Texas Education Code Chapter 22 Contractor Certification for Contractor Employees Introduction Texas Education Code Chapter 22 requires entities that contract with school districts to provide service s to obtain criminal history record information regarding covered employees. Contractors must certify to the district t hat they have complied. Covered employees with disqualifying criminal histories are prohibited from serving at a sch ool district. Definitions: Covered employees: Employees of a contractor or subcontractor who have or will have continuing dutie s related to the service to be performed at the District and have or will have direct contact with students. The District will be the final arbiter of what constitutes direct contact with students. Disqualifying criminal history: Any conviction or other criminal history information designated by the District, or one of the following offenses, if at the time of the o ffense, the victim was under 18 or enrolled in a public school: (a) a felony offense under Title 5, Texas Penal Code; (b) an offense for which a defendant is required to register as a sex offender under Chapter 62, Texas Code of Criminal Procedure; or (c) an equivalent offense under federal law or the laws of another state. I certify that: NONE (Section A) of the employees of Contractor and any subcontractors are covered employees, as defined abo ve. If this box is checked, I further certify that Contractor has taken precautions or imposed conditions to ensure tha t the employees of Contractor and any subcontractor will not become covered employees. Contractor will maintain t hese precautions or conditions throughout the time the contracted services are provided. OR SOME (Section B) or all of the employees of Contractor and any subcontractor are covered employees. If this box is checked, I further certify that: (1) Contractor has obtained all required criminal history record information regarding its covered employees. None of the covered employees has a disqualifying criminal history. (2) If Contractor receives information that a covered employee subsequently has a reported criminal history, Contra ctor will immediately remove the covered employee from contract duties and notify the District in writing within 3 busi ness days. (3) Upon request, Contractor will provide the District with the name and any other requested information of covered employees so that the District may obtain criminal history record information on the covered employees. (4) If the District objects to the assignment of a covered employee on the basis of the covered employee's criminal h istory record information, Contractor agrees to discontinue using that covered employee to provide services at the District. Noncompliance or misrepresentation regarding this certification may be grounds for contract termination. None Texas Business and Commerce Code § 272 Requirements as of 9-1-2017 SB 807 prohibits construction contracts to have provisions requiring the contract to be subject to the laws of anothe r state, to be required to litigate the contract in another state, or to require arbitration in another state. A contract wit h such provisions is voidable. Under this new statute, a “construction contract” includes contracts, subcontracts, or agreements with (among others) architects, engineers, contractors, construction managers, equipment lessors, or materials suppliers. “Construction contracts” are for the design, construction, alteration, renovation, remodeling, or repair of any building or improvement to real property, or for furnishing materials or equipment for the project. The t erm also includes moving, demolition, or excavation. BY RESPONDING TO THIS SOLICITATION, AND WHEN APPLI CABLE, THE PROPOSER AGREES TO COMPLY WITH THE TEXAS BUSINESS AND COMMERCE CODE § 272 WH EN EXECUTING CONTRACTS WITH TIPS MEMBERS THAT ARE TEXAS GOVERNMENT ENTITIES. 7 5 Texas Government Code 2270 Verification Form Texas Government Code 2270 Verification Form Texas 2017 House Xxxx 89 has been signed into law by the governor and as of September 1, 2017 will be codified as Texas Government Code § 2270 and 808 et seq. The relevant section addressed by this form reads as follows: Texas Government Code Sec. 2270.002. PROVISION REQUIRED IN CONTRACT. A governmental entity may not ent er into a contract with a company for goods or services unless the contract contains a written verification from the c ompany that it: (1) does not boycott Israel; and (2) will not boycott Israel during the term of the contract.engaged by ESC Region 8/The Interlocal Purchasing System (TIPS) 0000 Xxxxxxx 000 Xxxxx Xxxxxxxxx,XX,00000 verify by this writing that the above-named company affirms that it (1) does not boycott Israel; and (2) will not boycot t Israel during the term of this contract, or any contract with the above-named Texas governmental entity in the futur e. I further affirm that if our company’s position on this issue is reversed and this affirmation is no longer valid, that t he above-named Texas governmental entity will be notified in writing within one (1) business day and we understand that our company’s failure to affirm and comply with the requirements of Texas Government Code 2270 et seq. shall be grounds for immediate contract termination without penalty to the above-named Texas governmental entity. AND our company is not listed on and we do not do business with companies that are on the the Texas Comptroller of Pu blic Accounts list of Designated Foreign Terrorists Organizations per Texas Gov't Code 2270.0153 found at xxxxx://x xxxxxxxxxx.xxxxx.xxx/xxxxxxxxxx/xxxx/xxxxxxx-xxxxxxxxx.xxx I swear and affirm that the above is true and correct. YES
