Sub Project Leader Sample Clauses

Sub Project Leader. The Sub Project Leader of each Sub Project is appointed by the General Assembly. The Sub Project Leader shall have the following functions only: (a) communicating any plans, deliverables, documents and information connected with the Sub Project between its Members and, if relevant, to the Executive Board (b) submitting the implementation plan of the Sub Project to the Executive Board for review and proposing an update of the Consortium Plan. (c) coordinating on a day-to-day basis the progress of the technical work under the Sub Project (d) following up decisions made by Consortium Bodies insofar as they affect the Sub Project (e) advising the Coordinator of any discrepancy with the Consortium Plan, including any delay in delivery. Including communicating changes of tasks and/or budget within the Sub Project, delivery of Minutes, etc. Discrepancies can be e.g. delays in delivery, overspending or underspending, etc. In such cases it is the task of the Sub Project Committee to cure inside its possibilities and alert the Executive Board.
Sample 1
AutoNDA by SimpleDocs
Sub Project Leader. The Sub Project Management Team shall elect a Sub Project Leader. The Sub Project Leader shall have the following functions only: i. administration, preparation of minutes and provision of the chairman of the Sub-Project Management Team, and follow-up of its decisions; ii. transmission of any documents and information connected with the Sub- Project to the Contractors concerned; iii. transmission of any documents and information connected with the Sub– Project to the Co-ordinator; iv. transmission of the Project deliverables of the Contractors within the Sub- Project to the Co-ordinator; v. co-ordinating on a day-to-day basis the progress of the technical work under the Sub Project; vi. for the purpose of Article 6.4, reviewing deliverables at each agreed step under the Project Plan for the Sub-Project concerned and advise the Co- ordinator of any delay in delivery that could not be remedied or any major discrepancy. The Sub Project Leader shall neither be entitled to act or to make legally binding declarations on behalf of any other Contractor nor to enlarge its role beyond the one described herein.
Sample 1
Sub Project Leader. The Sub Project Leader of each Sub Project is appointed by the General Assembly. The Sub Project Leader shall have the following functions only: - communicating any plans, deliverables, documents and information connected with the Sub Project between its members and, if relevant, to the Executive Board - submitting the implementation plan of the Sub Project to the Executive Board for review and proposing an update of the Consortium Plan. - coordinating on a day-to-day basis the progress of the technical work under the Sub Project - following up decisions made by Consortium Bodies insofar as they affect the Sub Project - advising the Coordinator of any discrepancy with the Consortium Plan, including any delay in delivery. Including communicating changes of tasks and/or budget within the sub project, delivery of minutes, etc. Discrepancies can be e.g. delays in delivery, overspending or underspending, etc. In such cases it is the task of the Sub Project Committee to cure inside its possibilities and alert the Executive Board. 6.4 Coordinator 6.4
Sample 1

Related to Sub Project Leader

  • County’s Project Manager Note: The written approval of substituted A-E Key Personnel is for departmental use only and shall not be used for auditing purposes outside OC Public Works or other County department.

  • Project Manager The term “Project Manager” refers to the employee of the State who has been assigned responsibility for overseeing and managing the proper and timely implementation of the project.

  • Project Coordinator Within 14 days of the effective date of this Consent Agreement, DTSC and Respondent shall each designate a Project Coordinator and shall notify each other in writing of the Project Coordinator selected. Each Project Coordinator shall be responsible for overseeing the implementation of this Consent Agreement and for designating a person to act in his/her absence. All communications between Respondent and DTSC, and all documents, report approvals, and other correspondence concerning the activities performed pursuant to this Consent Agreement shall be directed through the Project Coordinators. Each party may change its Project Coordinator with at least seven days prior written notice.

  • Project Team To accomplish Owner’s objectives, Owner intends to employ a team concept in connection with the construction of the Project. The basic roles and general responsibilities of team members are set forth in general terms below but are more fully set forth in the Design Professional Contract with respect to the Design Professional, in the Program Management Agreement with any Program Manager, and in this Contract with respect to the Contractor.

  • Contractor’s Project Manager 7.2.1 The Contractor’s Project Manager is designated in Exhibit F (Contractor’s Administration). The Contractor shall notify the County in writing of any change in the name or address of the Contractor’s Project Manager. 7.2.2 The Contractor’s Project Manager shall be responsible for the Contractor’s day-to-day activities as related to this Contract and shall meet and coordinate with County’s Project Manager and County’s Contract Project Monitor on a regular basis.

  • Contractor Project Manager The Contractor Project Manager shall serve, from the Effective Date, as the Contractor project manager and primary Contractor representative under this Agreement. The Contractor Project Manager shall (i) have overall responsibility for managing and coordinating the performance of Contractor’s obligations under this Agreement, including the performance of all Subcontractors; and (ii) be authorized to act for and bind Contractor and Subcontractors in connection with all aspects of this Agreement. The Contractor Project Manager shall respond promptly and fully to all inquiries from the JBE Project Manager.

  • Project Managers The JBE’s project manager is: [Insert name]. The JBE may change its project manager at any time upon notice to Contractor without need for an amendment to this Agreement. Contractor’s project manager is: [Insert name]. Subject to written approval by the JBE, Contractor may change its project manager without need for an amendment to this Agreement.

  • Project Steering Committee 1. For a sound implementation and management of the project, a steering committee shall be set up in line with provisions of the programme manual. 2. The steering committee is the decision-making body of the project and it shall be composed by representatives of the LP and all PPs duly authorised to represent the respective LP and PP institutions. It shall be chaired by the LP and it shall meet on a regular basis. Associated partners shall be invited to take part in the steering committee in an advisory capacity. External key stakeholders may also be invited to take part to one or more meetings in an observer/advisory capacity. 3. The steering committee shall at least: a. be responsible for monitoring and validating the implementation of the project and the achievement of the planned results as in the approved application form; b. perform the financial monitoring of the project implementation and to decide on any budget modifications as in § 11 of this agreement; c. monitor and manage deviations of the project implementation; d. decide on project modifications (e.g. partnership, budget, activities, and duration) if needed; e. be responsible for the settlement of any disputes within the partnership (as stipulated in § 22 of this agreement). 4. Further aspects, including the creation of sub-groups or task forces, may be set out in the rules of procedure of the steering committee.

  • Project Director The individual designated by the juvenile board or Chief Administrative Officer, who is to be responsible for the administration and coordination of grant funds in accordance with this Contract ,, the general grant requirements, and applicable Targeted Grant requirements.

  • County Project Manager The County shall appoint a Project Manager to act as liaison with Contractor during the term of this Contract. The County’s Project Manager shall coordinate the activities of the County staff assigned to work with the Contractor.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!