occupancy of the Premises, then in every such cause, the rent herein set forth shall be abated or adjusted according to the extent to which the leased Premises have been rendered unfit for use and occupation by the Lessee and until the demised Premises have been put in a condition at the expense of the Lessor, at least to the extent of the value and as nearly as possible to the condition of the Premises existing immediately prior to such damage. It is understood, however, in the event of total or substantial destruction to the Premises that in no event shall the Lessor's obligation to restore, replace or rebuild exceed an amount equal to the sum of the insurance proceeds available for reconstruction with respect to said damage.
Lease of Premises Landlord hereby demises and leases to Tenant for the Term of this Lease and upon the terms and conditions hereinafter set forth, and Tenant hereby accepts from Landlord, the Premises.
RELOCATION OF PREMISES Landlord shall have the right to relocate the Premises to another part of the Building in accordance with the following:
(a) The new premises shall be substantially the same in size, dimensions, configuration, decor and nature as the Premises described in this Lease, and if the relocation occurs after the Commencement Date, shall be placed in that condition by Landlord at its cost.
(b) Landlord shall give Tenant at least thirty (30) days written notice of Landlord’s intention to relocate the Premises.
(c) As nearly as practicable, the physical relocation of the Premises shall take place on a weekend and shall be completed before the following Monday. If the physical relocation has not been completed in that time, Base Rent shall axxxx in full from the time the physical relocation commences to the time it is completed. Upon completion of such relocation, the new premises shall become the “Premises” under this Lease.
(d) All reasonable costs incurred by Tenant as a result of the relocation shall be paid by Landlord.
(e) If the new premises are smaller than the Premises as it existed before the relocation, Base Rent shall be reduced proportionately or Tenant has the option to terminate the Lease Agreement.
(f) The parties hereto shall immediately execute an amendment to this Lease setting forth the relocation of the Premises and the reduction of Base Rent, if any.
Abandonment of Premises If the property becomes vacant during the term of this lease, and if at the time of the vacancy Tenant are in default in the payment of any installment of rent, then the rent for the entire term shall become at once due and payable and Landlord may proceed to collect rent for said entire premises, with or without process of law, to take possession thereof, to remove any and all property there from and store as required by law, to lease the premises as agent of Tenant, and to apply the proceeds received from such letting toward the payment of Tenant' rent under this lease; such re-entry and re-letting shall not discharge Tenant from liability for rent, nor from any other obligation under the terms of this lease.
Use of Premises Tenant shall not use the premises or any part thereof, or permit the premises or any part thereof to be used, for any purpose other than the use hereinabove specifically mentioned, subject, however, to all the covenants, agreements, terms, provisions and conditions of this Lease. Those portions, if any, of the premises which on the plan(s) attached hereto are shown as toilets and utility areas shall be used by Tenant only for the purposes for which they are designed. Tenant will not at any time use or occupy the premises or any part thereof, or permit the premises or any part thereof to be used or occupied, in violation of the certificate of occupancy (temporary or final) issued for the Building and/or the premises. Tenant shall not xxx or permit the use of the premises or any part thereof in any way which would violate any of the covenants, agreements, terms, provisions and conditions of this Lease or for any unlawful purposes or in any unlawful manner and Tenant shall not suffer or permit the premises or any part thereof to be used in any manner or anything to be done therein or suffer or permit anything to be brought into or kept in the premises which, in the judgment of Landlord, shall in any way impair or tend to impair the character, reputation or appearance of the Building as a first-class office building, impair or interfere with or tend to impair or interfere with any of the Building services or the proper and economic heating, cleaning, air conditioning or other servicing of the Building or the premises, or impair or interfere with or tend to impair or interfere with the use of any of the other areas of the Building by, or occasion discomfort, inconvenience or annoyance to, any of the other tenants or occupants of the Building. Tenant shall not install any electrical or other equipment of any kind which, in the judgment of Landlord, might cause any such impairment, interference, discomfort, inconvenience or annoyance. Except as set forth in Article 1 hereof, Tenant will not, and will not permit anyone to, sell or traffic in any spirituous liquors, wine, ale or beer in or from the premises or carry on any manufacturing in the premises. If any governmental license or permit shall be required for the proper and lawful conduct of Tenant's business or other activity carried on it the premises, Tenant, at Tenant's expense, shall duly procure and thereafter maintain such license or permit and submit the same to inspection by Landlord. Tenant, at Tenant's expense, shall, at all times, comply with the terms and conditions of each license or permit.