CERTIFICATION REGARDING BOYCOTTING CERTAIN ENERGY COMPANIES (Texas law as of September 1, 2021) By submitting a proposal to this Solicitation, you certify that you agree, when it is applicable, to the following required by Texas law as of September 1, 2021: If (a) company is not a sole proprietorship; (b) company has ten (10) or more full-time employees; and (c) this contract has a value of $100,000 or more that is to be paid wholly or partly from public funds, the following certification shall apply; otherwise, this certification is not required. Pursuant to Tex. Gov’t Code Ch. 2274 of SB 13 (87th session), the company hereby certifies and verifies that the company, or any wholly owned subsidiary, majority-owned subsidiary, parent company, or affiliate of these entities or business associations, if any, does not boycott energy companies and will not boycott energy companies during the term of the contract. For purposes of this contract, the term “company” shall mean an organization, association, corporation, partnership, joint venture, limited partnership, limited liability partnership, or limited liability company, that exists to make a profit. The term “boycott energy company” shall mean “without an ordinary business purpose, refusing to deal with, terminating business activities with, or otherwise taking any action intended to penalize, inflict economic harm on, or limit commercial relations with a company because the company (a) engages in the exploration, production, utilization, transportation, sale, or manufacturing of fossil fuel-based energy and does not commit or pledge to meet environmental standards beyond applicable federal and state law, or (b) does business with a company described by paragraph (a).” See Tex. Gov’t Code § 809.001(1).
Lodgement of SWS wage assessment agreement C.6.1 All SWS wage assessment agreements under the conditions of this schedule, including the appropriate percentage of the relevant minimum wage to be paid to the employee, must be lodged by the employer with Fair Work Australia.
Provisioning of High Frequency Spectrum and Splitter Space 3.2.1 BellSouth will provide <<customer_name>> with access to the High Frequency Spectrum as follows:
Teaching Staff Assigned to More Than One Building Each Educator who is assigned to more than one building will be evaluated by the appropriate administrator where the individual is assigned most of the time. The principal of each building in which the Educator serves must review and sign the evaluation, and may add written comments. In cases where there is no predominate assignment, the superintendent will determine who the primary evaluator will be.
OGS Centralized Contract Modifications OGS, an Authorized User, or the Contractor may suggest modifications to the Centralized Contract or its Appendices. Except as specifically provided herein, modifications to the terms and conditions set forth herein may only be made with mutual written agreement of the Parties. Modifications may take the form of an update or an amendment. “
Staffing Plan 8.l The Board and the Association agree that optimum class size is an important aspect of the effective educational program. The Polk County School Staffing Plan shall be constructed each year according to the procedures set forth in Board Policy and, upon adoption, shall become Board Policy.
Treatment of Unallowable Costs Previously Submitted for Payment Defendants further agree that within 90 days of the Effective Date of this Agreement they shall identify to applicable Medicare and TRICARE fiscal intermediaries, carriers, and/or contractors, and Medicaid and FEHBP fiscal agents, any Unallowable Costs (as defined in this Paragraph) included in payments previously sought from the United States, or any State Medicaid program, including, but not limited to, payments sought in any cost reports, cost statements, information reports, or payment requests already submitted by Defendants or any of their subsidiaries or affiliates, and shall request, and agree, that such cost reports, cost statements, information reports, or payment requests, even if already settled, be adjusted to account for the effect of the inclusion of the Unallowable Costs. Defendants agree that the United States, at a minimum, shall be entitled to recoup from Defendants any overpayment plus applicable interest and penalties as a result of the inclusion of such Unallowable Costs on previously-submitted cost reports, information reports, cost statements, or requests for payment. Any payments due after the adjustments have been made shall be paid to the United States pursuant to the direction of the Department of Justice and/or the affected agencies. The United States reserves its rights to disagree with any calculations submitted by Defendants or any of their subsidiaries or affiliates on the effect of inclusion of Unallowable Costs (as defined in this Paragraph) on Defendants or any of their subsidiaries or affiliates’ cost reports, cost statements, or information reports.
Disclosure Statement for Xxxxxxxxx Education Savings Accounts 1. Who is Eligible for a Xxxxxxxxx Education Savings Account? Anyone may contribute to a Xxxxxxxxx Education Savings Account regardless of his or her relationship to the beneficiary. The beneficiary of a Xxxxxxxxx Education Savings Account
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
