Substitution of Key Personnel Consultant has represented to City that certain key personnel will perform and coordinate the Services under this Agreement. Should one or more of such personnel become unavailable, Consultant may substitute other personnel of at least equal competence upon written approval of City. In the event that City and Consultant cannot agree as to the substitution of key personnel, City shall be entitled to terminate this Agreement for cause. As discussed below, any personnel who fail or refuse to perform the Services in a manner acceptable to the City, or who are determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project or a threat to the safety of persons or property, shall be promptly removed from the Project by the Consultant at the request of the City. The key personnel for performance of this Agreement are as follows: Xxxxx Xxxxx.
Support Staff The College shall designate a clerical person on each campus whose primary responsibility will be to perform clerical duties related to workload assignments for Employees. Faculty assignments to the clerical person shall be given priority over non- faculty assignments. Any conflicts shall be reported to the Chief Academic Officer or to an academic officer of the College who holds the rank of Campus Director or higher. Employees will be notified of the identity of this person and the clerical person will be notified.
Pricing Instrument; Execution and Incorporation of Terms The parties hereto will enter into this Indenture by executing the Pricing Instrument. By executing the Pricing Instrument, the Indenture Trustee, the Registrar, the Transfer Agent, the Paying Agent, the Calculation Agent and the Trust hereby agree that the Indenture will constitute a legal, valid and binding agreement between the Indenture Trustee, the Registrar, the Transfer Agent, the Paying Agent, the Calculation Agent and the Trust. All terms relating to the Trust or the Notes not otherwise included herein will be as specified in the Pricing Instrument or Pricing Supplement, as indicated herein.
Term of Agreement; Resignation and Removal of Administrator This Agreement shall continue in force until the dissolution of the Issuing Entity, upon which event this Agreement shall automatically terminate.
(a) Subject to Sections 8(d) and 8(e), the Administrator may resign its duties hereunder by providing the Issuing Entity and the Indenture Trustee with at least 60 days’ prior written notice.
(b) Subject to Sections 8(d) and 8(e), the Issuing Entity may remove the Administrator without cause by providing the Administrator with at least 60 days’ prior written notice.
(c) Subject to Sections 8(d) and 8(e), at the sole option of the Issuing Entity, the Administrator may be removed immediately upon written notice of termination from the Issuing Entity to the Administrator if any of the following events shall occur:
(i) the Administrator shall default in the performance of any of its duties under this Agreement and, after notice of such default, shall not cure such default within 30 days (or, if such default cannot be cured in such time, shall not give within ten days such assurance of cure as shall be reasonably satisfactory to the Issuing Entity);
(ii) a court having jurisdiction in the premises shall enter a decree or order for relief, and such decree or order shall not have been vacated within 60 days, in respect of the Administrator in any involuntary case under any applicable bankruptcy, insolvency or other similar law now or hereafter in effect or appoint a receiver, liquidator, assignee, custodian, trustee, sequestrator or similar official for the Administrator or any substantial part of its property or order the winding-up or liquidation of its affairs; or
(iii) the Administrator shall commence a voluntary case under any applicable bankruptcy, insolvency or other similar law now or hereafter in effect, shall consent to the entry of an order for relief in an involuntary case under any such law, or shall consent to the appointment of a receiver, liquidator, assignee, trustee, custodian, sequestrator or similar official for the Administrator or any substantial part of its property, shall consent to the taking of possession by any such official of any substantial part of its property, shall make any general assignment for the benefit of creditors or shall fail generally to pay its debts as they become due. The Administrator agrees that if any of the events specified in clauses (ii) or (iii) above shall occur, it shall give written notice thereof to the Issuing Entity and the Indenture Trustee within seven days after the occurrence of such event.
(d) No resignation or removal of the Administrator pursuant to this Section shall be effective until (i) a successor Administrator acceptable to the Indenture Trustee and the Owner Trustee shall have been appointed by the Issuing Entity with the consent of the Owner Trustee and (ii) such successor Administrator shall have agreed in writing to be bound by the terms of this Agreement in the same manner as the Administrator is bound hereunder.
(e) The appointment of any successor Administrator shall be effective only after satisfaction of the Rating Agency Condition with respect to the proposed appointment.
Term of Agreement; Resignation and Removal of the Administrator (a) This Agreement shall continue in force until the dissolution of the Issuing Entity, upon which event this Agreement shall automatically terminate.
(b) Subject to Section 8(e), the Administrator may resign its duties hereunder by providing the Issuing Entity, the Trustee, the Indenture Trustee and the Servicer with at least 60 days’ prior written notice.
(c) Subject to Section 8(e), the Issuing Entity may remove the Administrator without cause by providing the Administrator, the Trustee, the Indenture Trustee and the Servicer with at least 60 days’ prior written notice.
