No Additional Compensation for Early Completion Sample Clauses

No Additional Compensation for Early Completion. Nothing contained in the Contract Documents creates any contractual right, express or implied, on the part of XXXX to early completion of the Project. Under no circumstances shall Owner owe additional compensation to XXXX for XXXX’x inability to achieve completion of the Project before the expiration of the Contract Time, whether or not such inability is caused by the acts or omissions of Owner or any other party for which Owner is responsible, regardless of any approval by Owner of the Accepted Construction Schedule.
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
No Additional Compensation for Early Completion. Nothing contained in the Contract Documents creates any contractual right, express or implied, on the part of D-BE to early completion of the Project. Under no circumstances shall Owner owe additional compensation to D-BE for D-BE’s inability to achieve completion of the Project before the expiration of the Contract Time, whether or not such inability is caused by the acts or omissions of Owner or any other party for which Owner is responsible, regardless of any approval by Owner of the Accepted Project Schedule.
Sample 1
No Additional Compensation for Early Completion. Nothing contained in the Contract Documents creates any contractual right, express or implied, on the part of D-BE to early completion of the Project. Under no circumstances shall County owe additional compensation to D-BE for D-BE’s inability to achieve completion of the Project before the expiration of the Contract Time, whether or not such inability is caused by the acts or omissions of County or any other party for which County is responsible, regardless of any approval by County of the accepted Construction Schedule.
Sample 1
No Additional Compensation for Early Completion. Nothing contained in the Contract Documents creates any contractual right, express or implied, on the part of CM to early completion of the Project. Under no circumstances shall County owe additional compensation to CM for CM’s inability to achieve completion of the Project before the expiration of the Contract Time, whether or not such inability is caused by the acts or omissions of County or any other party for which County is responsible, regardless of any approval by County of the Accepted Construction Schedule. Credits: Regardless of whether the equitable adjustment associated with changed work is recorded through a lump sum or time-and-materials Change Order: (1) if the net value of a change to the work results in a credit from CM, then the credit given shall include costs as well as overhead and profit; or (2) if the net value of a change to the work results in additional costs, then overhead and profit will only be applied to the amount by which the added costs of the change exceed the credited amount. When a change proposed by County results in the deletion of work and the County and CM are unable to agree upon the cost, overhead, and profit thereof, the County's estimate of the cost, overhead, and profit shall be deducted from the Contract Price by a Change Order unless within 15 days of receiving the County's estimate CM presents proof that the County's estimate is in error.
Sample 1Sample 2
No Additional Compensation for Early Completion. Nothing contained in the Contract Documents creates any contractual right, express or implied, on the part of Contractor to early completion of the Project. Under no circumstances shall County owe additional compensation to Contractor for Contractor whether or not such inability is caused by the acts or omissions of County or any other party for which County is responsible, regardless of any approval by County of the Accepted Project Schedule.
Sample 1
No Additional Compensation for Early Completion. Nothing contained in the Contract Documents creates any contractual right, express or implied, on the part of CMARE to early completion of the Project. Under no circumstances shall County owe additional compensation to CMARE for CMARE whether or not such inability is caused by the acts or omissions of County or any other party for which County is responsible, regardless of any approval by County of the Accepted Construction Schedule. Credits: Regardless of whether the equitable adjustment associated with changed work is recorded through a lump sum or time-and-materials Change Order: (1) if the net value of a change to the work results in a credit from CMARE, then the credit given shall include costs as well as overhead and profit; or (2) if the net value of a change to the work results in additional costs, then overhead and profit will only be applied to the amount by which the added costs of the change exceed the credited amount. When a change proposed by County results in the deletion of work and the County and CMARE are unable to agree upon the cost, overhead, and profit thereof, the County's estimate of the cost, overhead, and profit shall be deducted from the Contract Price by a Change Order unless within 15 days of receiving the County's estimate CMARE presents proof that the County's estimate is in error.
Sample 1
No Additional Compensation for Early Completion. Nothing contained in the Contract Documents creates any contractual right, express or implied, on the part of Contractor to early completion of the Project. Under no circumstances shall County owe additional compensation to Contractor for Contractor’s inability to achieve completion of the Project before the expiration of the Contract Time, whether or not such inability is caused by the acts or omissions of County or any other party for which County is responsible, regardless of any approval by County of the Accepted Project Schedule. County of Orange, OC Public Works Credits: Regardless of whether the equitable adjustment associated with changed work is recorded through a lump sum or time-and-materials Change Order: (1) if the net value of a change to the work results in a credit from Contractor, then the credit given shall include costs as well as overhead and profit; or (2) if the net value of a change to the work results in additional costs, then overhead and profit will only be applied to the amount by which the added costs of the change exceed the credited amount. When a change proposed by County results in the deletion of work and the County and Contractor are unable to agree upon the cost, overhead, and profit thereof, the County's estimate of the cost, overhead, and profit shall be deducted from the Contract Price by a Change Order unless within 15 days of receiving the County's estimate Contractor presents proof that the County's estimate is in error. Overhead and Profit: Contractor shall receive a maximum 15% for overhead and profit on above items if Contractor uses its own forces to perform changed work. If Contractor 's subcontractor's forces perform changed work, then the subcontractor shall be entitled to a maximum of 15% on above items for its overhead and profit and Contractor shall be entitled to a maximum of 6% on above items for its overhead and profit on the changed work. County will pay only one overhead and profit markup of 6% for Contractor and one markup of 15% for the subcontractor in connection with changed work, regardless of the actual number of intervening subcontractors involved in the changed work. County will not pay any overhead or profit for omitted work. Regardless of whether the equitable adjustment associated with changed work is recorded through a lump sum or time-and-materials Change Order, the amount County pays for overhead and profit shall be Contractor's only compensation for: all costs of supervision, superinten...
Sample 1
AutoNDA by SimpleDocs

Related to No Additional Compensation for Early Completion

  • Additional Compensation Notwithstanding anything in this Memorandum of Understanding to the contrary when in the judgment of the Board, it becomes necessary or desirable to utilize the services of County employees in capacities other than those for which they are regularly employed, the Board may authorize and, if appropriate, fix an additional rate of compensation for such employees.

