Princeton University Design Standards Sample Clauses

Princeton University Design Standards. Any design services provided under individual RO’s shall comply with the then current release of the Princeton University Facilities Design Standards Manual (the “Design Standards”). If the Professional Services Contractor judges an aspect of the Design Standards to be in conflict with a Project requirement, or to be otherwise detrimental to the Project, the Professional Services Contractor shall so notify, and abide by written direction from, the Princeton University Representative. If the Professional Services Contractor deviates from the Design Standards without specific written authorization from Princeton University to do so, Princeton University may instruct the Professional Services Contractor to modify any design documents as necessary, without additional compensation, to comply with the Design Standards. In the event that any aspect of the Project is constructed in a manner which deviates from the Design Standards without specific written authorization from Princeton University, in addition to any other rights or remedies which may be available pursuant to the terms of this BOA or by operation of law, Princeton University specifically reserves the right to claim an error or omission on the part of the Professional Services Contractor in that regard and seek indemnification therefore.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Princeton University Design Standards. Any design services provided as Basic Services under individual Release Orders shall comply with the Princeton University Facilities Design Standards Manual Release 12.0 (June 2018) (the “Design Standards”). Notwithstanding the preceding, the Professional Services Consultant is obligated to review the Design Standards subject to Professional Services Consultant’s Professional Standard and if the Professional Services Consultant judges any aspect of the Design Standards to be in conflict with a Project requirement, or any of the statutes, laws, codes, rules, regulation and orders for which the Professional Services Consultant shall design any Release Order Project and/or provide its Basic Services as provided in paragraph (e) above, or to be otherwise detrimental to the Project in any manner whatsoever, the Professional Services Consultant shall so notify the Princeton University Representative in writing, and abide by written direction from the Princeton University Representative; provided, however, that if in its professional judgment, the Professional Services Consultant believes that any such direction from the Princeton University Representative would violate any of the statutes, laws, codes, rules, regulation and orders for which the Professional Services Consultant shall design any Release Order Project and/or provide its Basic Services as provided in paragraph (e) above or its Professional Standard or sound design practice, or is likely to result in additional cost or delay, the Professional Services Consultant shall so notify the Princeton University Representative in writing before proceeding. If the Professional Services Consultant deviates from the Design Standards without specific written authorization from Princeton University to do so, Princeton University may instruct the Professional Services Consultant to modify any Design Documents or other Basic Services as necessary, without additional compensation and no adjustment to the Fixed Price or NTE Price, to comply with the Design Standards. In the event that any aspect of any Release Order Project is designed and constructed in a manner which deviates from the Design Standards without specific written authorization from Princeton University, in addition to any other rights or remedies which may be available pursuant to the terms of this BOA or by operation of law, Princeton University specifically reserves the right to make a Claim (as defined in Article XVII(a)) and/or other claim for errors...
Sample 1See All (4)

Related to Princeton University Design Standards

  • Research Design The data generated by excavations at the prehistoric site(s) will be used to examine at least three topics: (1) chronology; (2) technology; and (3) subsistence practices. Insights into changing patterns of community organization may also be granted, as may insights into changes in social organization. The data recovered will then be compared to data from other regional sites.

  • Schematic Design Phase Services § 3.2.1 The Architect shall review the program and other information furnished by the Owner, and shall review laws, codes, and regulations applicable to the Architect’s services.

  • Design Standards Most recent edition of the “Owner’s Design Standards,” including any partial updates as may be directed by the Owner.

  • SCOPE OF ARCHITECT’S BASIC SERVICES 3.1 The Architect’s Basic Services consist of those described in this Article 3 and include usual and customary structural, mechanical, and electrical engineering services. Services not set forth in this Article 3 are Supplemental or Additional Services.

  • Design Development Phase Services 3.3.1 Based on the Owner’s approval of the Schematic Design Documents, and on the Owner’s authorization of any adjustments in the Project requirements and the budget for the Cost of the Work, the Architect shall prepare Design Development Documents for the Owner’s approval. The Design Development Documents shall illustrate and describe the development of the approved Schematic Design Documents and shall consist of drawings and other documents including plans, sections, elevations, typical construction details, and diagrammatic layouts of building systems to fix and describe the size and character of the Project as to architectural, structural, mechanical and electrical systems, and other appropriate elements. The Design Development Documents shall also include outline specifications that identify major materials and systems and establish, in general, their quality levels.

  • University Any notice may be served upon the University by delivering it, in writing, to the University at the address set forth on the last page of this Agreement, by depositing it in a United States Postal Service deposit box with the postage fully prepaid and with the notice addressed to the University at the aforementioned address, or by sending a facsimile of it to the University facsimile number set forth on the last page of this Agreement.

  • Alignment with Modernization Foundational Programs and Foundational Capabilities The activities and services that the LPHA has agreed to deliver under this Program Element align with Foundational Programs and Foundational Capabilities and the public health accountability metrics (if applicable), as follows (see Oregon’s Public Health Modernization Manual, (xxxx://xxx.xxxxxx.xxx/oha/PH/ABOUT/TASKFORCE/Documents/public_health_modernization_man ual.pdf):

  • Design Professional to Design Work The Design Professional Contract requires the Design Professional to design and to prepare the Contract Documents, a copy of which shall be furnished to the Contractor upon request. The Design Professional Contract requires the Design Professional to designate a readily accessible representative (either on Site or by computer, phone or fax or otherwise) who shall have authority promptly to render decisions and to furnish information required of the Design Professional.

  • Study Design This includes a discussion of the evaluation design employed including research questions and hypotheses; type of study design; impacted populations and stakeholders; data sources; and data collection; analysis techniques, including controls or adjustments for differences in comparison groups, controls for other interventions in the State and any sensitivity analyses, and limitations of the study.

  • Research Use The Requester agrees that if access is approved, (1) the PI named in the DAR and (2) those named in the “Senior/Key Person Profile” section of the DAR, including the Information Technology Director and any trainee, employee, or contractor1 working on the proposed research project under the direct oversight of these individuals, shall become Approved Users of the requested dataset(s). Research use will occur solely in connection with the approved research project described in the DAR, which includes a 1-2 paragraph description of the proposed research (i.e., a Research Use Statement). Investigators interested in using Cloud Computing for data storage and analysis must request permission to use Cloud Computing in the DAR and identify the Cloud Service Provider (CSP) or providers and/or Private Cloud System (PCS) that they propose to use. They must also submit a Cloud Computing Use Statement as part of the DAR that describes the type of service and how it will be used to carry out the proposed research as described in the Research Use Statement. If the Approved Users plan to collaborate with investigators outside the Requester, the investigators at each external site must submit an independent DAR using the same project title and Research Use Statement, and if using the cloud, Cloud Computing Use Statement. New uses of these data outside those described in the DAR will require submission of a new DAR; modifications to the research project will require submission of an amendment to this application (e.g., adding or deleting Requester Collaborators from the Requester, adding datasets to an approved project). Access to the requested dataset(s) is granted for a period of one (1) year, with the option to renew access or close-out a project at the end of that year. Submitting Investigator(s), or their collaborators, who provided the data or samples used to generate controlled-access datasets subject to the NIH GDS Policy and who have Institutional Review Board (IRB) approval and who meet any other study specific terms of access, are exempt from the limitation on the scope of the research use as defined in the DAR.

Time is Money Join Law Insider Premium to draft better contracts faster.