Project Co Representative Sample Clauses

Project Co Representative. (a) (Contact): The Project Co Representative must act as the principal point of contact between Project Co and the State and be available to the State as and when required. (b) (Presence): Project Co must ensure that the Project Co Representative is present at the Site at such times as are necessary to ensure that Project Co is complying with its obligations in accordance with this Agreement and upon reasonable request by the State Representative. (c) (Directions): A direction is given to Project Co if it is given to the Project Co Representative. (d) (Replacement): Project Co may only replace the Project Co Representative if any such replacement has the prior approval of the State (which must not be unreasonably withheld). (e) (Employee of Project Co): The Project Co Representative must be an officer or employee of Project Co or a Related Body Corporate of Project Co (as that term is defined in the Corporations Xxx 0000 (Cth)). (f) (Authority and skills): Project Co will ensure that at all times during his or her appointment, the Project Co Representative has: (i) the authority to perform its role and duties and discharge its obligations in accordance with paragraph (g) and elsewhere in this Agreement; and (ii) a detailed knowledge of the Project and sufficient experience and skills to undertake the role of Project Co Representative. (g) (Duties during the Term): The Project Co Representative will be the principal person responsible for direct liaison with the State in connection with this Agreement and the Project during the Term and must perform the duties of the Project Co Representative in accordance with this Agreement, including to: (i) (spokesperson): act as the spokesperson for Project Co; (ii) (partnership): ensure the ongoing implementation of a partnership with the State; (iii) (management): understand, co-ordinate and manage all phases of the Project throughout the Term; (iv) (liaison): liaise and generally deal with stakeholders; (v) (manage): represent the views of Project Co and manage and co- ordinate issues with any Project Co Associate prior to presentation to the State; and (vi) (presence): ensure a strong presence and consistent project management role for Project Co in the implementation of the Project.
Sample 1
AutoNDA by SimpleDocs
Project Co Representative. (a) The Project Co Representative shall be appointed pursuant to this Agreement. or such other person (b) Project Co shall ensure that the Project Co Representative is competent and qualified to act in such role in connection with this Agreement. (c) The Project Co Representative shall have full authority to act on behalf of Project Co for all purposes of this Agreement and TfL shall be entitled to treat any act of the Project Co Representative in connection with this Agreement as being expressly authorised by Project Co, and TfL shall not be required to determine whether any express authority has in fact been given. (d) Promptly upon the Project Co Representative ceasing to act in the case of resignation, death or serious illness and prior to termination of the appointment in all other cases, Project Co shall by notice to TfL appoint a substitute Project Co Representative. (e) Any appointment of a replacement Project Co Representative shall be subject to the approval of TfL (such approval not to be unreasonably withheld or delayed). (f) The Project Co Representative may appoint a deputy to carry out any of the functions which it is authorised to perform in accordance with clause 4.9(c) and Project Co shall notify TfL of the identity of any such deputy.
Sample 1
Project Co Representative. (a) (Appointment): The Project Co Representative is the person set out in Schedule 1 (Contract Particulars) or such other person as may be appointed from time to time to replace that person in accordance with this Clause 5.4.
Sample 1
Project Co Representative. (a) Subject to the limitations set out in Section 3.2(d), the Project Co Representative shall have full authority to act on behalf of Project Co for all purposes of this Project Agreement. (b) Project Co may change the Project Co Representative with the prior written consent of the Province, not to be unreasonably withheld or delayed. (c) During any period when the Project Co Representative is unable, through illness, incapacity or any other reason whatsoever, to perform the Project Co Representative’s functions under this Project Agreement, or where no Project Co Representative is appointed, Project Co shall perform or may, by written notice to the Province, promptly appoint an alternative Project Co Representative to perform the functions which would otherwise be performed by the Project Co Representative, provided that, Project Co must seek the Province’s consent in accordance with Section 3.2(b) if such alternative Project Co Representative is in place for more than 180 days. Upon receipt of such written notice, the Province and the Province Representative shall be entitled to treat any act of such alternative Project Co Representative which is permitted by this Project Agreement as being authorized by Project Co, and the Province and the Province Representative shall not be required to determine whether authority has in fact been given. (d) The Project Co Representative shall not, except as otherwise provided in this Project Agreement, be entitled to modify or waive any provision of this Project Agreement. (e) Subject to the limitations set out in Section 3.2(d), unless otherwise notified in writing, the Province and the Province Representative shall be entitled to treat any act of the Project Co Representative which is authorized by this Project Agreement as being authorized by Project Co, and the Province and the Province Representative shall not be required to determine whether authority has in fact been given.
Sample 1

Related to Project Co Representative

  • Project Representative City shall designate a Project Manager to represent City in coordinating this Project with Consulting Engineer/Architect, with authority to transmit instructions and define policies and decisions of City.

