No Additional Compensation for Delays within Developer’s Control Sample Clauses

No Additional Compensation for Delays within Developer’s Control. 16.3.1 Developer is aware that governmental agencies and utilities, including, without limitation, the Division of the State Architect, the Department of General Services, gas companies, electrical utility companies, water districts, and other agencies may have to approve Developer-prepared drawings or approve a proposed installation. Accordingly, Xxxxxxxxx has included in the Guaranteed Maximum Price, time for possible review of its drawings and for reasonable delays and damages that may be caused by such agencies, including without limitation delays due to California Environmental Quality Act (“CEQA”) compliance. Thus, Developer is not entitled to make a claim for damages for delays arising from the review of Developer’s drawings. 16.3.2 Developer shall only be entitled to compensation for delay when all of the following conditions are met: 16.3.2.1 The District is responsible for the delay; 16.3.2.2 The delay is unreasonable under the circumstances involved; 16.3.2.3 The delay was not within the contemplation of the District and Developer; 16.3.2.4 The delay could not have been avoided or mitigated by reasonable diligence; and 16.3.2.5 Developer timely complies with the claims procedure of the Contract Documents. 16.3.3 Where a change in the Work extends the Contract Time, Developer may request and recover additional, actual direct costs, provided that Developer can demonstrate such additional costs are: 16.3.3.1 Actually incurred performing the Work; 16.3.3.2 Not compensated by the Markup allowed; and 16.3.3.3 Directly result from the extended Contract Time. 16.3.4 Contractor shall comply with all required procedures, documentation and time requirements in the Contract Documents. Contractor may not seek or recover such costs using formulas (e.g. Eichleay, labor factors).
AutoNDA by SimpleDocs
No Additional Compensation for Delays within Developer’s Control. 16.3.1. Developer is aware that governmental agencies, including, without limitation, the Division of the State Architect, the Department of General Services, gas companies, electrical utility companies, water districts, and other agencies may have to approve Developer-prepared drawings or approve a proposed installation. Accordingly, Developer has included in the Guaranteed Project Cost, time for possible review of its drawings and for reasonable delays and damages that may be caused by such agencies. Thus, Developer is not entitled to make a claim for damages or delays arising from the review of Developer’s drawings. 16.3.2. Developer shall only be entitled to compensation for delay when all of the following conditions are met: 16.3.2.1. The District or it’s consultants, employees, architects or contractors are responsible for the delay; 16.3.2.2. The delay was not reasonably anticipated by District and Developer; and 16.3.2.3. Developer complies with the claims procedure of the Contract Documents.
No Additional Compensation for Delays within Developer’s Control. 16.3.1 Developer is aware that governmental agencies and utilities, including, without limitation, the Division of the State Architect, the Department of General Services, gas companies, electrical utility companies, water districts, and other agencies may have to approve Developer-prepared drawings or approve a proposed installation. Accordingly, Xxxxxxxxx has included in the Guaranteed Maximum Price, time for possible review of its drawings and for reasonable delays and damages that may be caused by such agencies, including without limitation delays due to California Environmental Quality Act (“CEQA”) compliance. Thus, Developer is not entitled to make a claim for damages for delays arising from the review of Developer’s drawings. 16.3.1.1 Developer shall only be entitled to compensation for delay when all of the following conditions are met: 16.3.1.1.1 The District is responsible for the delay. 16.3.1.1.2 The delay is unreasonable under the circumstances involved. 16.3.1.1.3 The delay could not have been avoided or mitigated by reasonable diligence; and 16.3.1.1.4 Developer timely complies with the claims procedure of the Contract Documents.
No Additional Compensation for Delays within Developer’s Control. 1Developer is aware that governmental agencies and utilities, including, without limitation, the Division of the State Architect, the Department of General Services, gas companies, electrical utility companies, water districts, and other agencies may have to approve Developer-prepared drawings or approve a proposed installation. Accordingly, Xxxxxxxxx has included in the Guaranteed Maximum Price, time for possible review of its drawings and for reasonable delays and damages that may be caused by such agencies, including without limitation delays due to California Environmental Quality Act (“CEQA”) compliance. Thus, Developer is not entitled to make a claim for damages for delays arising from the review of Developer’s drawings.
No Additional Compensation for Delays within Developer’s Control. 16.3.1 Developer is aware that governmental agencies and utilities, including, without limitation, the Division of the State Architect, the Department of General Services, gas companies, electrical utility companies, water districts, and other agencies may have to approve Developer-prepared drawings or approve a proposed installation. Accordingly, Xxxxxxxxx has included in the Guaranteed Maximum Price, time for possible review of its drawings and for reasonable delays and damages that may be caused by such agencies, including without limitation delays due to California Environmental Quality Act (“CEQA”) compliance. Thus, Developer is not entitled to make a claim for damages for delays arising from the review of Developer’s drawings. 16.3.2 Developer shall only be entitled to compensation for delay when all of the following conditions are met: 16.3.2.1 The District is responsible for the delay; 16.3.2.2 The delay is unreasonable under the circumstances involved; 16.3.2.3 The delay was not within the contemplation of the District and Developer; 16.3.2.4 The delay could not have been avoided or mitigated by reasonable diligence; and 16.3.2.5 Developer timely complies with the claims procedure of the Contract Documents. 16.3.3 Where an event for which District is responsible impacts the projected Completion Date, the Developer shall provide a written mitigation plan, including a schedule diagram, which explains how (e.g., increase crew size, overtime, etc.) the impact can be mitigated. The Developer shall also include a detailed cost breakdown of the labor, equipment, and material the Developer would expend to mitigate District-caused time impact. The Developer shall submit its mitigation plan to District within fourteen (14) calendar days from the date of discovery of the impact. The Developer is responsible for the cost to prepare the mitigation plan. 16.3.4 Where a change in the Work extends the Contract Time, Developer may request and recover additional, actual direct costs, provided that Developer can demonstrate such additional costs are: 16.3.4.1 Actually incurred performing the Work; 16.3.4.2 Not compensated by the Markup allowed; and 16.3.4.3 Directly result from the extended Contract Time. 16.3.5 Developer shall comply with all required procedures, documentation and time requirements in the Contract Documents. Developer may not seek or recover such costs using formulas (x.x. Xxxxxxxx, labor factors). No time will be granted under this Contract for cu...

