Obligation to File Claims for Disputed Work Sample Clauses

Obligation to File Claims for Disputed Work. 25.1.1 Should Developer otherwise seek extra time or compensation for any reason whatsoever (“Disputed Work”), then Developer shall first follow procedures set forth in the Contract Documents including, without limitation, Articles 15, 16 and 17, all of which are conditions precedent to submitting a Claim pursuant to Article 25. A Notice of Delay or Proposed Change Order are less formal procedures that proceed the formal claim and do not constitute a Claim. A Claim also does not include correspondence, RFIs, vouchers, invoices, progress payment applications, or other routine or authorized form of requests for progress payments in compliance with the Contract. If a dispute remains, then Developer shall give written notice to District that expressly invokes this Article 25 within the time limits set forth herein. 25.1.2 Developer’s sole and exclusive remedy for Disputed Work is to file a written claim setting forth Developer’s position as required herein within the time limits set forth herein.
Sample 1Sample 2Sample 3See All (10)
AutoNDA by SimpleDocs
Obligation to File Claims for Disputed Work. Should it appear to the Contractor that the work to be performed or any of the matters relative to the Contract Documents are not satisfactorily detailed or explained therein, or should any questions arise as to the meaning or intent of the Contract Documents, or should any dispute arise regarding the true value of any work performed, work omitted, extra work that the Contractor may be required to perform, time extensions, payment to the Contractor during performance of the work, construction of the Project, and/or compliance with procedures or standards set forth in the Contract Documents, or should Contractor otherwise seek extra time or compensation FOR ANY REASON WHATSOEVER, then Contractor shall first follow the procedures set forth in this Agreement, including but not limited to Section 3.2, “Change Orders.” If a dispute remains, then Contractor shall give written notice to the City that expressly invokes this Section 3.3 and requests a determination of the issue. City shall decide the issue in writing within 15 days; City’s decision shall be final and the limitations period for the filing of a claim shall commence upon the City’s issuance of its decision. If Contractor disagrees with City’s decision, or if Contractor contends that City failed to provide a timely decision, then Contractor’s SOLE AND EXCLUSIVE REMEDY is to file a written claim setting forth Contractor’s position as required herein.
Sample 1Sample 2Sample 3
Obligation to File Claims for Disputed Work. 25.1.1 Should Developer otherwise seek extra time or compensation for any reason whatsoever (“Disputed Work”), then Developer shall first follow procedures set forth in the Contract Documents including, without limitation, Articles 15, 16 and 17, all of which are conditions precedent to submitting a Claim pursuant to Article 25. A Notice of Delay or Proposed Change Order are less formal procedures that proceed the formal claim and do not constitute a Claim. A Claim also does not include correspondence, RFIs, 25.1.2 Developer’s sole and exclusive remedy for Disputed Work is to file a written claim setting forth Developer’s position as required herein within the time limits set forth herein.
Sample 1Sample 2Sample 3
Obligation to File Claims for Disputed Work. Should it appear to the Contractor that the work to be performed or any of the matters relative to the Contract Documents are not satisfactorily detailed or explained therein, or should any questions arise as to the meaning or intent of the Contract Documents, or should Contractor have a claim against the City, as the term “claim” is defined in Section 9204 of the Public Contract Code, or should any dispute arise regarding the true value of any work performed, work omitted, extra work that the Contractor may be required to perform, time extensions, payment to the Contractor during performance of the work, construction of the Project, and/or compliance with procedures or standards set forth in the Contract Documents, or should Contractor otherwise seek extra time or compensation FOR ANY REASON WHATSOEVER (each, a “Claim”), then Contractor shall first follow the procedures set forth in this Agreement, including but not limited to Section 3.2, “Change Orders.” If a dispute remains, then Contractor shall give written notice by registered or certified mail with return receipt requested, and such Claim shall be resolved as set forth below.
Sample 1Sample 2
Obligation to File Claims for Disputed Work. 25.1.1 Should Developer otherwise seek extra time or compensation for any reason whatsoever (“Disputed Work”), then Developer shall first follow procedures set forth in the Contract Documents including, without limitation, Articles 15, 16 and 17, all of which are conditions precedent to submitting a Claim pursuant to Article 25. A Notice of Delay or Proposed Change Order are less formal procedures that proceed the formal claim and do not constitute a Claim. A Claim also does not include correspondence, RFIs, vouchers, invoices, 25.1.2 Developer’s sole and exclusive remedy for Disputed Work is to file a written claim setting forth Developer’s position as required herein within the time limits set forth herein.
Sample 1Sample 2