CONSTRUCTION OF PREMISES A. Lessor agrees that it will supply, at its own expense, its standard office space, as more particularly described and set forth on Exhibit “B” annexed hereto and made a part hereof (“Lessor’s Work”). /s/ Lessor /s/ Lessee
B. Lessee agrees to perform, at its own cost and expense, all work other than Lessor’s Work, including without limitation that work, as particularly described in Exhibit “E” annexed hereto (“Lessee’s Work”), which is necessary to make the Premises conform with Lessee’s plans as approved by Lessor. Within thirty (30) days after the execution of this Lease, Lessee shall furnish to Lessor, for Lessor’s written approval, plans and specifications for the Lessee’s Work, showing a layout, lighting plan, fixturing plan, interior finish and material samples, and any work or equipment to be done or installed by Lessee affecting any structural, mechanical or electrical part of the Premises or the Building. Failure to provide same within said thirty (30) day period shall constitute a default by Lessee under this Lease. Lessor’s failure to disapprove of Lessee’s plans within fifteen (15) days of receipt shall constitute acceptance by Lessor of such plans. Design elements as aforesaid will be displayed in color renderings in such detail as may be sufficient for Lessor’s needs. It is the purpose of this requirement that Lessee’s Premises be fixtured, designed and laid out so as not to be a detriment to the other tenants in the Building and that Lessee’s Work shall not be detrimental to the Building or other tenants therein, and Lessor’s approval of the plans and specifications as aforesaid for Lessee’s Work shall be at the Lessor’s sole discretion. Lessee agrees and acknowledges that all Lessee’s Work, improvements, alterations or additions performed by Lessee (hereinafter collectively “Alterations”) whether pursuant to this Section or otherwise, shall be carried out in compliance with all Requirements and is performed and accomplished solely for the benefit and convenience of Lessee, and not for the benefit of Lessor, such Alterations being nevertheless subject to each and every of the provisions of this Lease,.
Expansion of Premises (a) Effective as of the Expansion Date the Premises (and the definition of the “Premises”) shall be modified to mean and include both the Initial Premises and the Expansion Premises. As a result of such expansion, effective upon the Expansion Date, the deemed square footage of the Premises shall be and become 31,684 square feet and Tenant’s Prorata Share and Tenant’s Share of Expenses and Real Estate Taxes shall be one hundred percent (100.00%).
(b) If Landlord, for any reason whatsoever, cannot deliver possession of the Expansion Premises to Tenant on before August 1, 2012 for the purpose specified in Section 3(c), this Amendment shall not be void or voidable, Landlord shall not be liable to Tenant for any loss or damage resulting therefrom, and Tenant shall have no obligation to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises until the day following the date on which possession of the Expansion Premises is delivered to Tenant (such date thereupon becoming the “Expansion Date” for purposes of this Amendment). Notwithstanding the foregoing, if Landlord is unable to deliver the Expansion Premises by August 1, 2012 (as extended day-for-day for each day of Force Majeure Delay) (the “Expansion Premises Outside Delivery Date”), then Tenant shall have the right, as its sole remedy, to terminate this Amendment to Lease by providing written notice to Landlord within fifteen (15) business days following the Expansion Premises Outside Delivery Date, in which event the Lease shall continue in full force and effect as if the parties had not entered into this Amendment and Landlord shall promptly return to Tenant the August, 2012 Base Rent for the Expansion Premises paid by Tenant pursuant to the provisions of Section 6(d). For purposes hereof, the failure of the existing tenant of the Expansion Premises to vacate the Expansion Premises shall not be an event of Force Majeure Delay.
(c) Notwithstanding the above, Tenant shall be entitled to early occupancy of the Expansion Premises at any time after the Expansion Premises Delivery Date for the sole purposes of (1) installing Tenant’s furniture and telephone and other communications cabling and (2) performing Tenant’s Expansion Work (defined below), provided that (i) Tenant covenants and agrees that Tenant and Tenant’s employees, agents or contractors will cooperate with Landlord to coordinate the performance and completion of the Landlord’s Expansion Work concurrently with Tenant’s Expansion Work, (ii) Landlord shall have no liability to Tenant for delays in completing the Landlord’s Expansion Work which result from, are caused by or arise out of the interference by Tenant or Tenant’s employees, agents or contractors in the performance of the Landlord’s Expansion Work, (iii) Tenant and Tenant’s employees, agents and contractors shall promptly comply with any and all requests made by Landlord or Landlord’s contractor(s) that Tenant remove its property from those areas in or around which Landlord is performing the Landlord’s Expansion Work, and (iv) Landlord shall not be liable for, Tenant hereby waives all claims which Tenant may have against the Landlord Parties, and Tenant shall indemnify and hold harmless Landlord from and defend Landlord against any and all claims or liability for any injury or damage to any person or property in or about the Expansion Premises resulting from or arising out of or in connection with the performance of Tenant’s Expansion Work (except to the extent arising from the negligence or willful misconduct of Landlord). Tenant’s early occupancy of the Expansion Premises for the sole purpose provided in this Section shall be subject to all of the terms and conditions of the Lease, provided that (x) the Premises shall not include the Expansion Premises until the Expansion Date, and (y) Tenant shall not be obligated to pay monthly Base Rent or Additional Charges with respect to the Expansion Premises for the period from the Expansion Premises Delivery Date until the Expansion Date.
(d) Within five (5) business days after the Expansion Date, the parties shall execute a letter confirming the Expansion Date and certifying that Tenant has accepted delivery of the Premises, in form substantially similar to EXHIBIT “D” attached to the Lease (the “Expansion Date Memorandum”). Either party’s failure to request execution of, or to execute, the Expansion Date Memorandum shall not in any way alter the Expansion Date.
