Meter Tampering Sample Clauses

Meter Tampering. Subject to Clause 9.3, Purchaser and Seller undertake not to tamper or otherwise interfere with any part of the Metering System in any way and shall ensure that the Metering System is not tampered with by any other person. Where it is established that the Main Metering Equipment has been tampered or interfered with, or is defective: a) the quantity measured or recorded shall be that measured or recorded by the Back-Up Metering Equipment or, failing that, any secondary metering; and b) if there is no Back-Up Metering Equipment or secondary metering, or it is also established to have been tampered with, interfered with or is defective, the quantity shall be determined by agreement between the Parties, or failing such agreement, as determined by an Expert.
Sample 1Sample 2
AutoNDA by SimpleDocs
Meter Tampering. The Customer shall not tamper with or cause damage to the Supplier’s water meter, shut off valve, or any other portion of the Meter Installation. Failure to do so may result in loss of water service. The Customer shall pay the cost of repairing or replacing the damaged property. Water service shall not be restored until the Customer has paid the cost of repairing or replacing the damaged property. In addition, the Supplier reserves the right to file criminal charges against the Customer.
Sample 1Sample 2
Meter Tampering. It is a violation under city law to enter a meter box for the purpose of reconnection, after it has been disconnected, for non-payment or for any reason deemed necessary by the Utility. A tampering fee of $100.00 will be assessed and charged. It is punishable by a citation and fine up to $500.00.
Sample 1Sample 2
Meter Tampering. KPLC and the Seller undertake not to tamper or otherwise interfere with the Metering System in any way with the object of effect of distorting the quantity measured or recorded by the Metering System. Where it is established that the Metering System has been tempered or interfered with, the quantity measured or recorded shall be determined in accordance with paragraph 2(b) or Part B of Schedule 4.
Sample 1
Meter Tampering. Prairieland shall have the right to discontinue chilled water service to any customer and remove its property from the customer’s premises, where Xxxxxxxxxxx discovers evidence of tampering with any meter or service wiring leading thereto, and where such tampering is for the purpose of reducing the customer’s chilled water consumption. A customer’s service so disconnected shall be reconnected after customer has furnished satisfactory evidence of compliance with Prairieland’s rules and/or Terms and Conditions of service and paid all service charges as hereinafter set forth: 1. All delinquent bills, if any; 2. The amount of any Prairieland revenue loss attributable to said tampering; 3. Expenses incurred by Prairieland in replacing or repairing the meter or other appliance or equipment, and in the preparation of the bill; 4. A cash deposit, the amount not to exceed 1/6 of the estimated annual charges, less the amount of any cash deposit which the customer currently has on file with Prairieland.
Sample 1
Meter Tampering. 4.10.1 It is the policy of the Corporation to prosecute persons in violation of Section 812.14, Florida Statutes, to the fullest extent of the law, which shall include both civil and criminal prosecution. 4.10.2 When tampering is discovered, the Corporation shall adhere to the following procedures: 4.10.2.1 Law enforcement authorities shall be notified so that a law enforcement officer may accompany an employee of the Corporation to the premises for the removal of any devices used and to prepare for possible criminal or civil prosecution. Pictures shall be taken and any unauthorized devices removed. 4.10.2.2 When tampering has occurred which reverses or bypasses the water meter, the Corporation shall sever service from the main water line to prevent a possible recurrence. Prior to disconnection of service, the Corporation shall inform whatever person may be present at the premises at the time of such disconnection of its intended action and the reason therefore. If no one is present, the corporation shall disconnect service without additional notice. 4.10.2.3 In cases of meter bypass or reversal, or where the meter seal, curb stop or lock has been broken, the account of the Member shall be back-billed for the cost of the damaged equipment plus an estimated amount of water consumed and not paid for.
Sample 1
Meter Tampering. 7.2.1 If it is found that there has been any alteration to the metering installation or equipment, that causes the metering equipment to register or measure incorrectly, the following steps will be taken: 7.2.1.1 R5000 charged will be added to the tenant’s account. 7.2.1.2 Back charge shall be calculated at the discretion of the landlord and deducted from the tenant’s account. 7.2.2 The landlord shall not be liable for the reinstatement of credit in a pre-­‐paid meter lost due to tampering with, or the incorrect use or the abuse of, prepayment meters and/or tokens. 7.2.3 Depending on the seriousness of the tampering, further steps can be taken by the landlord as set out in the municipal bylaws and/or best practice per reselling of services.
Sample 1
AutoNDA by SimpleDocs
Meter Tampering. If Cooperative's meter which serves Customer has been tampered with or bypassed, the Cooperative may discontinue service. For purposes of this section, meter tampering, bypass, or diversion shall be defined as tampering with an electric meter or equipment, bypassing the same, or other instances of diversion, such as physically disorienting the meter, objects attached to the meter to divert service or to bypass, insertion of objects into the meter, and other electrical and mechanical means of tampering with bypassing, or diverting electrical service or there has been a theft of electric service (Section 31.04 of the Penal Code of the State of Texas) or criminal mischief for having damaged or tampered with the Cooperative's property (Section 28.03 of the Penal Code of the State of Texas). The Cooperative may charge for all labor, material and equipment necessary to repair or replace all equipment damaged due to meter tampering or bypassing or other service diversion, and other costs necessary to correct service diversion where there is no equipment damage, including incidents where service is reconnected without authority. An itemized bill of such charges must be provided to the customer. The Cooperative may also estimate and bill the Customer for electric service over the entire period of meter tampering, meter bypassing or service diversion.
Sample 1