Related to Obligation to File Claims for Disputed Work

  • Claims Submission Unless otherwise prohibited by federal or state law, Provider will submit Clean Claims for all Covered Services to BCBSM within one hundred eighty (180) days of the date of service.

  • Disputed Claims 4.1 Notwithstanding paragraph 4.5 of this Schedule, payment by the Authority of all or any part of any invoice rendered or other claim for payment by the Contractor shall not signify approval of such invoice/claim. The Authority reserves the right to verify invoices/claims after the date of payment and subsequently to recover any sums which have been overpaid. 4.2 If any part of a claim rendered by the Contractor is disputed or subject to question by the Authority either before or after payment then the Authority may call for the Contractor to provide such further documentary and oral evidence as it may reasonably require to verify its liability to pay the amount which is disputed or subject to question and the Contractor shall promptly provide such evidence in a form satisfactory to the Authority. 4.3 If any part of a claim rendered by the Contractor is disputed or subject to question by the Authority, the Authority shall not withhold payment of the remainder. 4.4 If any invoice rendered by the Contractor is paid but any part of it is disputed or subject to question by the Authority and such part is subsequently agreed or determined not to have been properly payable then the Contractor shall forthwith repay such part to the Authority. 4.5 The Authority shall be entitled to deduct from sums due to the Contractor by way of set-off any amounts owed to it or which are in dispute or subject to question either in respect of the invoice for which payment is being made or any previous invoice.

  • Arbitrable Claims Except as otherwise specified below, all actions, disputes, claims and controversies under common law, statutory law or in equity of any type or nature whatsoever (including, without limitation, all torts, whether regarding negligence, breach of fiduciary duty, restraint of trade, fraud, conversion, duress, interference, wrongful replevin, wrongful sequestration, fraud in the inducement, usury or any other tort, all contract actions, whether regarding express or implied terms, such as implied covenants of good faith, fair dealing, and the commercial reasonableness of any Collateral disposition, or any other contract claim, all claims of deceptive trade practices or lender liability, and all claims questioning the reasonableness or lawfulness of any act), whether arising before or after the date of this Agreement, and whether directly or indirectly relating to: (a) this Agreement and/or any amendments and addenda hereto, or the breach, invalidity or termination hereof; (b) any previous or subsequent agreement between DFS and Dealer; (c) any act committed by DFS or by any parent company, subsidiary or affiliated company of DFS (the "DFS Companies"), or by any employee, agent, officer or director of a DFS Company whether or not arising within the scope and course of employment or other contractual representation of the DFS Companies provided that such act arises under a relationship, transaction or dealing between DFS and Dealer; and/or (d) any other relationship, transaction or dealing between DFS and Dealer (collectively the "Disputes"), will be subject to and resolved by binding arbitration.

  • CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.

