Negotiation; Alternative Dispute Resolution The Parties will attempt in good faith to resolve any dispute or controversy arising out of or relating to the performance of services under this Agreement. If the Parties are unable to resolve the dispute, then, pursuant to San Francisco Administrative Code Section 21.36, Contractor may submit to the Contracting Officer a written request for administrative review and documentation of the Contractor's claim(s). Upon such request, the Contracting Officer shall promptly issue an administrative decision in writing, stating the reasons for the action taken and informing the Contractor of its right to judicial review. If agreed by both Parties in writing, disputes may be resolved by a mutually agreed-upon alternative dispute resolution process. If the parties do not mutually agree to an alternative dispute resolution process or such efforts do not resolve the dispute, then either Party may pursue any remedy available under California law. The status of any dispute or controversy notwithstanding, Contractor shall proceed diligently with the performance of its obligations under this Agreement in accordance with the Agreement and the written directions of the City. Neither Party will be entitled to legal fees or costs for matters resolved under this section.
Alternative Dispute Resolution Prior to filing of litigation, the parties may select non-binding mediation as a method of conflict resolution for issues arising out of or relating to this procurement process or any contract resulting from or any contemplated transaction. The parties agree that if non-binding mediation is chosen as a resolution process, the parties must agree to the chosen mediator(s) and that all mediation venue shall be at a location in Xxx Xxxxx County, Texas or agreed by the parties. The parties agree to share equally the cost of the mediation process and venue cost.
Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. 5 5 Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. 6
Dispute Resolution Mandatory Arbitration Class Action Waiver SAMPLE
(a) Claims Subject to Arbitration. Except as expressly provided below, the parties agree that to the fullest extent permitted by applicable law, any dispute arising out of or relating in any way to this Agreement or a similar prior agreement, the Property or the relationship between Resident and Owner or Manager (including matters occurring prior to the date of this Agreement and disputes also involving third parties) (collectively, “Claims”) will, at the election of either party, be resolved by arbitration, including any dispute about arbitrability, such as scope and enforceability.
Mandatory Arbitration Except as provided in subsection (h) of this Section 31, any Dispute must be resolved by binding arbitration in accordance with the following:
(a) Either Party may begin arbitration by filing a demand for arbitration in accordance with the Commercial Arbitration Rules of the AAA (the “Arbitration Rules”) and concurrently notifying the other Party of that demand. If the Parties are unable to agree upon a panel of three neutral arbitrators within twenty days after the demand for arbitration was filed (the Parties agree to a reasonable, one-time extension of that twenty-day period), either Party may request the Houston, Texas office of the American Arbitration Association (“AAA”) to appoint the arbitrator or arbitrators necessary to complete the panel in accordance with the Arbitration Rules. Each arbitrator so appointed shall be deemed accepted by the Parties as part of the panel. Notwithstanding the foregoing, the Parties, by mutual consent, may agree to a single arbitrator instead of a panel of three arbitrators and, in such event, references herein to “panel” shall refer to the single appointed arbitrator.
(b) The arbitration shall be conducted in the Houston, Texas metropolitan area at a place and time agreed upon by the Parties with the panel, or if the Parties cannot agree, as designated by the panel. The panel may, however, call and conduct hearings and meetings at such other places as the Parties may agree or as the panel may, on the motion of one Party, determine to be necessary to obtain significant testimony or evidence.
(c) The panel may authorize any and all forms of discovery upon a Party’s showing of need that the requested discovery is likely to lead to material evidence needed to resolve the Dispute and is not excessive in scope, timing, or cost.
(d) The arbitration shall be subject to the Federal Arbitration Act and conducted in accordance with the Arbitration Rules to the extent that they do not conflict with this Section 31. The Parties and the panel may, however, agree to vary to provisions of this Section 31 or the matters otherwise governed by the Arbitration Rules as permitted by law.