  • Contractor’s Representative Contractor hereby designates [***INSERT NAME OR TITLE***], or his or her designee, to act as its representative for the performance of this Agreement (“Contractor’s Representative”). Contractor’s Representative shall have full authority to represent and act on behalf of the Contractor for all purposes under this Agreement. The Contractor’s Representative shall supervise and direct the Services, using his best skill and attention, and shall be responsible for all means, methods, techniques, sequences and procedures and for the satisfactory coordination of all portions of the Services under this Agreement.

  • Contractor Representative The Contractor shall appoint a Contractor Representative fluent in English, who shall:

  • Safety Representative On every job site, workers may elect a Workers’ Safety Representative in accordance with the Act.

  • City’s Representative The City hereby designates Xxx Xxxxx, or his or her designee, to act as its representative for the performance of this Agreement (“City’s Representative”). City’s Representative shall have the power to act on behalf of the City for all purposes under this Contract. Consultant shall not accept direction or orders from any person other than the City’s Representative or his or her designee.

  • Representative The employee or School Board may be represented during any step of the procedure by any person or agent designated by such party to act in his behalf.

  • Staff Representatives A. The Union will provide the Employer with a written list of staff representatives and the bargaining unit for which they are responsible. The Union will provide written notice to the Employer of any changes within thirty (30) calendar days of the changes. B. Staff representatives may have access to the Employer’s offices or facilities to carry out representational activities. The representatives will notify the Employer prior to their arrival and will not interrupt the normal operations of the Employer. The staff representative may meet with bargaining unit employees in non-work areas during the employee’s meal periods, rest periods, and before and after the employee’s shift. C. The Employer’s written Board of Trustee or administrative policies pertaining to employees represented by the Union will be made available to staff representatives.

  • Project Representatives The Contractor designates the following individual as project representative for all matters concerning this Agreement: Xxx Xxxxxxxxx, Principal 00000 Xxxxxx Xxxxxxxx Xxxxxxx, Xxxxx 000, Xxxxxxxx, Xxxxxxxx 00000 Phone: 000.000.0000 Email: Xxx@XXXX.xxx The Authority designates the following individual as Contract Administrator/project representative to be the initial point of contact for all matters concerning this Agreement: Xxxx Xxxxxxxxxxxxx, Authority Buyer 000 Xxxx Xxxxxxxx Xxxxxx, Xxxxxxx, Xxxxxxxx 00000 Phone: 000.000.0000 Email: XxxxxxxxxxxxxX0@xxxxxxxx.xxx Except for changes to the performance schedule (not including the project’s completion date), the designated project representatives shall have no authority to make promises or binding obligations on behalf of the Authority, as such authority rests with the duly authorized persons executing this Agreement.

  • Union Representative Visits The Union shall inform the Employer in advance whenever the designated representatives of the Union intend to visit the Employer’s premises for the purpose of conducting Union business. Such visits shall not interfere with the normal operations of the worksite. Reasonable accommodation will be made to allow the Presidents of the Unions to have access to union members to conduct union business.

  • Project Coordinator Within 14 days of the effective date of this Consent Agreement, DTSC and Respondent shall each designate a Project Coordinator and shall notify each other in writing of the Project Coordinator selected. Each Project Coordinator shall be responsible for overseeing the implementation of this Consent Agreement and for designating a person to act in his/her absence. All communications between Respondent and DTSC, and all documents, report approvals, and other correspondence concerning the activities performed pursuant to this Consent Agreement shall be directed through the Project Coordinators. Each party may change its Project Coordinator with at least seven days prior written notice.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!