Related to No Additional Compensation for Delays within Developer’s Control

  • No Additional Compensation Notwithstanding any other provision of this Agreement, the obligation of Agency to return Referred Accounts, provide current status reports of all such accounts or information reasonably required by Client shall be without right to any additional Contingent Fee, administrative fees or other compensation of any kind or type whatsoever after such termination date, including, without limitation, in quantum meruit, for any Services rendered prior to termination (except on recoveries received and remitted to Client pursuant to this Agreement prior to termination) whether or not said Services result in or contribute to recoveries received after termination.

  • Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.

  • Compensation for Additional Services Additional Services shall be compensated as set forth on Exhibit A for the stipulated payment amounts set forth therein. Other Additional Services not set forth on Exhibit A that are required or requested by the Owner shall be compensated as agreed, using the methodology set forth on Exhibit A, prior to the Design Professional undertaking such Additional Services; provided, however, that if such compensation cannot be agreed, the Additional Services shall be performed at the hourly rates set forth and listed in Exhibit B, plus reimbursable expenses pursuant to Article 4.1.3 below, with a limitation as to maximum amount specified.

  • Compensation for Losses Upon demand of any Lender (with a copy to the Administrative Agent) from time to time, the Borrower shall promptly compensate such Lender for and hold such Lender harmless from any loss, cost or expense incurred by it as a result of: (a) any continuation, conversion, payment or prepayment of any Loan other than a Base Rate Loan on a day other than the last day of the Interest Period for such Loan (whether voluntary, mandatory, automatic, by reason of acceleration, or otherwise); (b) any failure by the Borrower (for a reason other than the failure of such Lender to make a Loan) to prepay, borrow, continue or convert any Loan other than a Base Rate Loan on the date or in the amount notified by the Borrower; or (c) any assignment of a Eurodollar Rate Loan on a day other than the last day of the Interest Period therefor as a result of a request by the Borrower pursuant to Section 10.13; including any loss of anticipated profits and any loss or expense arising from the liquidation or reemployment of funds obtained by it to maintain such Loan or from fees payable to terminate the deposits from which such funds were obtained. The Borrower shall also pay any customary administrative fees charged by such Lender in connection with the foregoing. For purposes of calculating amounts payable by the Borrower to the Lenders under this Section 3.05, each Lender shall be deemed to have funded each Eurodollar Rate Loan made by it at the Eurodollar Rate for such Loan by a matching deposit or other borrowing in the London interbank eurodollar market for a comparable amount and for a comparable period, whether or not such Eurodollar Rate Loan was in fact so funded.