(d) Subject to Section 8(e), at the sole option of the Issuing Entity, the Administrator may be removed immediately upon written notice of termination from the Issuing Entity to the Administrator, the Trustee, the Indenture Trustee and the Servicer if any of the following events shall occur:
(i) the Administrator shall default in the performance of any of its duties under this Agreement and, after notice of such default, shall not cure such default within ten days (or, if such default cannot be cured in such time, shall not give within ten days such assurance of cure as shall be reasonably satisfactory to the Issuing Entity);
(ii) a court having jurisdiction in the premises shall enter a decree or order for relief, and such decree or order shall not have been vacated within 60 days, in respect of the Administrator in any involuntary case under any applicable bankruptcy, insolvency or other similar law now or hereafter in effect or appoint a receiver, liquidator, assignee, custodian, trustee, sequestrator or similar official for the Administrator or any substantial part of its property or order the winding-up or liquidation of its affairs; or
(iii) the Administrator shall commence a voluntary case under any applicable bankruptcy, insolvency or other similar law now or hereafter in effect, shall consent to the entry of an order for relief in an involuntary case under any such law, or shall consent to the appointment of a receiver, liquidator, assignee, trustee, custodian, sequestrator or similar official for the Administrator or any substantial part of its property, shall consent to the taking of possession by any such official of any substantial part of its property, shall make any general assignment for the benefit of creditors or shall fail generally to pay its debts as they become due. The Administrator agrees that if any of the events specified in clauses (ii) or (iii) of this subsection shall occur, it shall give written notice thereof to the Issuing Entity, the Servicer, the Trustee and the Indenture Trustee within seven days after the happening of such event.
(e) Upon the Administrator’s receipt of notice of termination, pursuant to Sections 8(c) or (d), or the Administrator’s resignation in accordance with this Agreement, the predecessor Administrator shall continue to perform its functions as Administrator under this Agreement, in the case of termination, only until the date specified in such termination notice or, if no such date is specified in a notice of termination, until receipt of such notice and, in the case of resignation, until the later of: (x) the date 45 days from the delivery to the Issuing Entity, the Trustee, the Indenture Trustee and the Servicer of written notice of such resignation (or written confirmation of such notice) in accordance with this Agreement and (y) the date upon which the predecessor Administrator shall become unable to act as Administrator, as specified in the notice of resignation and accompanying Opinion of Counsel. In the event of the Administrator’s termination hereunder, the Issuing Entity shall appoint a successor Administrator acceptable to the Indenture Trustee, and the successor Administrator shall accept its appointment by a written assumption in form acceptable to the Indenture Trustee. In the event that a successor Administrator has not been appointed at the time when the predecessor Administrator has ceased to act as Administrator in accordance with this Section, and if the predecessor Administrator is currently serving as the Servicer under the Transaction Documents, the Indenture Trustee without further action shall automatically be appointed the successor Administrator and the Indenture Trustee shall be entitled to the compensation specified in Section 3. Notwithstanding the above, the Indenture Trustee shall, if it shall be unable so to act, appoint or petition a court of competent jurisdiction to appoint any established institution having a net worth of not less than $50,000,000 and whose regular business shall include the performance of functions similar to those of the Administrator, as the successor to the Administrator under this Agreement.
(f) Upon appointment, the successor Administrator (including the Indenture Trustee acting as successor Administrator) shall be the successor in all respects to the predecessor Administrator and shall be subject to all the responsibilities, duties and liabilities arising thereafter relating thereto placed on the predecessor Administrator and shall be entitled to the compensation specified in Section 3 and all the rights granted to the predecessor Administrator by the terms and provisions of this Agreement.
(g) Except when and if the Indenture Trustee is appointed successor Administrator, the Administrator may not resign unless it is prohibited from serving as such by law as evidenced by an Opinion of Counsel to such effect delivered to the Indenture Trustee. No resignation or removal of the Administrator pursuant to this Section shall be effective until: (i) a successor Administrator shall have been appointed by the Issuing Entity and (ii) such successor Administrator shall have agreed in writing to be bound by the terms of this Agreement in the same manner as the Administrator is bound hereunder.
(h) The appointment of any successor Administrator shall be effective only after satisfaction of the Rating Agency Condition with respect to the proposed appointment.
Replacement of Key Personnel The Engineer must notify the State in writing as soon as possible, but no later than three business days after a project manager or other key personnel is removed from association with this contract, giving the reason for removal.
Uncovering and Correction of Work 12.1 The Contractor shall promptly correct Work rejected by the Owner or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed, and shall correct any Work found to be not in accordance with the requirements of the Contract Documents within a period of two years from the date of Substantial Completion, or by terms of an applicable special warranty required by the Contract Documents. The provisions of this Article apply to work done by Subcontractors as well as to Work done by direct employees of the Contractor.
12.2 At any time during the progress of the work, or in any case where the nature of the defects shall be such that it is not expedient to have them corrected, the Owner, at their option, shall have the right to deduct such sum, or sums, of money from the amount of the contract as they consider justified to adjust the difference in value between the defective work and that required under contract including any damage to the structure.
Office and Support Staff During the Employment Period, the Executive shall be entitled to an office or offices of a size and with furnishings and other appointments, and to exclusive personal secretarial and other assistance, at least equal to the most favorable of the foregoing provided to the Executive by the Company and its affiliated companies at any time during the 120-day period immediately preceding the Effective Date or, if more favorable to the Executive, as provided generally at any time thereafter with respect to other peer executives of the Company and its affiliated companies.
Assistance by COUNTY STAFF 1.3.1. County shall assign an appropriate staff member to work with A-E in connection with the work of this Contract. Said staff member's duties will consist of the giving of advice and consultations, assisting A-E in negotiations with other public agencies and private parties, miscellaneous items which in the judgment of A-E or County's staff warrant attention, and all other duties as may be described in Attachment A.
1.3.2. All of the above activities, however, shall be the primary responsibility of A-E to schedule, initiate and carry through to completion.
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
