PROJECT SERVICES Landlord shall furnish services as follows:
Scope of Project i. The work to be per formed under the terms of this Agreement for the Rapid City Metropolitan Transportation Planning Process will be conducted in accordance with the CY 2019 Unified Planning Work Program incorporated in this Agreement by reference as Attachment D.
ii. The Sub-Recipient’s Responsibilities:
Payment for Project Services As full consideration for the Services to be performed by Contractor, City agrees to pay Contractor as set forth in accordance with the bid and not to exceed fee of $215,500.00 for the project. A monthly progress payment in the amount of ninety-five percent (95%) of the value of the work completed may be made every thirty (30) days upon application by the Contractor and certification by the Project Manager that such work has been completed. Partial payments will be made once each month as the work satisfactorily progresses and after acceptance by the authorized City representative. The progress estimates shall be based upon materials in place, or on the job site and invoiced, and labor expended thereon. From the total of the amount ascertained will be deducted an amount equivalent to five percent (5%) of the whole, which five percent (5%) will be retained by the City until after completion of the entire Contract in an acceptable manner. Any time after fifty percent (50%) of the value of the work has been completed, the City will make any of the remaining partial payments in full. No such estimates or payments shall be required to be made, when, in the judgment of the City Project Manager, the work is not proceeding in accordance with the provision of the Contract, or when in his judgment the total value of the work done since last estimate amounts to less than Five Hundred Dollars ($500.00). The cost of materials conforming to the plans and specifications (materials being those which are required to be contained and incorporated in a finished contract bid item) delivered to the project and not at the time incorporated in the work, may also be included in the estimate for payment. No such estimate or payment shall be construed to be an acceptance of any defective work or improper material. The Contractor shall be responsible for, and shall not remove from the project any material that has been included in the estimate for payment. Final payment shall be made upon the Project Manager certifying that the Contractor has satisfactorily completed the work in conformity with the Contract Documents.
Scope of the Services UNOPS intends to retain the Contractor for the implementation of the Services, and the Contractor intends to provide the Services. The Contractor has represented to UNOPS that it has the appropriate experience, expertise, licences, and resources to undertake the Services and has agreed to undertake the Services in accordance with the Contract. In reliance on the Contractor’s representations UNOPS has entered into the Contract. The Contract sets out the terms and conditions upon which the Contractor will undertake the Services.
Scope of Professional Services 3.1 On the terms and conditions set forth in this Agreement, COUNTY hereby engages CONTRACTOR to provide all labor, materials and equipment to complete the Project/Service in accordance with the Scope of Services, attached hereto and incorporated herein as Attachment A, as modified or clarified by Addendum(s) # , dated , attached hereto and incorporated herein by reference as Attachment B. It is understood that the Scope of Services may be modified by change order as the Project/Service progresses, but to be effective and binding, any such change order must be in writing, executed by the parties, and in accordance with the COUNTY’s Purchasing Policies and Procedures. A copy of these policies and procedures shall be made available to the CONTRACTOR upon request.
3.2 The term of this Agreement shall be as follows (please check box): The parties acknowledge that this is a project specific agreement and that the single Project/Service shall be completed by the CONTRACTOR within ( ) calendar days after the Notice to Proceed is issued. The CONTRACTOR and COUNTY acknowledge that this Agreement is for a twelve (12) month term and that the CONTRACTOR shall complete the work as specified in the Scope of Services. The COUNTY has the option to renewal this Agreement for four (4) additional one (1) year period(s). The prices set forth in this Agreement shall prevail for the full duration of the initial contract term unless otherwise indicated elsewhere in this document. Prior to completion of each exercised contract term, the COUNTY may consider an adjustment to price based on changes in the following pricing index: CPI. It is the CONTRACTOR’s responsibility to request any pricing adjustment in writing under this provision. The CONTRACTOR’s written request for adjustment should be submitted thirty (30) calendar days prior to expiration of the then current contract term and clearly substantiate the requested increase. The written request for adjustment should not be in excess of the relevant pricing index change. If no adjustment request is received from the CONTRACTOR, the COUNTY will assume that the CONTRACTOR has agreed that the optional term may be exercised without pricing adjustment. Any adjustment request received after the commencement of a new option period shall not be considered. The COUNTY reserves the right to reject any written price adjustments submitted by the CONTRACTOR and/or to not exercise any otherwise available option period based on such price adjustments. Continuation of the contract beyond the initial period, and any option subsequently exercised, is a COUNTY’s prerogative, and not a right of the CONTRACTOR. This prerogative will be exercised only when such continuation is clearly in the best interest of the COUNTY. All work shall be performed in accordance with good commercial practice. The work schedule and completion dates shall be adhered to by the CONTRACTOR except in such cases where the completion date will be delayed due to acts of God, strikes, or other causes beyond the control of the CONTRACTOR. In these cases, the CONTRACTOR shall notify the COUNTY of the delays in advance of the original completion so that a revised delivery schedule can be appropriately considered by the COUNTY. No additional days shall be granted for rain delays.
