Contract Amendment A. Contract Exhibit A, Scope of Work, is hereby deleted and replaced in its entirety with the attached Exhibit A, Scope of Work, which is incorporated into the Contract by reference herein.
B. Contract Exhibit B, Additional Special Contract Conditions, is hereby deleted in its entirety and replaced with the attached Exhibit B, Additional Special Contract Conditions, which is incorporated into the ACS by reference herein.
C. Contract Exhibit I, PUR 1355: Foreign Country of Concern Attestation, is hereby incorporated in its entirety to the ACS by reference herein.
Lane closure (i) The Contractor shall not close any lane of the Project Highway for undertaking maintenance works except with the prior written approval of the Authority’s Engineer. Such approval shall be sought by the Contractor through a written request to be made at least 10 (ten) days before the proposed closure of lane and shall be accompanied by particulars thereof. Within 5 (five) business days of receiving such request, the Authority’s Engineer shall grant permission with such modifications as it may deem necessary and a copy of such permission shall be sent to the Authority.
(ii) Upon receiving the permission pursuant to Clause 14.5 (i), the Contractor shall be entitled to close the designated lane for the period specified therein, and for all lane closures extending a continuous period of 48 (forty-eight) hours, the Contractor shall, in the event of any delay in re-opening such lane, for every stretch of 250 (two hundred and fifty) metres, or part thereof, pay Damages to the Authority calculated at the rate of 0.1% (zero point one per cent) of the monthly maintenance payment for each day of delay until the lane has been re-opened for traffic. In the event of any delay in re-opening such lanes or in the event of emergency decommissioning and closure to traffic of the whole or any part of the Project Highway due to failure of the Contractor, the Contractor shall pay damages to the Authority at double the above rate, without prejudice the rights of the Authority under this Agreement including Termination thereof.
Contract Closure Contracting Officer shall give appropriate written notice to Purchaser when Purchaser has complied with the terms of this contract. Purchaser shall be paid refunds due from Timber Sale Account un- der B4.24 and excess cooperative deposits under B4.218.
Continuing Agreement (a) This Pledge Agreement shall be a continuing agreement in every respect and shall remain in full force and effect so long as any of the Secured Obligations remain outstanding (other than any such obligations which by the terms thereof are stated to survive termination of the Loan Documents and any contingent indemnity obligations that are not yet due and payable) and until all of the commitments relating thereto have been terminated. Upon such payment and termination, this Pledge Agreement shall be automatically terminated and the Administrative Agent and the holders of the Secured Obligations shall, upon the request and at the expense of the Pledgors, (i) return all certificates representing the Pledged Capital Stock, all other certificates and instruments constituting Pledged Collateral and all instruments of transfer or assignment which have been delivered to the Administrative Agent pursuant to this Pledge Agreement and (ii) forthwith release all of its liens and security interests hereunder and shall execute and deliver all UCC termination statements and/or other documents reasonably requested by the Pledgors evidencing such termination. Notwithstanding the foregoing, all releases and indemnities provided hereunder shall survive termination of this Pledge Agreement.
(b) This Pledge Agreement shall continue to be effective or be automatically reinstated, as the case may be, if at any time payment, in whole or in part, of any of the Secured Obligations is rescinded or must otherwise be restored or returned by the Administrative Agent or any holder of the Secured Obligations as a preference, fraudulent conveyance or otherwise under any bankruptcy, insolvency or similar law, all as though such payment had not been made; provided that in the event payment of all or any part of the Secured Obligations is rescinded or must be restored or returned, all reasonable costs and expenses (including without limitation any reasonable legal fees and disbursements) incurred by the Administrative Agent or any holder of the Secured Obligations in defending and enforcing such reinstatement shall be deemed to be included as a part of the Secured Obligations.
School Closure The following shall apply in the event of an NPS school closure due to an emergency consistent with guidelines followed by LEAs under Education Code Section 41422 and 46392: In the event of a NPS School Closure for the reasons set forth in Education Code section 41422, if the LEA is able to obtain alternative placement for the student, CONTRACTOR shall not receive payment for days the student is not in attendance due to CONTRACTOR’S school closure. If the LEA is unable to obtain an alternative placement, CONTRACTOR shall receive payment consistent with the student’s approved ISA, contingent upon the provision of agreed upon services consistent with the Emergency Circumstances documented in the pupil’s IEP in accordance with Education Code section 56345(a)(9). When the emergency school closure is lifted, CONTRACTOR shall notify the LEAs it serves of any lost instructional minutes. CONTRACTOR and XXXx shall work collaboratively to determine the need for make-up days or service changes, and shall work together to amend IEP and ISA paperwork as appropriate.
TIME OF COMMENCEMENT AND COMPLETION 2.1 The Contractor shall commence the Work upon the date established in the Notice to Proceed.