  • Claims Process We intend to appoint the senior trustee as the authorized representative to take action on behalf of holders of each series of the notes under the guarantee. The authorized representative will agree to make a demand of the FDIC upon our failure to pay interest or principal on any series of the notes when due. As provided in the FDIC’s regulations, a holder will also have the option to elect not to be represented by the authorized representative. Upon our failure to pay interest or principal, the authorized representative and a holder that has elected not to be so represented must follow the FDIC’s required procedures for making a demand under the guarantee. In addition to the procedures described below, the authorized representative will be required when making a demand, to the extent not previously provided in the master agreement, to provide the FDIC with information regarding its authority, including: its financial and organizational capacity to act as representative, its exclusive authority to act on behalf of each noteholder and its fiduciary responsibility to the noteholders when acting as such, as established by the senior indenture, and its authority to make the assignment of each noteholder’s right, title, and interest in the notes to the FDIC. Any demand under the guarantee must be accompanied by a proof of claim, satisfactory in form and content to the FDIC, which includes evidence of the occurrence of a payment default and the claimant’s ownership of the applicable notes. The claimant must provide to the FDIC an assignment, satisfactory in form and content to the FDIC, of the noteholder’s right, title and interest in the notes to the FDIC and the transfer to the FDIC of any claim in any insolvency proceeding against us. The assignment must also grant to the FDIC the right to receive any and all distributions on the note from the proceeds of any bankruptcy. If a holder receives a payment on a note from a bankruptcy, any obligation of the FDIC under the guarantee would be reduced proportionally. Demands must be made by the authorized representative or by a holder that elects not to be represented by the authorized representative within 60 days of the occurrence of the payment default. Upon payment by the FDIC of any amount under the guarantee, the FDIC will be subrogated to the rights of the recipient noteholder against us, including in respect of any insolvency proceeding, to the extent of such payment.

  • Claims Review The IRO shall perform the Claims Review annually to cover each of the five Reporting Periods. The IRO shall perform all components of each Claims Review.

  • Third Party Claim Procedures In the case of any claim asserted by a third party (a “Third Party Claim”) against a party entitled to indemnification under this Agreement (an “Indemnified Party”), notice shall be given by the Indemnified Party to the party required to provide indemnification (the “Indemnifying Party”) promptly after such Indemnified Party has actual knowledge of such Third Party Claim, and the Indemnified Party shall permit the Indemnifying Party (at the expense of such Indemnifying Party and so long as the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party for Losses related to such Third Party Claim) to assume the defense of such Third Party Claim, provided that (a) counsel for the Indemnifying Party who shall conduct the defense of such Third Party Claim shall be reasonably satisfactory to the Indemnified Party, and the Indemnified Party may participate in such defense at such Indemnified Party’s expense, and (b) the failure of any Indemnified Party to give notice as provided herein shall not relieve the Indemnifying Party of its indemnification obligation under this Agreement except to the extent that such failure results in a lack of actual notice to the Indemnifying Party and such Indemnifying Party is materially prejudiced as a result of such failure to be given notice. If the Indemnifying Party does not promptly assume the defense of such Third Party Claim following notice thereof, the Indemnified Party shall be entitled to assume and control such defense and to settle or agree to pay in full such Third Party Claim without the consent of the Indemnifying Party without prejudice to the ability of the Indemnified Party to enforce its claim for indemnification against the Indemnifying Party hereunder. Except with the prior written consent of the Indemnified Party, no Indemnifying Party, in the defense of any such Third Party Claim, shall consent to entry of any judgment or enter into any settlement that provides for injunctive or other nonmonetary relief affecting the Indemnified Party or that does not include as an unconditional term thereof the giving by each claimant or plaintiff to such Indemnified Party of an irrevocable release from all liability and wrongdoing with respect to such Third Party Claim. Seller and Buyers shall cooperate in the defense of any Third Party Claim subject to this Article IX and the records of each shall be reasonably available to the other with respect to such defense.

  • Claims for Benefits All Claims for benefits will be deemed to have been filed on the date received by AvMed. If a Claim is a Pre-Service or Urgent Care Claim, a Health Professional with knowledge of the Member’s Condition will be permitted to act as the Member’s authorized representative, and will be notified of all approvals on the Member’s behalf.

  • Litigation; Disputes No legal action may be brought against NCCI, its shareholders, officers, employees, and/or agents for actions taken reasonably and in good faith in fulfilling the specifically stated responsibilities of NCCI under this Agreement. NCCI reserves the right to obtain a determination from a court of competent jurisdiction as to the ownership of funds and/or documents in its possession in the event it receives conflicting instructions, instructions which are, in the opinion of NCCI, inconsistent with this Agreement, or if NCCI fails to receive instructions which NCCI concludes that it requires to fulfill its duties under this Agreement.

  • Litigation; Claims Any rights (including indemnification) and claims and recoveries under litigation of Seller against third parties arising out of or relating to events prior to the Closing Date;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!