(e) The arbitration hearing shall be held within 60 days after the appointment of the panel. The panel’s final decision or award shall be made within 30 days after the hearing. That final decision or award shall be made by unanimous or majority vote or consent of the arbitrators constituting the panel, and shall be deemed issued at the place of arbitration. The panel’s final decision or award shall be based on the terms and conditions of this Agreement and applicable law.
(f) The panel’s final decision or award may include injunctive relief in response to any actual or impending breach of this Agreement or any other actual or impending action or omission of a Party under or in connection with this Agreement.
(g) The panel’s final decision or award shall be final and binding upon the Parties, and judgment upon that decision or award may be entered in any court having jurisdiction. The Parties waive any right to apply or appeal to any court for relief from the preceding sentence or from any decision of the panel that is made before the final decision or award.
(h) Nothing in this Section 31 limits the right of either Party to apply to a court having jurisdiction to (i) enforce the agreement to arbitrate in accordance with this Section 31, (ii) seek provisional or temporary injunctive relief, in response to an actual or impending breach of the Agreement or otherwise so as to avoid an irreparable damage or maintain the status quo, until a final arbitration decision or award is rendered or the Dispute is otherwise resolved, or challenge or vacate any final arbitration decision or award that does not comply with this Section 31. In addition, nothing in this Section 31 prohibits the Parties from resolving any Dispute (in whole or in part) at any time by mutual agreement or compromise. This Section 31 shall also not preclude the Parties at any time from mutually agreeing to pursue non-binding mediation of the Dispute.
(i) The panel may proceed to an award notwithstanding the failure of any Party to participate in such proceedings. The prevailing Party in the arbitration proceeding may be entitled to an award of reasonable attorneys’ fees incurred in connection with the arbitration in such amount, if any, as determined by the panel in its discretion. The costs of the arbitration shall be borne equally by the Parties unless otherwise determined by the panel in its award.
(j) The panel shall be empowered to impose sanctions and to take such other actions as it deems necessary to the same extent a judge could impose sanctions or take such other actions pursuant to the Federal Rules of Civil Procedure and applicable law. Each Party agrees to keep all Disputes and arbitration proceedings strictly confidential except for disclosure of information required by applicable law which cannot be waived.
Referral to Dispute Resolution If the Issuing Entity, the Owner Trustee, the Indenture Trustee, a Noteholder or a Note Owner (the “Requesting Party”) requests that World Omni repurchase a Receivable due to an alleged breach of a representation and warranty in Section 3.01(a) (which repurchase request shall provide sufficient detail so as to allow World Omni to reasonably investigate the alleged breach of the representations and warranties in Section 3.01(a); provided that with respect to a repurchase request from a Noteholder or a Note Owner, such repurchase request shall initially be provided to the Indenture Trustee) (each, a “Repurchase Request”), and the Repurchase Request has not been resolved, the alleged breach has not otherwise been cured or the related Receivable has not otherwise been repurchased, paid-off or otherwise satisfied, within 180 days of the receipt of notice of the Repurchase Request by World Omni, the Requesting Party may refer the matter, in its discretion, to either mediation (including non-binding arbitration) or binding third-party arbitration by filing in accordance with ADR Rules and providing a notice to World Omni. The Requesting Party must start the mediation (including non-binding arbitration) or arbitration proceeding according to the ADR Rules of the ADR Organization within 90 days after the end of the 180-day period. World Omni agrees to participate in the dispute resolution method selected by the Requesting Party. However, if the Receivable subject to a Repurchase Request was part of a Review and the Review Report states no Test Fails for the Receivable, the Repurchase Request for the Receivable will be deemed to have been resolved.
Alternate Dispute Resolution In the event of any issue of controversy under this Agreement, the PARTIES may pursue Alternate Dispute Resolution procedures to voluntarily resolve those issues. These procedures may include, but are not limited to, conciliation, facilitation, mediation, and fact finding.
