Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES The Allottee hereby agrees to purchase the [Apartment/Plot] on the specific understanding that is/her right to the use of Common Areas shall be subject to timely payment of total maintenance charges, as determined and thereafter billed by the maintenance agency appointed or the association of allottees (or the maintenance agency appointed by it) and performance by the Allottee of all his/her obligations in respect of the terms and conditions specified by the maintenance agency or the association of allottees from time to time.
Limitations on Sale and Lease-Back Transactions (a) The Company shall not, nor shall it permit any Restricted Subsidiary to, enter into any Sale and Lease-Back Transaction with respect to any Principal Property, other than any such transaction involving a lease for a term of not more than three years or any such transaction between the Company and a Restricted Subsidiary or between Restricted Subsidiaries, unless: (1) the Company or such Restricted Subsidiary would be entitled to incur indebtedness secured by a Lien on the Principal Property involved in such transaction at least equal in amount to the Attributable Debt with respect to such Sale and Lease-Back Transaction, without equally and ratably securing the Notes as described in Section 4.02(a); or (2) the Company shall apply an amount equal to the greater of the net proceeds of such sale or the Attributable Debt with respect to such Sale and Lease-Back Transaction within 365 days of such sale to either (or a combination of) the retirement (other than mandatory retirement, mandatory prepayment or sinking fund payment or by a payment at maturity) of debt for borrowed money of the Company or a Restricted Subsidiary that matures more than 12 months after the creation of such indebtedness or the purchase, construction or development of other comparable property.
(b) Notwithstanding the restrictions outlined in clause (a) above, the Company or any Restricted Subsidiary shall be permitted to enter into Sale and Lease-Back Transactions which would otherwise be subject to such restrictions, without applying the net proceeds of such transactions in the manner set forth in clause (2) of the preceding paragraph, provided that after giving effect thereto, the aggregate amount of such sale and Lease-Back Transactions, together with the aggregate amount of all Secured Debt not permitted by clauses (1) through (11) under Section 4.02(a), does not exceed the greater of $1,000 million or 15% of Consolidated Net Tangible Assets of the Company as most recently determined on or prior to such date.
Definitions of Key Terms Relating to Additional Rent As used in this Article 4, the following terms shall have the meanings hereinafter set forth:
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Maintenance of Properties and Leases Each Loan Party shall, and shall cause each of its Subsidiaries to, maintain in good repair, working order and condition (ordinary wear and tear excepted) in accordance with the general practice of other businesses of similar character and size, all of those properties useful or necessary to its business, and from time to time, such Loan Party will make or cause to be made all appropriate repairs, renewals or replacements thereof.
RIGHT OF ALLOTTEE TO USE COMMON AREAS AND FACILITIES SUBJECT TO PAYMENT OF TOTAL MAINTENANCE CHARGES
COMPLIANCE WITH COVENANTS, RESTRICTIONS AND BUILDING CODE Lessor warrants that any improvements (other than those constructed by Lessee or at Lessee's direction) on or in the Premises which have been constructed or installed by Lessor or with Lessor's consent or at Lessor's direction shall comply with all applicable covenants or restrictions of record and applicable building codes, regulations and ordinances in effect on the Commencement Date. Lessor further warrants to Lessee that Lessor has no knowledge of any claim having been made by any governmental agency that a violation or violations of applicable building codes, regulations, or ordinances exist with regard to the Premises as of the Commencement Date. Said warranties shall not apply to any Alterations or Utility Installations (defined in Paragraph 7.3(a)) made or to be made by Lessee. If the Premises do not comply with said warranties, Lessor shall, except as otherwise provided in this Lease, promptly after receipt of written notice from Lessee given within six (6) months following the Commencement Date and setting forth with specificity the nature and extent of such non-compliance, take such action, at Lessor's expense, as may be reasonable or appropriate to rectify the non-compliance. Lessor makes no warranty that the Permitted Use in Paragraph 1.8 is permitted for the Premises under Applicable Laws (as defined in Paragraph 2.4).