3.3 The CONTRACTOR shall be solely responsible for obtaining all necessary approvals and permits to complete the Project/Service.
3.4 The CONTRACTOR shall remain appropriately licensed and/or employ the services of a subcontractor who is appropriately licensed throughout the course of the Project/Service. Failure to maintain all required licenses shall entitle the COUNTY, at its option, to terminate this Agreement.
3.5 Although this Agreement identifies specific facilities to be serviced, it is hereby agreed and understood that any County department or agency facility may be added to this Agreement at the option of the County. When required by the pricing structure of the Agreement, the CONTRACTOR shall be invited to submit price quotes for these additional facilities. The additional site(s) shall be added to this Agreement by formal modification. The COUNTY may obtain price quotes for the additional facilities from other vendors in the event that fair and reasonable pricing is not obtained from the CONTRACTOR or for other reasons at the County’s discretion. Although this Agreement identifies specific facilities to be serviced, it is hereby agreed and understood that any County department or agency may delete service for any facility when such service is no longer required, upon fourteen (14) calendar days written notice.
3.6 The CONTRACTOR acknowledges that it has sufficient understanding of the nature and location of the work; the general and local conditions, including but not limited to, those bearing upon transportation, disposal, handling and storage of materials; availability of labor, water, electric power, and roads; and uncertainties of weather or similar physical conditions at the site; the character of equipment and facilities needed preliminary to and during the completion of the Project/Service. The CONTRACTOR further acknowledges that the CONTRACTOR has satisfied itself as to the character, quality and quantity of surface and subsurface materials, obstacles or conditions of the site. Any failure by the CONTRACTOR to acquaint itself with any aspect of the work or with any of the applicable conditions shall not relieve the CONTRACTOR from responsibility for adequately evaluating the difficulty or cost of successfully performing the work required, nor shall it be considered a basis for any claim for additional time or compensation. The COUNTY assumes no responsibility for any conclusions or interpretations made by the CONTRACTOR on the basis of the information made available by the COUNTY. The COUNTY also assumes no responsibility for any understanding or representations made by its officers or agents during or prior to the execution of this contract, unless such understanding or interpretations are made in writing and incorporated herein by reference.
3.7 If required, the Contractors shall attend a mandatory pre-bid meeting. Whether or not there is a mandatory or non-mandatory pre-bid, the contractor shall be required to carefully examine any supplied drawings and/or specifications and be thoroughly aware regarding any and all conditions that may in any manner affect the work to be performed under the contract. If a pre-bid meeting is not required the Contractor shall visit the site to familiarize themselves with the Project/Service, see existing conditions, and take measurements. No additional allowances will be made for lack of knowledge of these conditions.
3.8 In the event of any conflict between the drawings and specifications contained within this Agreement, the following shall govern:
A. Addenda shall supersede all other contract documents to the extent specified in the addenda. Subsequent addenda shall supersede prior to addenda only to the extent specified therein.
B. Drawings and specifications are intended to agree and be mutually complete. Any item not contained within the drawings, but contained in the specifications, or vice-versa, shall be provided and/or executed as shown in either the drawing or specification at no extra costs to the COUNTY. Should anything not included in either the drawing and/or the specifications be necessary for the proper construction and/or operation of the Project/Service as herein specified, or should any error or disagreement between the specifications and drawings exist or appear to exist, the CONTRACTOR shall not derive unjust benefit thereby, or use such disagreement counter to the best interests of the COUNTY. The CONTRACTOR shall immediately notify the COUNTY’s Project Manager of any discrepancy and await the Project Manager’s direction before proceeding with the work in question.
3.9 CONTRACTOR acknowledges and agrees that CONTRACTOR shall utilize the U.S. Department of Homeland Security’s E-Verify system in accordance with the terms governing use of the system to confirm the employment eligibility of:
A. All persons employed by the CONTRACTOR during the term of this Agreement to perform employment duties within Lake County; and
B. All persons, including subcontractors, assigned by the CONTRACTOR to perform work pursuant to the contract.
3.10 CONTRACTOR acknowledges and agrees that, in accordance with Section 255.099, Florida Statutes, if the Project/Service assigned to CONTRACTOR is being supported in whole or in part by State funding the CONTRACTOR shall give preference to the employment of state residents in the performance of the work on the Project/Service if state residents have substantially equal qualifications to those of non- residents. If the CONTRACTOR is required to employ state residents, the CONTRACTOR shall contact the Department of Economic Opportunity to post the employment needs in the State’s job bank system. However, in work involving the expenditure of federal aid funds, this section may not be enforced in such a manner as to conflict with or be contrary to federal law prescribing a labor preference to honorably discharged soldiers, sailors, or marines, or prohibiting as unlawful any other preference or discrimination among the citizens of the United States.
Scope of Processing The subject-matter of Processing of Personal Data by Okta is the performance of the Service pursuant to the Agreement. The duration of the Processing, the nature and purpose of the Processing, the types of Personal Data and categories of Data Subjects Processed under this DPA are further specified in Appendix 1 to this DPA.
