Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Final Space Plan Tenant shall supply Landlord with four (4) copies signed by Tenant of its final space plan for the Premises before any architectural working drawings or engineering drawings have been commenced. The final space plan (the “Final Space Plan”) shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Space Plan for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require, and (ii) deliver such revised Final Space Plan to Landlord.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.
Space Plans Prior to drafting any Construction Drawings, Tenant shall furnish Landlord with Tenant's final space plans for the Premises ("Space Plans"). The Space Plans shall show locations of all proposed improvements, including partitions, cabinetry, equipment and fixtures, shall identify materials and finishes by location, and shall specify the location of any proposed structural floor penetrations, the location and extent of floor loading in excess of Building capacity, if any, any special HVAC requirements, the location and description of any special plumbing requirements, and any special electrical requirements. In addition, the Space Plans shall show telephone and telecommunications facilities, and computer and electronic data facilities. Landlord shall approve or disapprove the Space Plans by written notice given to Tenant within ten (10) business days after receipt of the Space Plans. Landlord shall not unreasonably withhold its approval of the Space Plans, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plans if, in Landlord's good faith judgment, any one or more of the following situations exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Buildings; or (b) the proposed Tenant Improvements may impair the structural strength of the Buildings, adversely affect any Building Systems or materially adversely affect the value of the Buildings; or (c) the specifications for the proposed Tenant Improvements are not consistent with, or would detract from, the character or image of the Project. If Landlord disapproves the Space Plans, Landlord shall return the Space Plans to Tenant with a statement of Landlord's reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plans by written notice given to Tenant within five (5) business days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plans.
WORK LETTER This Lease is supplemented by that certain Work Letter of even date executed by Lessor and Lessee, attached hereto as Exhibit C, and incorporated herein by this reference.
Tenant’s Work After the Commencement Date, Tenant at its sole cost and expense intends to construct leasehold improvements in the Demised Premises (“Tenant’s Work”) as detailed in the plans and specifications to be prepared by Tenant’s architect (“TI Architect”). Tenant shall be allowed to select a general contractor to perform the Tenant’s Work, provided said general contractor shall be properly licensed, bonded and of a reputation reasonably acceptable to Landlord. An affiliate of Landlord, Minkoff Development Corporation (“MDC”), shall act as Landlord’s construction manager to review plans and oversee construction of the Tenant’s Work by the general contractor. MDC shall receive a fee equal to one percent (1%) of the cost of the Tenant’s Work, which fee shall not exceed $50,000. Tenant shall have the right to submit plans for the Tenant’s Work in stages for portions of the Demised Premises. Tenant shall cause the TI Architect to prepare and deliver to Landlord for Landlord’s or MDC’s review preliminary plans (architectural, mechanical, electrical, plumbing and structural, if necessary) and specifications for the proposed leasehold improvements (the “Preliminary Plans”). Landlord shall have five (5) business days after its receipt thereof (or such additional time as may reasonably be necessary) to review the Preliminary Plans, request any changes it deems reasonably appropriate, and indicate on the Preliminary Plans which portions of the leasehold improvements are to be removed by Tenant prior to the expiration or termination of the Lease. The TI Architect shall modify the Preliminary Plans to accommodate Landlord’s changes, and resubmit the revised plans (the “Revised Preliminary Plans”) to Landlord for approval. If Tenant or the TI Architect elect not to make said changes to the Preliminary Plans, then Landlord shall have the right to require Tenant to perform corresponding restoration work to effect said changes prior to the expiration or termination of the Lease. Upon receipt of Landlord’s approval of the Revised Preliminary Plans, the TI Architect shall prepare a complete set of construction drawings and specifications for the construction of the proposed leasehold improvements (the “Working Drawings”). The Working Drawings shall be in sufficient detail for (i) Tenant’s general contractor to obtain bids from all trades for and to perform the work described on the Working Drawings; (ii) Tenant’s general contractor to secure building permits from the requisite governmental authorities having jurisdiction over same; and (iii) Landlord or MDC to indicate the portion of Tenant’s Work, if any, which Tenant is to remove by expiration or termination of the Lease. The Working Drawings shall conform to and be consistent with the Revised Preliminary Plans and comply with all applicable Laws and Insurance Requirements, as those terms are defined in the Lease. The Working Drawings shall be submitted to MDC for review and approval, which approval (or a request for changes to be made) shall be given within ten (10) days after receipt thereof. Within five (5) business days after MDC’s approval of the Working Drawings, as modified by any revisions requested by MDC, Landlord and Tenant shall initial same to confirm their mutual approval thereof (the “Approved Working Drawings ”). The Approved Working Drawings will indicate which portions of the Tenant’s Work, if any, will have to be removed by Tenant prior to the expiration or termination of the Lease, and Tenant will timely comply with such requirement and repair any damage to the Land or the Building caused thereby at its own expense. Tenant will have no obligation to remove any other portion of the Tenant’s Work.
Completion of Landlord’s Work On or before the Target Commencement Date (subject to Tenant Delays and Force Majeure delays), Landlord shall substantially complete or cause to be substantially completed Landlord’s Work in a good and workmanlike manner, with the Building Shell in a water tight condition, in accordance with the TI Permit subject, in each case, to Minor Variations and normal “punch list” items of a non-material nature that do not interfere with the use of the Premises and with a certificate or temporary certificate of occupancy (or an equivalent approval having been issued) for the Premises permitting lawful occupancy of the Premises (but specifically excluding any permits, licenses or other governmental approvals required to be obtained in connection with Tenant’s operations in the Premises)(“Substantial Completion” or “Substantially Complete”). Upon Substantial Completion of Landlord’s Work, Landlord shall require the TI Architect and the general contractor to execute and deliver, for the benefit of Tenant and Landlord, a Certificate of Substantial Completion in the form of the American Institute of Architects (“AIA”) document G704, and Landlord will require the vendors installing the major mechanical equipment to perform operational testing/commissioning of their respective equipment to confirm that the same are in good working order and functioning as designed. Upon Tenant’s request, Landlord will deliver “as built” drawings of the Tenant Improvements to Tenant and will provide copies of all warranties and manuals relating to any components of the Tenant Improvements for which such items are provided. For purposes of this Work Letter, “Minor Variations” shall mean any modifications reasonably required: (i) to comply with all applicable Legal Requirements and/or to obtain or to comply with any required permit (including the TI Permit); (ii) to comply with any request by Tenant for modifications to the Tenant Improvements; (iii) to comport with good design, engineering, and construction practices that are not material; or (iv) to make reasonable adjustments for field deviations or conditions encountered during the construction of Landlord’s Work.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Tenant Improvement Costs The Tenant Improvements’ cost (the “Tenant Improvement Costs”) shall mean and include any and all costs and expenses of the Work, including, without limitation, all of the following: