Tenant’s General Contractor. Tenant shall enter into a construction contract with a general contractor selected by Tenant and approved by Landlord (such approval not to be unreasonably withheld, conditioned or delayed) in a form acceptable to Tenant’s representative for the Tenant Work, which shall comply with the provisions of this Section 4 and provide for, among other things, (1) a one-year warranty for all defective Tenant Work; (2) a requirement that Tenant’s Contractor maintain general commercial liability insurance of not less than a combined single limit of $5,000,000 (which may be satisfied by an umbrella policy), naming Landlord, Landlord’s property management company, Landlord’s mortgagee and Tenant as additional insureds; (3) a requirement that the contractor perform the Tenant Work in substantial accordance with the Working Drawings and in a good and workmanlike manner; (4) a requirement that the contractor is responsible for daily cleanup work and final clean up (including removal of debris); and (5) those items described in Section 4.(b) below (collectively, the “Approval Criteria”). Landlord shall have three business days to notify Tenant whether it approves the proposed construction agreements. If Landlord disapproves of the proposed construction agreements, then it shall specify in reasonable detail the reasons for such disapproval, in which case Tenant shall revise the proposed construction agreements to correct the objections and resubmit them to Landlord within five business days after Landlord notifies Tenant of its objections thereto, following which Landlord shall have two business days to notify Tenant whether it approves the revised construction agreements. Landlord shall not unreasonably withhold, condition or delay its approval. Tenant must deliver to Landlord a true, correct and complete copy of the executed construction contract between Tenant and Tenant’s general contractor and all amendments thereto promptly after execution thereof.
Tenant’s General Contractor. Tenant shall be responsible for bidding the Tenant Improvements and selecting the General Contractor (herein so called). Landlord shall have the right to approve the General Contractor and all subcontractors, such approval not to be unreasonably withheld, conditioned or delayed. Without limitation, it will be reasonable for Landlord to disapprove of a contractor or subcontractor on the basis that (i) such contractor or subcontractor is not licensed and bonded, or (ii) Landlord has had previous unsatisfactory experience with such contractor.
Tenant’s General Contractor. Tenant shall enter into a construction contract with a contractor mutually agreeable to Landlord and Tenant, in a form acceptable to Tenant’s representative for the Work.
Tenant’s General Contractor. Tenant shall enter into a construction contract with a general contractor selected by Tenant and approved by Landlord in a form acceptable to Tenant’s representative for the Work, which shall comply with the provisions of this Section 4 and provide for, among other things, (1) a one-year warranty for all defective Work; (2) a requirement that Tenant’s Contractor maintain general commercial liability insurance of not less than a combined single limit of $3,000,000, naming Landlord, Landlord’s property management company, Landlord’s mortgagee and Tenant as additional insureds; (3) a requirement that the contractor perform the Work in substantial accordance with the Working Drawings and in a good and workmanlike manner; (4) a requirement that the contractor is responsible for daily cleanup work and final clean up (including removal of debris); and (5) those items described in Section 4.(b) (collectively, the “Approval Criteria”). Landlord shall have three (3) business days to notify Tenant whether it approves the proposed construction agreements. If Landlord disapproves of the proposed construction agreements, then it shall specify in reasonable detail the reasons for such disapproval, in which case Tenant shall revise the proposed construction agreements to correct the objections and resubmit them to Landlord within two business days after Landlord notifies Tenant of its objections thereto, following which Landlord shall have two business days to notify Tenant whether it approves the revised construction agreements.
Tenant’s General Contractor. Tenant shall enter into a construction contract with a general contractor selected by Xxxxxx and reasonably approved by Landlord in a form acceptable to Tenant’s representative for the Tenant Improvements, which shall comply with the provisions of this Section 5 and provide for, among other things, (a) a one-year warranty for all defective Tenant Improvements; (b) a requirement that Tenant’s contractor maintain commercial general liability insurance of not less than a combined single limit of $5,000,000, naming Landlord, Landlord’s property management company, Landlord’s asset management company, Landlord’s mortgagee, Tenant, and each of their respective affiliates as additional insureds; (c) a requirement that the contractor perform the Tenant Improvements in substantial accordance with plans approved by the applicable governmental authority (and such plans and drawings are specifically referenced and/or itemized in Tenant’s construction contract) and in a good and workmanlike manner; (d) a requirement that the contractor is responsible for daily cleanup work and final clean up (including removal of debris); and (e) those items described in Section 5.2 below (collectively, the “Approval Criteria”).