Out of Scope Services Axon is only responsible to perform the professional services described in the Quote and this Appendix. Any additional professional services are out of scope. The Parties must document scope changes in a written and signed change order. Changes may require an equitable adjustment in the charges or schedule.
Engineering Services Definition: Engineering Services includes any service or creative work, the adequate performance of which requires education, training and experience in the application of special knowledge in consulting, investigating, evaluating, planning and designing, engineering principles. Engineering Services covered by the Xxxxxx Architect-Engineers Act (40 U.S.C. 1102) are not covered in the primary scope of OASIS SB. Examples: Service areas that are included under the Engineering Services discipline include, but are not limited to the following:
1. Systems Engineering
2. Advanced Technology Pilots and Trials
3. Alternative Energy Sources and Engineering
4. Configuration Management 5. Concept Development
OVERSIGHT SERVICES Oversight services for the Fund provided by Price Associates shall include all oversight of BNY Mellon, Delegates and service providers that provide accounting, administrative, and tax support services and not specifically provided for under each Fund’s Investment Management Agreement. Price Associates provides all accounting, administrative, tax and oversight services to the Funds listed on Exhibit A2, including the below. Accounting Services provided by Price Associates shall include, among other things: · oversight of quality control, including processing results related to fund accounting services provided by Delegates or other third party service providers relating to pricing. Such oversight includes, but is not limited to, review of (a) NAV calculations and fund valuations, (b) securities pricing and resolution of pricing exceptions, and (c) calculation and preparation of any financial information or schedules; · end-of-day INAV oversight for ETFs that provide INAV · determining accounting and valuation policies, instructing Delegates and/or other service providers, and/or providing it with such advice that may be reasonably necessary, to properly account for all financial transactions and to maintain the Fund’s accounting procedures and records so as to ensure compliance with generally accepted accounting principles and tax practices and rules; and · calculating and authorizing expense accruals and payments; annual fund expense budgets; accrual analysis; rollforward calculations; payment of expenses; fees for payment to service providers; · facilitating on behalf of the Fund resolution and remediation of fund accounting issues escalated by Delegates and/or other service providers; · preparing daily NAV calculations, including all necessary component services such as valuation and particularly private company investment valuation, corporate actions processing, trade processing, and performing month-end and fiscal-period-end close processes; · recordkeeping as required; and · such other accounting services as agreed to by the parties not otherwise performed by Price Associates under the Investment Management Agreement. Administrative Services provided by Price Associates shall include, among other things: · ensuring maintenance for the Fund of all records that may be reasonably required in connection with the audit performed by the Fund’s independent registered public accountants, or by the Securities and Exchange Commission (“SEC”), the Internal Revenue Service (“IRS”) or such other Federal or state regulatory agencies; · cooperating with the Fund’s independent registered public accountants and taking all reasonable action in the performance of its obligations under the Agreement to assure that the necessary information is made available to such accountants for the expression of their opinion without any qualification as to the scope of their examination including, but not limited to, their opinion included in the Fund’s annual report on Form N-CSR and annual amendment to Form N-1A; · implementing and maintaining the systems, data storage and reporting necessary to perform services outlined herein; · all efforts concerning financial reporting services, including shareholder reports and financial information in regulatory filings; N-PORT and N-CEN; and other financial reporting services as necessary; · determining financial reporting policies, maintaining adequate controls over financial reporting to provide complete and accurate financial information and disclosures that are certified by officers of the Funds. Providing sub-certifications, as requested by officers of the Funds, for the adequacy of such controls and the completeness and accuracy of information included in Form N-CSR or any other form that may require certification; · periodic testing of Internal Revenue Code qualification requirements; · prepare and furnish fund performance information; · prepare and disseminate vendor survey information; · prepare and file Rule 24f-2 notices and payment; and · such other administrative services as agreed to by the parties, not otherwise performed by Price Associates under the Investment Management Agreement.
Financial Planning Services The Executive shall receive financial planning services, on an in-kind basis, for a period of eighteen (18) months following the Date of Termination. Such financial planning services shall include expert financial and legal resources to assist the Executive with financial planning needs and shall be limited to (i) current investment portfolio management, (ii) tax planning, (iii) tax return preparation, and (iv) estate planning advice and document preparation (including xxxxx and trusts); provided, however, that the Company shall provide such financial planning services during any taxable year of the Executive only to the extent the cost to the Company for such taxable year does not exceed $25,000. The Company shall provide such financial planning services through a financial planner selected by the Company, and shall pay the fees for such financial planning services. The financial planning services provided during any taxable year of the Executive shall not affect the financial planning services provided in any other taxable year of the Executive. The Executive’s right to financial planning services shall not be subject to liquidation or exchange for any other benefit. Such financial planning services shall be provided in a manner that complies with Treasury Regulation Section 1.409A-3(i)(1)(iv).
