STAGE ONE AND STAGE TWO STATEMENTS Sample Clauses

STAGE ONE AND STAGE TWO STATEMENTS. (a) Stage One Statement of Geotechnical Engineer: I, the undersigned registered geotechnical engineer, have made a visual inspection and subsurface investigation at the project site and, based upon my analysis of (i) soil and test borings, (ii) geophysical observations and testing, (iii) surveys, and (iv) electrical resistivity tests made as I deemed necessary in my professional judgment to be suitable or advisable to the end that all subsurface conditions that might necessitate redesign or Change Orders during construction if not taken into consideration in the design of the work or provided for in the Bidding Documents, I find that:
Sample 1Sample 2Sample 3See All (42)
AutoNDA by SimpleDocs
STAGE ONE AND STAGE TWO STATEMENTS. (a) Stage One Statement of Geotechnical Engineer: I, the undersigned registered geotechnical engineer, have made a visual inspection and subsurface investigation at the project site and, based upon my analysis of (i) soil and test borings,
Sample 1Sample 2

Related to STAGE ONE AND STAGE TWO STATEMENTS

  • Completion Dates The Recipient agrees to complete each Project within the time periods specified in the Underlying Agreement and all activities must be completed by the Award’s end date, unless FTA agrees in writing to extend the end date. Unless FTA determines otherwise in writing, interim milestone dates and other completion dates applicable to the Award are good faith estimates and are not intended to be firm contractual requirements. However, FTA and the Recipient agree that milestone dates and other completion dates for Full Funding Grant Agreements, Small Starts Grant Agreements or other specific agreements in which FTA expressly states that the milestone dates or other completion dates for the Underlying Agreement are firm dates that may be enforced.

  • Project Completion The Contractor agrees to schedule a final job walk with the County. If required, the County will prepare a list of incomplete items, the “Punch List”. The Contractor agrees to complete the “Punch List” corrections and schedule a final project completion job walk. The County will sign the “Punch List” as completed when determined, the project is finished. The Contractor agrees to submit the following along with its final payment request:

Time is Money Join Law Insider Premium to draft better contracts faster.