Tenant’s Signage Tenant shall be entitled to install the following signage in connection with Tenant's lease of the Premises (collectively, the "Tenant's Signage"):
Construction of Tenant Improvements by Tenants Agents Construction Contract; Cost Budget. Prior to Tenant's execution of ---------------------------------- the construction contract and general conditions with Contractor (the "Contract"), Tenant shall submit the Contract to Landlord for its approval, which approval shall not be unreasonably withheld or delayed. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, of the final costs to be incurred, or which have been incurred, as set forth more particularly in Sections 2.2.1.1 through ---------------- 2.2.1.8 above, in connection with the design and construction of the Tenant ------- Improvements to be performed by or at the direction of Tenant or the Contractor (which costs form a basis for the amount of the Contract, if any (the "Final Costs"). Prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with a completion bond in an amount equal to the Final Costs to ensure Landlord of the completion of the Tenant Improvements.
TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.
Tenant’s Signs Except as expressly provided in this Article 32, without Landlord’s prior consent, which Landlord may withhold in its sole discretion, Tenant shall not place on the Premises or on the Building any exterior signs nor any interior signs that are visible from the exterior of the Premises or Building. Tenant shall pay all costs and expenses relating to any such sign approved by Landlord, including without limitation, the cost of the installation and maintenance of the sign. On the date of expiration or earlier termination of this Lease, Tenant, at its sole cost and expense, shall remove all signs and repair any damage caused by such removal. Notwithstanding the foregoing, if the lobby signage rights of Scient Corporation (“Scient”) are relinquished pursuant to the terms of that certain lease between Scient Corporation and Landlord with respect to the 5th and 6th Floors of the Building (the “Scient Premises”), then, subject to obtaining Landlord’s prior written consent as to size, design and location, which consent shall not be unreasonably withhold, Tenant shall have the right to install signage in the lobby of the Building for the remainder of the Term of this Lease so long as such signage shall not be more than 80% as large as the Del Monte signage. Landlord and Tenant agree that the Scient Lease contains the following provision, which shall not be amended by Landlord without obtaining Tenant’s prior written consent, which shall not be unreasonably withheld: “If Tenant [Scient] at any time pursuant to the terms of this Article 17 [of the Scient Lease] either (a) subleases less than the entire Premises [Scient Premises] or (ii) subleases all of the Premises [Scient Premises] to a subtenant, other than Epicentric, whose “creditworthiness” is less than that of Epicentric, such subletting shall result in Tenant’s [Scient’s] relinquishment for the balance of the Term of any rights to signage in the ground floor lobby of the Building as provided in Article 32 [of the Scient Lease]. For purposes of determining “creditworthiness” under this Section 17.10 [of the Scient Lease], the company with the greater net worth shall be considered the more creditworthy company. Net worth shall be determined according to the following formula: assets minus current and long term liabilities equals net worth, as determined according to generally accepted accounting principles.”
Landlord’s General Conditions for Tenant’s Agents and Tenant Improvement Work Tenant’s and Tenant’s Agent’s construction of the Tenant Improvements shall comply with the following: (i) the Tenant Improvements shall be constructed in strict accordance with the Approved Working Drawings; (ii) Tenant’s Agents shall submit schedules of all work relating to the Tenant’s Improvements to Contractor and Contractor shall, within five (5) business days of receipt thereof, inform Tenant’s Agents of any changes which are necessary thereto, and Tenant’s Agents shall adhere to such corrected schedule; and (iii) Tenant shall abide by all rules made by Landlord’s Building manager with respect to the use of freight, loading dock and service elevators, storage of materials, coordination of work with the contractors of other tenants, and any other matter in connection with this Tenant Work Letter, including, without limitation, the construction of the Tenant Improvements.
Tenant’s Repairs and Maintenance Tenant covenants and agrees that, from and after the date that possession of the Premises is delivered to Tenant and until the end of the Lease Term, Tenant will keep neat and clean and maintain in good order, condition and repair the Premises and every part thereof, excepting only for those repairs for which Landlord is responsible under the terms of Article VII of this Lease and damage by fire or casualty and as a consequence of the exercise of the power of eminent domain. Tenant shall not permit or commit any waste, and Tenant shall be responsible for the cost of repairs which may be made necessary by reason of damages to common areas in the Building or Prudential Center by Tenant, Tenant’s agents, employees, contractors, sublessees, licensees, concessionaires or invitees. Tenant shall maintain all its equipment, furniture and furnishings in good order and repair. If repairs are required to be made by Tenant pursuant to the terms hereof, Landlord may demand that Tenant make the same forthwith, and if Tenant refuses or neglects to commence such repairs and complete the same with reasonable dispatch after such demand, Landlord may (but shall not be required to do so) make or cause such repairs to be made and shall not be responsible to Tenant for any loss or damage that may accrue to Tenant’s stock or business by reason thereof. If Landlord makes or causes such repairs to be made, Tenant agrees that Tenant will forthwith on demand, pay to Landlord as Additional Rent the cost thereof together with interest thereon at the rate specified in Section 16.21, and if Tenant shall default in such payment, Landlord shall have the remedies provided for non-payment of rent or other charges payable hereunder.
