Suspension Due to Breach. Network Solutions, in its sole and exclusive discretion, may immediately take corrective action, including, but not limited to, removal of all or a portion of the Content on your Website and suspension and/or termination of your Hosting Services, in the event of notice of any possible violation of this Agreement or the AUP by you or your end users. You agree that Network Solutions will have no liability to you due to any corrective action that Network Solutions may take and that you will not be entitled to a refund of any fees paid in advance prior to the corrective action. You agree to the additional restrictions of use provided by Network Solutions in conjunction with the Hosting Services that are found in other schedules to this Agreement.
Suspension Due to Breach. In the event AOC determines that a breach of Contract has occurred in Contractor’s (including without limitation any Subcontractor’s) compliance with the conditions of this Contract or if AOC have reason to believe that fraud, abuse, malfeasance, misfeasance or nonfeasance has occurred on the part of Contractor under this Contract, and the situation is deemed by AOC to merit corrective action, the following sequential suspension procedure may be implemented by AOC:
15.7.1 AOC Project Director will give Notice to Contractor of a perceived compliance breach describing AOC’s concerns.
15.7.2 Contractor will respond to AOC Project Director’s concerns by letter describing proposed corrective actions and proposing completion dates for bringing the Contract into compliance. Such response will be sent in accordance with the Notice provisions of this Contract and delivered to AOC Project Director within five Days of the date of receipt of AOC’s letter.
15.7.3 AOC will give Notice to Contractor as to AOC Project Director’s final disposition of AOC’s concerns.
15.7.4 Upon receipt of Notice of final disposition by Contractor, AOC reserves the right to suspend all, or part of, the Contract, and to withhold further payments, or to prohibit Contractor from incurring additional obligations of funds during investigation of the alleged compliance breach and pending corrective action, if necessary, by Contractor or a decision by AOC to terminate in accordance with Section 20.1 below.
Suspension Due to Breach. In the event the WSLCB, in its reasonable judgment, determines that a material breach of Contract has occurred in Contractor's compliance with the conditions of this Contract or if the WSLCB has reason to believe that fraud, abuse, malfeasance, misfeasance or nonfeasance has occurred on the part of Contractor under this Contract, and the situation is deemed by the WSLCB to merit corrective action, the following sequential suspension procedure may be implemented by the WSLCB: • The WSLCB will notify Contractor in writing by registered mail to Contractor's last known address with a return receipt to the WSLCB of a perceived compliance breach describing the WSLCB's concerns. • Contractor will respond to the WSLCB's concerns by letter describing proposed corrective actions and proposing completion dates for bringing this Contract into compliance. Such response will be sent by registered mail and delivered to the WSLCB within ten (10) calendar days of the date of receipt of the WSLCB's letter. • The WSLCB will notify Contractor in writing by registered mail to Contractor's last known address with a return receipt to the WSLCB as to the WSLCB's final disposition of the WSLCB's concerns. • Upon receipt of Notice of final disposition by Contractor, the WSLCB reserves the right to suspend all, or part of, this Contract, and to withhold further payments, or to prohibit Contractor from incurring additional obligations of funds during investigation of the alleged compliance breach and pending corrective action, if necessary, by Contractor or a decision by the WSLCB to terminate in accordance with Section 21.2 below.
Suspension Due to Breach. In the event County determines that a breach of Agreement has occurred in Contractor’s compliance with the conditions of this Agreement or if County has reason to believe that fraud, abuse, malfeasance, misfeasance or nonfeasance has occurred on the part of Contractor under this Agreement, and the situation is deemed by County to merit corrective action, the following sequential suspension procedure may be implemented by County:
15.6.1 County will notify Contractor in writing by certified mail to
15.6.2 Contractor will respond to County’s concerns by letter describing
15.6.3 County will notify Contractor in writing by certified mail to
15.6.4 Upon receipt of Notice of final disposition by Contractor, County
Suspension Due to Breach. In the event the Exchange determines that a breach of Agreement has occurred in Contractor’s compliance with the conditions of this Agreement or if the Exchange have reason to believe that fraud, abuse, malfeasance, misfeasance or nonfeasance has occurred on the part of Contractor under this Agreement, and the situation is deemed by the Exchange to merit corrective action, the following sequential suspension procedure may be implemented by the Exchange:
15.7.1 The Exchange Project Director will give Notice to Contractor of a perceived compliance breach describing the Exchange’s concerns.
15.7.2 Contractor will respond to the Exchange Project Director’s concerns by letter describing proposed corrective actions and proposing completion dates for bringing the Agreement into compliance. Such response will be sent in accordance with the Notice provisions of this Agreement and delivered to the Exchange Project Director within five Days of the date of receipt of the Exchange’s letter.
15.7.3 The Exchange will give Notice to Contractor as to the Exchange Project Director’s final disposition of the Exchange’s concerns.
15.7.4 Upon receipt of Notice of final disposition by Contractor, the Exchange reserves the right to suspend all, or part of, the Agreement, and to withhold further payments, or to prohibit Contractor from incurring additional obligations of funds during investigation of the alleged compliance breach and pending corrective action, if necessary, by Contractor or a decision by the Exchange to terminate in accordance with Section 21.1 below.