  • Final Compensation Final Compensation for an employee, who is employed by the State for the first time and becomes a member of CalPERS prior to January 15, 2011, is based on the highest average monthly pay rate during twelve (12) consecutive months of employment. Final Compensation for an employee, who is employed by the State for the first time and becomes a member of CalPERS on or after January 15, 2011, is based on the highest average monthly pay rate during thirty-six (36) consecutive months of employment.

  • HOLIDAY COMPENSATION FOR TIME WORKED 177. Employees required by their respective appointing officers to work on any of the above designated or observed holidays, excepting Fridays observed as holidays in lieu of holidays falling on Saturday, shall be paid extra compensation of one additional day's pay at time- and-one-half the usual rate (i.e. 12 hours pay for 8 hours worked) or a proportionate amount for less than 8 hours worked. At the employee's request and with the approval of the appointing officer, an employee may be granted compensatory time off in lieu of paid overtime pursuant to the provisions herein. 178. Executive, administrative and professional employees designated in the Annual Salary Ordinance with the "Z" symbol shall not receive extra compensation for holiday work but may be granted time off equivalent to the time worked at the rate of one-and-one-half times for work on the holiday.

  • Compensation for Overtime 9.5.1 All overtime hours, except those overtime hours exceeding twelve (12) hours in one day, shall be compensated at a rate of pay equal to time and one-half the regular rate of pay of the employee. Those overtime hours exceeding twelve (12) in one day shall be compensated at a rate of pay equal to two times the regular pay of the employee.

  • Compensation for Delay The time allowed for carrying out the work, as entered in the tender form, shall be strictly observed by the contractor and shall be deemed to be the essence of the contract and shall be reckoned from the fifteenth day after the date on which the order to commence the work is issued to the contractor, for a work where completion is up to 6 months For works, for which the completion period is beyond six months: - The period will be reckoned from the thirtieth day after the date on which the order to commence the work is issued to contractor .The work shall throughout the stipulated period of contract be proceeded with all due diligence, keeping in view that time is the essence of the contract. The contractor shall be bound in all cases, in which the time allowed for any work exceeds one month, to complete 1/8th of the whole work before 1/4th of the whole time allowed under the contract has elapsed, 3/8th of the work before 1/2 of such time has elapsed and 3/4th of the work before 3/4th of such time has elapsed. In the event of the contractor failing to comply with the above conditions, the Commissionor/CMO shall levy on the contractor, as compensation an amount equal to: 0.5% (zero point five percent) of the value of work (contract sum) for each week of delay, provided that the total amount of compensation under this provision of the clause shall be limited to 6% (six percent) of the value of work. (Contract sum) Provided further that if the contractor fails to achieve 30% (thirty percent) progress in half (1/2) of original or validly extended period of time (reference clause 5 below) the contract shall stand terminated after due notice to the contractor and his contract finallised, with xxxxxxx money and or security deposit forfeited and levy of further compensation at the rate of 10% of the balance amount of contract left incomplete, either from the bill, and or from available security/performance guarantee or shall be recovered as "Arrears of land revenue". The decision of the Competent Authority in the matter of grant of extension of time only (reference clause 5 below) shall be final, binding and conclusive. But he has no right to change either the rate of compensation or reduce and or condone the period of delay- once such an order is passed by him (on each extension application of the contractor). It shall not be open for a revision. Where the Commissioner/CMO or Competent Authority or Commissioner/CMO as the case may decides that the contractor is liable to pay compensation for not giving proportionate progress under this clause and the compensation is recommended during the intermediate period, such compensation shall be kept in deposit and shall be refunded if the contractor subsequently makes up the progress for the lost time, within the period of contract including extension granted, if any. failing which the compensation amount shall be forfeited in favour of the Nagar Xxxxx/Nagar Palika Parishad/Nagar Panchayat Clause 3 -:Action when the work is left incomplete abandoned or delayed beyond the time limit permitted by the Commissioner/CMO or Competent Authority: -

  • Lump Sum Compensation Lump sum computation refers to the method of payment under this Agreement for the professional services of the Consultant.

  • Basic Compensation An employee, at the employee's option, may report to court when subpoenaed or remain on call. If the employee elects to appear in court, the division supervisor must be notified, at the latest, one administrative day prior to the scheduled court appearance. If the employee wishes to remain on call, the employee must be able to appear in court not more than one hour after being notified that the employee's appearance is required in court. To appear in court more than an hour after having been notified will void the employee's right to on-call compensation. An employee need not remain at home, but must be available for telephonic notification at a location where the supervisor knows the employee can be reached.

  • Total Compensation Contractor shall include Total Compensation in XXX for each of its five most highly compensated Executives for the preceding fiscal year if:

  • Salary Determination 12.5.1 A unit member shall receive a salary not less than the minimum salary nor more than the maximum salary (Articles 12.3 and 12.4) for the rank to which appointed, except as provided in Articles 4.15, 5.6, 10.6.1 or Article 10.6.1.1. The effective dates for salaries shall be the appropriate dates specified in Article 12.2.2.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!