Related to Meter Tampering

  • Metering The Interconnection Customer shall be responsible for the Connecting Transmission Owner’s reasonable and necessary cost for the purchase, installation, operation, maintenance, testing, repair, and replacement of metering and data acquisition equipment specified in Attachments 2 and 3 of this Agreement. The Interconnection Customer’s metering (and data acquisition, as required) equipment shall conform to applicable industry rules and Operating Requirements.

  • Meter Testing Company shall provide at least twenty-four (24) hours' notice to Seller prior to any test it may perform on the revenue meters or metering equipment. Seller shall have the right to have a representative present during each such test. Seller may request, and Company shall perform, if requested, tests in addition to the every fifth-year test and Seller shall pay the cost of such tests. Company may, in its sole discretion, perform tests in addition to the fifth year test and Company shall pay the cost of such tests. If any of the revenue meters or metering equipment is found to be inaccurate at any time, as determined by testing in accordance with this Section 10.2 (Meter Testing), Company shall promptly cause such equipment to be made accurate, and the period of inaccuracy, as well as an estimate for correct meter readings, shall be determined in accordance with Section 10.3 (Corrections).

  • Calibration The comparison of a measurement system or device of unverified accuracy with a measurement system of known and greater accuracy to detect deviation of the unverified measurement system from required performance specifications (of the unverified measurement system or device) and to quantify all measured values to applicable units of the international system of units.

  • Outputs Analogue and digital outputs of protected content are allowed if they meet the requirements in this section and if they are not forbidden elsewhere in this Agreement..

  • Outages 9.7.1.1 Outage Authority and Coordination. Interconnection Customer and Transmission Owner may each in accordance with Good Utility Practice in coordination with the other Party and Transmission Provider remove from service any of its respective Interconnection Facilities, System Protection Facilities, Network Upgrades, System Protection Facilities or Distribution Upgrades that may impact the other Party’s facilities as necessary to perform maintenance or testing or to install or replace equipment. Absent an Emergency Condition, the Party scheduling a removal of such facility(ies) from service will use Reasonable Efforts to notify one another and schedule such removal on a date and time mutually acceptable to the Parties. In all circumstances, any Party planning to remove such facility(ies) from service shall use Reasonable Efforts to minimize the effect on the other Parties of such removal.

  • Access Toll Connecting Trunk Group Architecture 9.2.1 If CSTC chooses to subtend a Verizon access Tandem, CSTC’s NPA/NXX must be assigned by CSTC to subtend the same Verizon access Tandem that a Verizon NPA/NXX serving the same Rate Center Area subtends as identified in the LERG. 9.2.2 CSTC shall establish Access Toll Connecting Trunks pursuant to applicable access Tariffs by which it will provide Switched Exchange Access Services to Interexchange Carriers to enable such Interexchange Carriers to originate and terminate traffic to and from CSTC’s Customers. 9.2.3 The Access Toll Connecting Trunks shall be two-way trunks. Such trunks shall connect the End Office CSTC utilizes to provide Telephone Exchange Service and Switched Exchange Access to its Customers in a given LATA to the access Tandem(s) Verizon utilizes to provide Exchange Access in such LATA. 9.2.4 Access Toll Connecting Trunks shall be used solely for the transmission and routing of Exchange Access to allow CSTC’s Customers to connect to or be connected to the interexchange trunks of any Interexchange Carrier which is connected to a Verizon access Tandem.

  • Physical Access Control Unauthorized persons are prevented from gaining physical access to premises, buildings or rooms where data processing systems that process and/or use Personal Data are located.

  • Network Interconnection Architecture Each Party will plan, design, construct and maintain the facilities within their respective systems as are necessary and proper for the provision of traffic covered by this Agreement. These facilities include but are not limited to, a sufficient number of trunks to the point of interconnection with the tandem company, and sufficient interoffice and interexchange facilities and trunks between its own central offices to adequately handle traffic between all central offices within the service areas at a P.01 grade of service or better. The provisioning and engineering of such services and facilities will comply with generally accepted industry methods and practices, and will observe the rules and regulations of the lawfully established tariffs applicable to the services provided.

  • Compatibility 1. Any unresolved issue arising from a mutual agreement procedure case otherwise within the scope of the arbitration process provided for in this Article and Articles 25A to 25G shall not be submitted to arbitration if the issue falls within the scope of a case with respect to which an arbitration panel or similar body has previously been set up in accordance with a bilateral or multilateral convention that provides for mandatory binding arbitration of unresolved issues arising from a mutual agreement procedure case. 2. Nothing in this Article and Articles 25A to 25G shall affect the fulfilment of wider obligations with respect to the arbitration of unresolved issues arising in the context of a mutual agreement procedure resulting from other conventions to which the Contracting States are or will become parties.”.

  • SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!