Tenant’s General Contractor. Tenant, through Tenant's general contractor (who shall first be approved by Landlord, which approval shall not be unreasonably withheld or delayed), shall construct within the Premises those improvements (the "Tenant Improvements") shown on the Tenant's Final Space Plans (including, without limitation, the Tenant Base Building Responsibilities), as approved by the Landlord and Tenant pursuant to Section 2 below. Landlord hereby approves WEI as Tenant's general contractor. All Tenant Improvements shall be constructed pursuant to this Work Letter and shall be performed only by Tenant's general contractor pursuant to a construction contract approved by Landlord as set forth in Section 4.1.1. Tenant shall be responsible for the coordination and supervision of the construction of the Tenant Improvements by Tenant's general contractor. Tenant agrees that Tenant's general contractor shall be licensed and fully insured in the construction of the Tenant Improvements.
Tenant’s General Contractor. Tenant shall enter into a construction contract with a general contractor selected by Tenant in a form acceptable to Tenant's representative for the Work, which shall comply with the provisions of this Section 4 and provide for, among other things, (1) a one-year warranty for all defective Work; (2) a requirement that Tenant's contractor and subcontractor maintains insurance (unless, as it relates to subcontractor’s insurance obligation, Tenant’s contractor is obligated under the construction contract to maintain subguard insurance, in which event this insurance requirement shall only apply Tenant’s contractor) against such risks, in amounts provided in Section 4(c) below with companies in compliance with the guidelines set forth in Section 11(b)(7) of the Lease, each policy covering the general contractor and each architect, each engineer, and further, naming Landlord, Landlord's property management company, Landlord's asset management company, Landlord's Mortgagee, and Tenant as additional insureds; (3) a requirement that the contractor perform the Work in substantial accordance with the Working Drawings and in a good and workmanlike manner; (4) a requirement that the contractor is responsible for daily cleanup work and final clean up (including removal of debris); and (5) those items described in Section 4.(b) (collectively, the "Approved Criteria"). Promptly following Landlord’s written request, Tenant shall provide Landlord with a copy of the construction contract entered into for the Work.
Tenant’s General Contractor. Tenant shall enter into a construction contract with a general contractor selected by Tenant that shall comply with the provisions of this Section 5 and provide for, among other things, (i) a one-year warranty for all defective Work; (ii) a requirement that Tenant’s Contractor maintain insurance in accordance with Landlord’s insurance requirements; (iii) a requirement that the contractor perform the Work in substantial accordance with the Working Drawings and in a good and workmanlike manner; (iv) a requirement that the contractor is responsible for daily cleanup work and final clean up (including removal of debris); and (v) those items described in Section 5.(b) (collectively, the “Approval Criteria”). Tenant agrees to select one of the general contractors listed on Schedule 1. Tenant shall cause its general contractor to select its subcontractors from those listed on Schedule 1 or otherwise approved by Landlord, which approval shall not be unreasonably withheld.
Tenant’s General Contractor. Landlord and Tenant hereby agree that --------------------------- the general contractor to be employed by Tenant in connection with the construction and installation of the Tenant Improvements shall be selected by Tenant after the completion of a competitive bid process designed and implemented by Tenant (the "Tenant's General Contractor"). Not later than ten (10) days after the Date of Lease Landlord shall advise Tenant, in writing, of the name of at least one (1) general contractor with whom Landlord has had satisfactory experience in the past and which Landlord believes to have expertise in connection with the construction of alterations and improvements similar to the Tenant Improvements. Tenant shall provide promptly to Landlord, upon execution and delivery of same, a photocopy of the full and complete contract made between the Tenant's General Contractor and Tenant with respect to the Tenant Improvements, which contract shall be acceptable to Landlord in all respects, in its reasonable judgment.