I2 Dispute Resolution The Parties shall attempt in good faith to negotiate a settlement to any dispute between them arising out of or in connection with the Contract within twenty (20) Working Days of either Party notifying the other of the dispute and such efforts shall involve the escalation of the dispute to the finance director of the Contractor and the commercial director of the Authority.
Applicable Law; Dispute Resolution i. This Agreement, and all claims, disputes or disagreements arising out of or connected with this Agreement, its validity or any breach thereof, shall be governed by the laws in effect in the State of Texas (excluding conflicts of laws provisions), and to the extent applicable to maritime issues, the maritime laws of the United States (excluding conflict of laws provisions).
ii. PHA and Carrier desire to resolve any dispute, which may arise in connection with the Agreement in a timely and efficient manner. The parties therefore agree that the parties will attempt to resolve disputes arising hereunder in accordance with the following procedures.
iii. Either party may request the other to attend a meeting for the purpose of resolving any dispute or disagreement arising from the provisions specified in the Agreement. Said meeting shall be held either in person in Houston, Texas, or by telephone within five (5) business days of receipt of written request specifying a brief description of the dispute, the monetary amount involved if known, and the remedies sought.
iv. If the matter is not resolved in such meeting, or if such meeting is not held, either party may make written demand to attempt to resolve such dispute by non-binding mediation. Within seven (7) days after service of written notice on the other party demanding mediation, the parties in dispute shall jointly agree upon a mediator, and within thirty (30) days thereafter the parties shall undertake such mediation in Houston, Texas. In no event shall the parties be obligated to pursue mediation that does not resolve the issue within thirty
Governing Law; Dispute Resolution (a) This Limited Guarantee shall be interpreted, construed and governed by and in accordance with the Laws of the State of New York without regard to the conflicts of law principles thereof that would subject such matter to the Laws of another jurisdiction other than the State of New York.
(b) Any disputes, actions and proceedings against any party or arising out of or in any way relating to this Limited Guarantee shall be submitted to the Hong Kong International Arbitration Centre (the “HKIAC”) and resolved in accordance with the Arbitration Rules of HKIAC in force at the relevant time (the “Rules”) and as may be amended by this Section 10(b). The place of arbitration shall be Hong Kong. The official language of the arbitration shall be English and the arbitration tribunal shall consist of three arbitrators (each, an “Arbitrator”). The claimant(s), irrespective of number, shall nominate jointly one Arbitrator; the respondent(s), irrespective of number, shall nominate jointly one Arbitrator; and a third Arbitrator will be nominated jointly by the first two Arbitrators and shall serve as chairman of the arbitration tribunal. In the event the claimant(s) or respondent(s) or the first two Arbitrators shall fail to nominate or agree on the joint nomination of an Arbitrator or the third Arbitrator within the time limits specified by the Rules, such Arbitrator shall be appointed promptly by the HKIAC. The arbitration tribunal shall have no authority to award punitive or other punitive-type damages. The award of the arbitration tribunal shall be final and binding upon the disputing parties. Any party to an award may apply to any court of competent jurisdiction for enforcement of such award and, for purposes of the enforcement of such award, the parties irrevocably and unconditionally submit to the jurisdiction of any court of competent jurisdiction and waive any defenses to such enforcement based on lack of personal jurisdiction or inconvenient forum.
(c) Notwithstanding the foregoing, the parties hereto consent to and agree that in addition to any recourse to arbitration as set out in Section 10(b), any party may, to the extent permitted under the Laws of the jurisdiction where application is made, seek an interim injunction from a court or other authority with competent jurisdiction and, notwithstanding that this Agreement is governed by the Laws of the State of New York, a court or authority hearing an application for injunctive relief may apply the procedural Law of the jurisdiction where the court or other authority is located in determining whether to grant the interim injunction. For the avoidance of doubt, this Section 10(c) is only applicable to the seeking of interim injunctions and does not restrict the application of Section 10(b) in any way.