  • Six Month Delay for Specified Employees If any payment, compensation or other benefit provided to the Executive in connection with his employment termination is determined, in whole or in part, to constitute “nonqualified deferred compensation” within the meaning of Section 409A and the Executive is a “specified employee” as defined in Section 409A, no part of such payments shall be paid before the day that is six months plus one day after the Executive’s date of termination or, if earlier, the Executive’s death (the “New Payment Date”). The aggregate of any payments that otherwise would have been paid to the Executive during the period between the date of termination and the New Payment Date shall be paid to the Executive in a lump sum on such New Payment Date. Thereafter, any payments that remain outstanding as of the day immediately following the New Payment Date shall be paid without delay over the time period originally scheduled, in accordance with the terms of this Agreement.

  • Compensation for Overtime Assigned overtime is designated as those hours over the regular hours of work which are requested of the employee by management. Assigned overtime worked shall be paid at the rate of time and one-half (1 1/2).

  • Compensation for Loss of Employee Tools (a) The Employer will replace all Employee tools lost or stolen in accordance with the Award.

  • PROFESSIONAL COMPENSATION 11.1 The basic salaries of teachers covered by this Contract shall be set in accordance with the procedures set forth in this Agreement. 11.2 The salary of the teacher will be presumed correct as shown in the Uniform Teacher’s Contract unless the teacher or the Employer furnishes evidence of error. 11.3 An explanation as to how contract salary figures are computed will accompany the first paycheck of each school year. 11.4 Basic salaries for teachers shall be paid in twenty-six (26) payments. Basic salaries for teachers shall be paid in twenty-six (26) payments in a given calendar year. Exceptions may be made with the approval of the Cash Flow Committee. A teacher may receive the balance due on his contract with the first scheduled paycheck in July by written notice to the Business Office by May 1. If May 1 occurs on a day that school is not in session, the deadline shall be the next regular school day. A teacher who makes this election shall continue each year to receive the balance due on his contract with the first scheduled paycheck in July unless he notifies the Business Office by May 1 that he prefers to be paid in twenty-six (26) payments. Teachers will be notified by the Cash Flow Committee of the Xxxxxxx Teachers’ Federation prior to June 1 in the event the balance on teachers’ contracts due on the first scheduled paycheck in July cannot be paid. 11.5 New teachers will receive one half (½) of their first pay one payroll in advance and the remaining one half (½) on the next pay date. 11.6 Effective January 1, 2009, teacher pay will be issued via direct deposit only. 11.7 The Superintendent may approve additional compensation for individual teachers who have been authorized by the Superintendent to perform additional work assignments. 11.8 Payroll deductions for teachers shall be made as required by law or as mutually agreed to by the parties. Teachers may authorize deductions for tax-sheltered annuities during open enrollment periods of the carrier companies involved. 11.9 Deductions for daily absences not covered by provisions in the Contract shall be made at the same rate as earned. 11.10 Effective January 1, 1993, the Board shall pay directly to the Indiana State Teachers Retirement Fund each teacher’s three percent (3%) contribution to the fund. 11.11 The parties recognize that the salaries which appear on Regular Teacher’s Contracts and Teacher’s Temporary Contracts will be inaccurate whenever a salary increase is approved after these contracts have been executed. At the time of a teacher’s retirement, the Employer will review these contracts and, when necessary, revise the contracts for the five (5) years of service before retirement in which the teacher’s annual compensation was highest so they accurately reflect the sums which the teacher earned in each of those five (5) years. 11.12 The parties recognize that students are entitled to be taught by fully qualified teachers, while at the same time recognizing a professional responsibility to assist in the preparation of student teachers. Therefore, supervision by a teacher of a student teacher shall be voluntary. No teacher should serve as a supervising teacher more than one-half (1/2) of the total teaching time each year. This provision was not bargained and has been included for informational purposes only. Should 11.13 If the Employer determines that any committee should continue its work during the summer, teachers belonging to the committee performing such services shall be paid on the same basis and in the same manner as summer school teachers. If the Employer determines that professional development should occur in the summer, specific teachers invited to participate shall be paid on the same basis as summer school teachers.

  • Developer Compensation for Emergency Services If, during an Emergency State, the Developer provides services at the request or direction of the NYISO or Connecting Transmission Owner, the Developer will be compensated for such services in accordance with the NYISO Services Tariff.

  • ADDITIONAL COMPENSATION AND BENEFITS The Executive shall receive the following additional compensation and welfare and fringe benefits:

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!