LANDLORD'S MAINTENANCE Subject to the provisions of Articles 4 and 14, Landlord shall, as an Operating Expense, maintain and make necessary repairs to the foundations, roofs, exterior walls, and the structural elements of the Building, the electrical, plumbing, heating, ventilating, air-conditioning, mechanical, communication, security and the fire and life safety systems of the Building and those corridors, washrooms and lobbies which are Common Areas of the Building, except that: (a) Landlord shall not be responsible for the maintenance or repair of any floor or wall coverings in the Premises or any of such systems which are located within the Premises and are supplemental or special to the Building’s standard systems; and (b) the cost of performing any of said maintenance or repairs whether to the Premises or to the Building caused by the negligence of Tenant, its employees, agents, servants, licensees, subtenants, contractors or invitees, shall be paid by Tenant, subject to the waivers set forth in Section 16.4. Landlord shall not be liable to Tenant for any expense, injury, loss or damage resulting from work done in or upon, or in connection with the use of, any adjacent or nearby building, land, street or alley.
TENANT'S IMPROVEMENTS If the Lessor is the Insuring Party, the Lessor shall not be required to insure Lessee Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease. If Lessee is the Insuring Party, the policy carried by Lessee under this Paragraph 8.3 shall insure Lessee Owned Alterations and Utility Installations.
Tenant’s Work During the Term Tenant may not perform any work, alterations, installations, additions, improvements, structural repairs or restorations to the Property (“Tenant’s Work”) without the prior written consent of Landlord which (i) in the case of alterations, additions, installations or improvements of a structural nature or involving the Building systems, may be granted or withheld by Landlord in its sole and absolute discretion and (ii) in the case of alterations or improvements of a non-structural nature or not involving Building systems, shall not be unreasonably withheld or delayed. In connection with such consent, Tenant shall submit to Landlord such detailed plans, specifications, drawings and other materials reasonably requested by Landlord. Tenant may make such non-structural alterations and perform work of a decorative nature without Xxxxxxxx’s prior written consent. At Tenant’s sole cost, Xxxxxxxx agrees to cooperate with Xxxxxx (including signing applications) in obtaining any necessary permits for any Tenant’s Work that Xxxxxx is permitted to make hereunder. In all cases the Tenant’s Work shall be performed at Tenant’s sole cost and expense and by contractors selected by Xxxxxx. Tenant agrees that the Tenant’s plans and specifications shall be in compliance with applicable laws, rules and regulations, that Tenant shall not commence construction until it obtains (if required) a building permit for Tenant’s Work, and that such Tenant’s Work shall be performed in accordance with the building permit, in compliance with applicable law and in accordance with the Tenant’s plans and specifications. As a condition of approving such Tenant's Work the Landlord may require the Tenant to maintain such additional insurance coverages (in addition to those required in Article 8 hereof) as the Landlord may reasonably require.
TENANT'S USE OF PREMISES Tenant agrees that the Premises shall be used and occupied only for the Permitted Uses specified in the Basic Provisions, and for no other use. Tenant shall not use or permit the Premises to be used for any other purpose or purposes or under any other trade name whatsoever without the prior written consent of Landlord, which consent may be withheld or granted at Landlord’s sole and absolute discretion. Tenant’s use of the Premises shall be in compliance with and subject to all applicable governmental laws, ordinances, statutes, orders and regulations and any CC&R’s (including payments thereunder, if any) or any supplement thereto recorded in any official or public records with respect to the Project or any portion thereof. In the event Landlord desires to record CC&R’s against the Project after the date of full execution of this Lease, Landlord shall, at its option, either (i) obtain Tenant’s consent thereto, which consent shall not be unreasonably withheld (provided Tenant’s material rights and obligations under the Lease are not impaired, but provided that any provisions of such CC&R’s which require Tenant to pay reasonable assessments such as for common area maintenance and landscaping shall not be deemed to impair Tenant’s material rights and obligations under this Lease), conditioned or delayed or (ii) elect not to obtain Tenant’s consent thereto, in which event the provisions of this Lease shall prevail over any conflicting provisions of the CC&R’s. Tenant further covenants and agrees that it will not use or suffer or permit any person or persons to use the Premises or any part thereof for conducting therein a second-hand store, auction, distress or fire sale or bankruptcy or going-out-of- business sale, or for any use or purpose in violation of the laws of the United States of America or the laws, ordinances, regulations and requirements of the State, County and City wherein the Premises are situated, including in violation of any of the permitted use restrictions outlined in Exhibit N. Tenant, at Tenant’s sole cost and expense, shall comply with the rules and regulations attached hereto as Attachment 1, together with such additional rules and regulations as Landlord may from time to time prescribe. Tenant shall not commit waste; overload the floors or structure of the Building in which the Premises are located; subject the Premises, the Building, the Common Area or the Project to any use which would damage the same or increase the risk of loss or violate any insurance coverage; permit any unreasonable odors, smoke, dust, gas, substances, noise or vibrations to emanate from the Premises, take any action which would constitute a nuisance or would disturb, obstruct or endanger any other tenants, take any action which would abrogate any warranties; or use or allow the Premises to be used for any unlawful purpose. Tenant shall promptly comply with the reasonable require- Landlord’s Initials CZ Tenant’s Initials HZ ments of any board of fire insurance underwriters or other similar body now or hereafter constituted. Tenant shall not do any act which shall in any way encumber the title of Landlord in and to the Premises, the Building or the Project. Tenant further covenants and agrees that during the term hereof the Premises, and every part thereof, shall be kept by Tenant in a first-class, clean and wholesome condition, free of any objectionable noises, odors or nuisances, and that all fire, safety, health and police regulations shall, in all respects and at all times, be fully complied with by Tenant.