Compliance with Laws; Payment of Taxes and Liabilities (a) Comply, and cause each other Loan Party to comply, in all material respects with all applicable laws, rules, regulations, decrees, orders, judgments, licenses and permits, except where failure to comply could not reasonably be expected to have a Material Adverse Effect; (b) without limiting clause (a) above, ensure, and cause each other Loan Party to ensure, that no person who owns a controlling interest in or otherwise controls a Loan Party is or shall be (i) listed on the Specially Designated Nationals and Blocked Person List maintained by the Office of Foreign Assets Control (“OFAC”), Department of the Treasury, and/or any other similar lists maintained by OFAC pursuant to any authorizing statute, Executive Order or regulation or (ii) a person designated under Section 1(b), (c) or (d) of Executive Order No. 13224 (September 23, 2001), any related enabling legislation or any other similar Executive Orders, (c) without limiting clause (a) above, comply, and cause each other Loan Party to comply, with all applicable Bank Secrecy Act (“BSA”) and anti-money laundering laws and regulations and (d) pay, and cause each other Loan Party to pay, prior to delinquency, all taxes and other governmental charges against it or any collateral, as well as claims of any kind which, if unpaid, could become a Lien on any of its property; provided that the foregoing shall not require any Loan Party to pay any such tax or charge so long as it shall contest the validity thereof in good faith by appropriate proceedings and shall set aside on its books adequate reserves with respect thereto in accordance with GAAP and, in the case of a claim which could become a Lien on any collateral, such contest proceedings shall stay the foreclosure of such Lien or the sale of any portion of the collateral to satisfy such claim.
Tax Matters; Compliance with REMIC Provisions (a) Each of the Trustee and the Master Servicer covenants and agrees that it shall perform its duties hereunder in a manner consistent with the REMIC Provisions and shall not knowingly take any action or fail to take any action that would (i) affect the determination of the Trust Estate's status as a REMIC; or (ii) cause the imposition of any federal, state or local income, prohibited transaction, contribution or other tax on either the REMIC or the Trust Estate. The Master Servicer, or, in the case of any tax return or other action required by law to be performed directly by the Trustee, the Trustee, shall (i) prepare or cause to be prepared, timely cause to be signed by the Trustee and file or cause to be filed annual federal and applicable state and local income tax returns using a calendar year as the taxable year for the REMIC and the accrual method of accounting; (ii) in the first such federal tax return, make, or cause to be made, elections satisfying the requirements of the REMIC Provisions, on behalf of the Trust Estate, to treat the Trust Estate as a REMIC; (iii) prepare, execute and forward, or cause to be prepared, executed and forwarded, to the Certificateholders all information reports or tax returns required with respect to the REMIC, as and when required to be provided to the Certificateholders, and to the Internal Revenue Service and any other relevant governmental taxing authority in accordance with the REMIC Provisions and any other applicable federal, state or local laws, including without limitation information reports relating to "original issue discount" and "market discount" as defined in the Code based upon the issue prices, prepayment assumption and cash flows provided by the Seller to the Trustee and calculated on a monthly basis by using the issue prices of the Certificates; (iv) make available information necessary for the application of any tax imposed on transferors of residual interests to "disqualified organizations" (as defined in the REMIC Provisions); (v) file Form 8811 and apply for an Employee Identification Number with a Form SS-4 or any other permissible method and respond to inquiries by Certificateholders or their nominees concerning information returns, reports or tax returns; (vi) maintain (or cause to be maintained by the Servicers) such records relating to the REMIC, including but not limited to the income, expenses, individual Mortgage Loans (including REO Mortgage Loans), other assets and liabilities of the REMIC, and the fair market value and adjusted basis of the property of the REMIC determined at such intervals as may be required by the Code, as may be necessary to prepare the foregoing returns or information reports; (vii) exercise reasonable care not to allow the creation of any "interests" in the REMIC within the meaning of Code Section 860D(a)(2) other than the interests represented by the Class A-1, Class B-1, Class B-2, Class B-3, Class B-4, Class B-5 and Class B-6 Certificates; (viii) exercise reasonable care not to allow the occurrence of any "prohibited transactions" within the meaning of Code Section 860F(a), unless the Master Servicer shall have provided an Opinion of Counsel to the Trustee that such occurrence would not (a) result in a taxable gain, (b) otherwise subject either the Trust Estate or the REMIC to tax or (c) cause the Trust Estate to fail to qualify as a REMIC; (ix) exercise reasonable care not to allow the REMIC to receive income from the performance of services or from assets not permitted under the REMIC Provisions to be held by a REMIC; (x) pay (on behalf of the REMIC) the amount of any federal income tax, including, without limitation, prohibited transaction taxes, taxes on net income from foreclosure property, and taxes on certain contributions to a REMIC after the Startup Day, imposed on the REMIC, when and as the same shall be due and payable (but such obligation shall not prevent the Master Servicer or any other appropriate Person from contesting any such tax in appropriate proceedings and shall not prevent the Master Servicer from withholding or depositing payment of such tax, if permitted by law, pending the outcome of such proceedings); and (xi) if required or permitted by the Code and applicable law, act as "tax matters person" for the REMIC within the meaning of Treasury Regulations Section 1.860F-4(d), and the Master Servicer is hereby designated as agent of the Class A-R Certificateholder for such purpose (or if the Master Servicer is not so permitted, the Holder of the Class A-R Certificate shall be the tax matters person in accordance with the REMIC Provisions). The Master Servicer shall be entitled to be reimbursed pursuant to Section 3.02 for any taxes paid by it pursuant to clause (x) of the preceding sentence, except to the extent that such taxes are imposed as a result of the bad faith, willful misfeasance or gross negligence of the Master Servicer in the performance of its obligations hereunder. The Trustee shall sign the tax returns referred to in clause (i) of the second preceding sentence. In order to enable the Master Servicer or the Trustee, as the case may be, to perform its duties as set forth above, the Seller shall provide, or cause to be provided, to the Master Servicer within ten days after the Closing Date all information or data that the Master Servicer determines to be relevant for tax purposes to the valuations and offering prices of the Certificates, including, without limitation, the price, yield, prepayment assumption and projected cash flows of each Class of Certificates and the Mortgage Loans in the aggregate. Thereafter, the Seller shall provide to the Master Servicer or the Trustee, as the case may be, promptly upon request therefor, any such additional information or data that the Master Servicer or the Trustee, as the case may be, may from time to time request in order to enable the Master Servicer to perform its duties as set forth above. The Seller hereby indemnifies the Master Servicer or the Trustee, as the case may be, for any losses, liabilities, damages, claims or expenses of the Master Servicer or the Trustee arising from any errors or miscalculations by the Master Servicer or the Trustee pursuant to this Section that result from any failure of the Seller to provide, or to cause to be provided, accurate information or data to the Master Servicer or the Trustee, as the case may be, on a timely basis. The Master Servicer hereby indemnifies the Seller and the Trustee for any losses, liabilities, damages, claims or expenses of the Seller or the Trustee arising from the Master Servicer's willful misfeasance, bad faith or gross negligence in preparing any of the federal, state and local tax returns of the REMIC as described above. In the event that the Trustee prepares any of the federal, state and local tax returns of the REMIC as described above, the Trustee hereby indemnifies the Seller and the Master Servicer for any losses, liabilities, damages, claims or expenses of the Seller or the Master Servicer arising from the Trustee's willful misfeasance, bad faith or negligence in connection with such preparation.
(b) Notwithstanding anything in this Agreement to the contrary, each of the Master Servicer and the Trustee shall pay from its own funds, without any right of reimbursement therefor, the amount of any costs, liabilities and expenses incurred by the Trust Estate (including, without limitation, any and all federal, state or local taxes, including taxes imposed on "prohibited transactions" within the meaning of the REMIC Provisions) if and to the extent that such costs, liabilities and expenses arise from a failure of the Master Servicer or the Trustee, respectively, to perform its obligations under this Section 8.13.
