Security Procedures The Fund shall comply with data access operating standards and procedures and with user identification or other password control requirements and other security procedures as may be issued from time to time by State Street for use of the System on a remote basis and to access the Data Access Services. The Fund shall have access only to the Fund Data and authorized transactions agreed upon from time to time by State Street and, upon notice from State Street, the Fund shall discontinue remote use of the System and access to Data Access Services for any security reasons cited by State Street; provided, that, in such event, State Street shall, for a period not less than 180 days (or such other shorter period specified by the Fund) after such discontinuance, assume responsibility to provide accounting services under the terms of the Custodian Agreement.
Security Procedure The Client acknowledges that the Security Procedure it has designated on the Selection Form was selected by the Client from Security Procedures offered by State Street. The Client agrees that the Security Procedures are reasonable and adequate for its wire transfer transactions and agrees to be bound by any payment orders, amendments and cancellations, whether or not authorized, issued in its name and accepted by State Street after being confirmed by any of the selected Security Procedures. The Client also agrees to be bound by any other valid and authorized payment order accepted by State Street. The Client shall restrict access to confidential information relating to the Security Procedure to authorized persons as communicated in writing to State Street. The Client must notify State Street immediately if it has reason to believe unauthorized persons may have obtained access to such information or of any change in the Client’s authorized personnel. State Street shall verify the authenticity of all instructions according to the Security Procedure.
Security Protocols Both parties agree to maintain security protocols that meet industry standards in the transfer or transmission of any data, including ensuring that data may only be viewed or accessed by parties legally allowed to do so. Provider shall maintain all data obtained or generated pursuant to the Service Agreement in a secure digital environment and not copy, reproduce, or transmit data obtained pursuant to the Service Agreement, except as necessary to fulfill the purpose of data requests by LEA.
Safety and Security Procedures Contractor shall maintain and enforce, at the Contractor Work Locations, industry-standard safety and physical security policies and procedures. While at each Court Work Location, Contractor shall comply with the safety and security policies and procedures in effect at such Court Work Location.
Safety Procedures The Contractor shall:
(a) comply with all applicable safety regulations according to Attachment H;
(b) take care for the safety of all persons entitled to be on the Site;
(c) use reasonable efforts to keep the Site and Works clear of unnecessary obstruction so as to avoid danger to these persons;
(d) provide fencing, lighting, guarding and watching of the Works until completion and taking over under clause 10 [Employer's Taking Over]; and
(e) provide any Temporary Works (including roadways, footways, guards and fences) which may be necessary, because of the execution of the Works, for the use and protection of the public and of owners and occupiers of adjacent land.
Security Program Contractor will develop and implement an effective security program for the Project Site, which program shall require the Contractor and subcontractors to take measures for the protection of their tools, materials, equipment, and structures. As between Contractor and Owner, Contractor shall be solely responsible for security against theft of and damage of all tools and equipment of every kind and nature and used in connection with the Work, regardless of by whom owned.
WARRANTY PROCEDURES You need proof of purchase for warranty service.
Procurement procedures 11.1 The Recipient must secure the best value for money and shall act in a fair, open and non-discriminatory manner in all purchases of goods and services.
Other Procurement Procedures National Competitive Bidding
Indemnity Procedures Promptly after receipt by an Indemnified Party of any claim or notice of the commencement of any action or administrative or legal proceeding or investigation as to which the indemnity provided for in Article 18.1 may apply, the Indemnified Party shall notify the Indemnifying Party of such fact. Any failure of or delay in such notification shall not affect a Party’s indemnification obligation unless such failure or delay is materially prejudicial to the Indemnifying Party. Except as stated below, the Indemnifying Party shall have the right to assume the defense thereof with counsel designated by such Indemnifying Party and reasonably satisfactory to the Indemnified Party. If the defendants in any such action include one or more Indemnified Parties and the Indemnifying Party and if the Indemnified Party reasonably concludes that there may be legal defenses available to it and/or other Indemnified Parties which are different from or additional to those available to the Indemnifying Party, the Indemnified Party shall have the right to select separate counsel to assert such legal defenses and to otherwise participate in the defense of such action on its own behalf. In such instances, the Indemnifying Party shall only be required to pay the fees and expenses of one additional attorney to represent an Indemnified Party or Indemnified Parties having such differing or additional legal defenses. The Indemnified Party shall be entitled, at its expense, to participate in any such action, suit or proceeding, the defense of which has been assumed by the Indemnifying Party. Notwithstanding the foregoing, the Indemnifying Party (i) shall not be entitled to assume and control the defense of any such action, suit or proceedings if and to the extent that, in the opinion of the Indemnified Party and its counsel, such action, suit or proceeding involves the potential imposition of criminal liability on the Indemnified Party, or there exists a conflict or adversity of interest between the Indemnified Party and the Indemnifying Party, in such event the Indemnifying Party shall pay the reasonable expenses of the Indemnified Party, and (ii) shall not settle or consent to the entry of any judgment in any action, suit or proceeding without the consent of the Indemnified Party, which shall not be unreasonably withheld, conditioned or delayed.
