Resumption of Work, Delivery or Erection Sample Clauses

Resumption of Work, Delivery or Erection. At any time following a suspension under Clause 25.1 the Purchaser may give notice to the Contractor to proceed with the Works, which are the subject of a suspension. Not later than 30 (thirty) days after the receipt of such notice to resume the suspended part of the Works, the Contractor shall submit a Request for Variation to the Purchaser its request for additional Cost due to such suspension in accordance with Clause 27 and its request for extension of Time for Completion in accordance with Clause 33. The extension of Time for Completion shall also take into account a reasonable period for resumption. If any such suspension continues for more than 14 (fourteen) days and the suspension is not necessitated by the reasons stated in Clause 25.4 the Contractor may by notice to the Purchaser elect to treat the suspension as a Variation instructed by the Purchaser under Clause 27 of the part affected thereby. Upon such notice to the Purchaser by the Contractor, the risk of loss or damage to the suspended portion of the Works shall pass to the Purchaser. If any suspension affects the whole of the Works and continues for 180 (one hundred eighty)days, the Contractor may terminate the Contract in which event it shall be entitled to be paid in accordance with Clause 46.3.1(b). The Purchaser shall reserve the right to elect at its discretion to treat the suspension as a Variation of part of the Works or to terminate the Contract. Upon receipt of notice to proceed, the Contractor shall examine the Works affected by the suspension. The Contractor shall make good any deterioration or defect in or loss of the Works that may have occurred during suspension. The Cost incurred by the Contractor in making such examination and of making good and resuming work shall be assessed by the Engineer and added to the Contract Price unless the suspension was necessitated by any of the reasons stated in Clause 25.4, in which event such Cost shall be borne by the Contractor. The Contractor shall not be entitled to be paid any Cost incurred in making good any deterioration, defect or loss caused by defective materials or workmanship of or by the Contractor's failure to comply with any instructions of the Purchaser under Clause 25.1 (Instructions to Suspend).
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Resumption of Work, Delivery or Erection

  • CORRECTION OF WORK 13.2.1 The Contractor shall be responsible for correcting all Work which the Architect has found to be defective or which fails to conform to the Contract Documents whether observed be- fore or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear all costs of correcting such rejected Work, including compensation for the Architect's and the State’s additional services made necessary thereby. 13.2.2 If, within one year after the Date of Substantial Completion of the Work or designated portion thereof or within one year after acceptance by the State of designated equipment or within such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, the Contractor shall correct it promptly after receipt of a written notice from the State to do so unless the State has previously given the Contractor a written acceptance of such condition. This obligation shall survive termination of the Contract. The State shall give such notice promptly after discovery of the condition. 13.2.3 The Contractor shall remove from the site all portions of the Work which are defective or non-conforming and which have not been corrected under Subparagraphs 4.5.1, 13.2.1 and 13.2.4 If the Contractor fails to correct defective or nonconforming Work as provided in Subparagraphs 4.5.1, 13.2.1 and 13.2.2, the State may correct it in accordance with Paragraph 13.2.5 If the Contractor does not proceed with the correction of such defective or non- conforming Work within a reasonable time fixed by written notice from the Architect, the State may remove it and may store the materials or equipment at the expense of the Contractor. If the Contractor does not pay the cost of such removal and storage within ten days thereafter, the State may upon ten additional days written notice sell such Work at auction or at private sale and shall account for the net proceeds thereof, after deducting all the costs that should have been borne by the Contractor, including compensation for the Architect's and the State’s additional services and expenses made necessary thereby. If such proceeds of sale do not cover all costs which the Contractor should have borne, the difference shall be charged to the Contractor and an appropriate Change Order shall be issued. If the payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the State. 13.2.6 The Contractor shall bear the cost of making good all work of the State or separate contractors destroyed or damaged by such correction or removal. 13.2.7 Nothing contained in this Paragraph 13.2 shall be construed to establish a period of limitation with respect to any other obligation which the Contractor might have under the

  • Location of Work The Executive shall be based in the United States in West Orange, New Jersey. However, the Executive agrees to undertake whatever domestic and worldwide travel is required by the Company. The Executive shall not be required or permitted to relocate without the mutual, written consent of the Executive and the Company.

  • Coordination of Work Licensee shall be responsible for coordination of its Equipment installation work to avoid any interference with existing utilities, substructures, facilities and/or SFMTA transit operations. Licensee shall be the City's point of contact for all Equipment installation and except in case of emergency, all communications concerning Equipment installation shall be through Licensee's field representatives.

  • Inspection of Work It is FIRST PARTY's obligation to make the work product available for CITY's inspections and periodic reviews upon request by CITY.

  • Delivery of Work If the Director terminates the Master Agreement and/or any Approved Service Order(s) – whether for convenience or for cause – the Director has the option of requiring the Consultant to provide to the City any finished or unfinished Work Product prepared by the Consultant up to the date of Consultant’s receipt of the written notice of termination.

  • Rejection of Work Using the Notice of Non-Conforming Work procedures outlined in the General Conditions, the Design Professional shall reject work that does not comply with the requirements of the Contract Documents or that does not comply with the applicable laws and codes. The Design Professional shall have authority to order testing of the Work, as is provided in the Contract Documents or as otherwise required in its judgment, whether such work is fabricated, installed, or completed.

  • Cessation and Resumption of Work 24.15.1 At the time employees cease work due to inclement weather the employer or the employers representative on site and the employee’s representative shall agree and note the time of cessation of work. 24.15.2 After the period of inclement weather has clearly ended the employees shall resume work and the time shall be similarly agreed and noted.

  • Performance of Work by City If the Contractor fails to perform the Work in accordance with the schedule referred to in section 2 above, the City may, in its discretion, in order to bring the project closer to the schedule, perform or cause to be performed some or all of the Work, and doing so shall not waive any of the City’s rights and remedies. Before doing so, the City shall give the Contractor notice of its intention. The Contractor shall reimburse the City for additional costs incurred by the City in exercising its right to perform or cause to be performed some or all of the Work pursuant to this section.

  • Completion of Work The Contractor agrees to complete the work on, or before October 29, 2021.

  • Acceptance of Work The completion of the Work shall be subject to acceptance by NYSERDA in writing of all deliverables as defined in Exhibit A, Statement of Work.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!