2.2 The Contractor shall achieve Final Completion, as defined in Section 105.01, Contract Time, Notice of Contract Execution and Notice to Proceed of the Loudoun County Revisions to the 0000 XXXX Xxxx & Bridge Specifications, Division I - General Provisions, within one hundred and eighty (180) calendar days from the date specified in the Notice to Proceed. This time period shall be designated the Contract Time. The Notice to proceed will be issued approximately than thirty (30) days after the execution of this agreement. The Contractor agrees that the time for completion of the Work as described in the Contract Documents shall govern unless specifically amended in writing by the County, and that no claims for early completion are allowed to be presented by the Contractor to the County.
2.3 The County specifies that time is of the essence under this Contract. Time being of the essence, it is essential to the County that Contract work will be completed within the Contract Time. The County and the Contractor agree that damages for failure to complete the work within the Contract Time are not susceptible to exact determination but that $600 per day is in proportion to the actual loss that the County would suffer from such delay. Therefore, the Contractor will pay the County on demand $600 per day for each and every day beyond the one hundred and eighty (180) calendar days, or modified date of completion, that the County determines that work is not complete, as damages caused by such delay and not as a penalty. The County shall be entitled to offset liquidated damages against any sum owed by the County to the Contractor under this Contract.
2.4 The amount of liquidated damages set forth in Articles 2.3 above shall be assessed cumulatively. This provision for liquidated damages does not bar County's right to enforce other rights and remedies against Contractor, which are otherwise legally enforceable, including but not limited to, specific performance or injunctive relief.
2.5 The Contractor hereby waives any defense as to the validity of any liquidated damages stated in this Agreement as they may appear on grounds that such liquidated damages are void as penalties or are not reasonably related to actual damages.
Christmas Closedown 15.1 It is agreed that whenever annual leave is taken in conjunction with the Christmas/New Year period (as per Calendar in sub-clause 2.11), it is to be taken in accordance with the following procedure.
15.2 Employees who have not accrued sufficient pro rata annual leave prior to commencement of the Christmas/New Year period, may be granted leave without pay by their Employer to give that employee at least the minimum leave of absence required.
15.3 Where the Employer decides to close a site over the Christmas/New Year period for any period in excess of the agreed minimum closedown, up to and including 20 Annual Leave days, then the Employer shall give at least 2 months’ notice to employees as per the relevant Award. Employees who have no, or insufficient, accrued annual leave equal to the period of the closure, may be granted leave without pay for that period.
15.4 Notwithstanding anything elsewhere contained in this Agreement, the Employer may require any employee to work in unforeseen or emergency circumstances during the Christmas period.
15.5 Where an employee requests that annual leave be allowed in one continuous period at Christmas, such a request shall not be unreasonably refused.
15.6 It is a breach of this Agreement and the Award for an employee to be paid his/her full accrual, or part thereof, of annual leave at Christmas or any other time, unless that employee takes such annual leave or his/her employment is terminated. Employment is not to be terminated for reasons of avoidance of this clause.
Effective Date of Agreement The provisions of the agreement will come into full force and effect on the date of ratification, unless specified otherwise.
Tax Periods Beginning Before and Ending After the Closing Date The Company or the Purchaser shall prepare or cause to be prepared and file or cause to be filed any Returns of the Company for Tax periods that begin before the Closing Date and end after the Closing Date. To the extent such Taxes are not fully reserved for in the Company’s financial statements, the Sellers shall pay to the Company an amount equal to the unreserved portion of such Taxes that relates to the portion of the Tax period ending on the Closing Date. Such payment, if any, shall be paid by the Sellers within fifteen (15) days after receipt of written notice from the Company or the Purchaser that such Taxes were paid by the Company or the Purchaser for a period beginning prior to the Closing Date. For purposes of this Section, in the case of any Taxes that are imposed on a periodic basis and are payable for a Taxable period that includes (but does not end on) the Closing Date, the portion of such Tax that relates to the portion of such Tax period ending on the Closing Date shall (i) in the case of any Taxes other than Taxes based upon or related to income or receipts, be deemed to be the amount of such Tax for the entire Tax period multiplied by a fraction the numerator of which is the number of days in the Tax period ending on the Closing Date and the denominator of which is the number of days in the entire Tax period (the “Pro Rata Amount”), and (ii) in the case of any Tax based upon or related to income or receipts, be deemed equal to the amount that would be payable if the relevant Tax period ended on the Closing Date. The Sellers shall pay to the Company with the payment of any taxes due hereunder, the Sellers’ Pro Rata Amount of the costs and expenses incurred by the Purchaser or the Company in the preparation and filing of the Tax Returns. Any net operating losses or credits relating to a Tax period that begins before and ends after the Closing Date shall be taken into account as though the relevant Tax period ended on the Closing Date. All determinations necessary to give effect to the foregoing allocations shall be made in a reasonable manner as agreed to by the parties.
Please see the current Washtenaw Community College catalog for up-to-date program requirements Conditions & Requirements