Suspension Due to Breach. In the event the CONSORTIUM determines that a breach of this Agreement has occurred on the part of CONTRACTOR, and the situation is deemed by the CONSORTIUM to merit corrective action, the following sequential suspension procedure will be implemented:
14.4.1 The CONSORTIUM shall send a Notice to CONTRACTOR in writing to CONTRACTOR’s Notice address of a perceived compliance breach describing the CONSORTIUM’s concerns.
14.4.2 CONTRACTOR shall respond to the CONSORTIUM’s concerns in writing describing proposed corrective actions and proposing completion dates for bringing the CONTRACTOR’s performance under this Agreement into compliance. Such response will be sent within ten (10) days of the date of receipt of the CONSORTIUM’s Notice described in Section 14.4.1.
14.4.3 The CONSORTIUM shall notify CONTRACTOR in writing within ten (10) days as to the CONSORTIUM’s final disposition of its concerns.
14.4.4 Upon receipt of notice of final disposition by CONTRACTOR, the CONSORTIUM reserves the right to suspend all, or part of, the Agreement for a period no greater than thirty (30) calendar days, and to withhold further payments, or to prohibit CONTRACTOR from incurring additional obligations of funds during investigation of the alleged compliance breach and pending corrective action, if necessary, by CONTRACTOR or a decision by the CONSORTIUM to terminate in accordance with Section 16.1 below.
Suspension Due to Breach. Xxx.xxx, in its sole and exclusive discretion, may immediately take corrective action, including, but not limited to, removal of all or a portion of the Content on your Website and suspension and/or termination of your Web Hosting Services, in the event of notice of any possible violation of this Agreement or the AUP by you or your end users. You agree that Xxx.xxx will have no liability to you due to any corrective action that Xxx.xxx may take and that you will not be entitled to a refund of any fees paid in advance prior to the corrective action. You agree to the additional restrictions of use provided by Xxx.xxx in conjunction with the Web Hosting Services that are found in other Schedules to this Agreement.
Suspension Due to Breach. In the event CalACES CONSORTIUM determines that a breach of this Agreement has occurred on the part of CONTRACTOR under this Agreement, and the situation is deemed by CalACES CONSORTIUM to merit corrective action, the following sequential suspension procedure may be implemented by CalACES CONSORTIUM:
13.5.1 CalACES CONSORTIUM shall send a Notice to CONTRACTOR in writing by certified mail or other hand deliveries to CONTRACTOR’s Notice address below the signatures to the Agreement with a return receipt to CalACES CONSORTIUM of a perceived compliance breach describing CalACES CONSORTIUM’s concerns.
13.5.2 CONTRACTOR shall respond to CalACES CONSORTIUM’s concerns by letter describing proposed corrective actions and proposing completion dates for bringing the Agreement into compliance. Such response will be sent by registered mail or other hand delivery with evidence of receipt acknowledged and delivered to CalACES CONSORTIUM within ten Days of the date of receipt of CalACES CONSORTIUM’s letter.
13.5.3 CalACES CONSORTIUM shall notify CONTRACTOR in writing by certified mail or other hand delivery with evidence of receipt acknowledged to CONTRACTOR’s Notice address with a return receipt to CalACES CONSORTIUM as
13.5.4 Upon receipt of notice of final disposition by CONTRACTOR, CalACES CONSORTIUM reserves the right to suspend all, or part of, the Agreement, and to withhold further payments, or to prohibit CONTRACTOR from incurring additional obligations of funds during investigation of the alleged compliance breach and pending corrective action, if necessary, by CONTRACTOR or a decision by CalACES CONSORTIUM to terminate in accordance with Section 16.1 below.
Suspension Due to Breach. In the event State determines that a breach of Contract has occurred in Contractor’s (including without limitation any Subcontractor’s) compliance with the conditions of this Contract or if State have reason to believe that fraud, abuse, malfeasance, misfeasance or nonfeasance has occurred on the part of Contractor under this Contract, and the situation is deemed by State to merit corrective action, the following sequential suspension procedure may be implemented by State:
17.7.1 State Project Director will give Notice to Contractor of a perceived compliance breach describing State’s concerns.
17.7.2 Contractor will respond to State Project Director’s concerns by letter describing proposed corrective actions and proposing completion dates for bringing the Contract into compliance. Such response will be sent in accordance with the Notice provisions of this Contract and delivered to State Project Director within five Days of the date of receipt of State’s letter.
17.7.3 State will give Notice to Contractor as to State Project Director’s final disposition of State’s concerns.
17.7.4 Upon receipt of Notice of final disposition by Contractor, State reserves the right to suspend all, or part of, the Contract, and to withhold further payments, or to prohibit Contractor from incurring additional obligations of funds during investigation of the alleged compliance breach and pending corrective action, if necessary, by Contractor or a decision by State to terminate in accordance with Section 22.1 below.
Suspension Due to Breach. In the event AOC determines that a breach of Contract has occurred in Contractor’s (including without limitation any Subcontractor’s) compliance with the conditions of this Contract or if AOC have reason to believe that fraud, abuse, malfeasance, misfeasance or nonfeasance has occurred on the part of Contractor under this Contract, and the situation is deemed by AOC to merit corrective action, the following sequential suspension procedure may be implemented by AOC:
