SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
Teaching Experience Recognized Years of Experience: Uncredited Experience:
Termination Payment for Force Majeure Event 30.9.1 If Termination is on account of a Non-Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to 55% (fifty five per cent) of the Debt Due less Insurance Cover.
30.9.2 If Termination is on account of an Indirect Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount equal to:
(a) 55% of the Debt Due less Insurance Cover; provided that if any insurance claims forming part of the Insurance Cover are not admitted and paid, then 80% (eighty per cent) of such unpaid claims shall be included in the computation of Debt Due;
(b) 60.5% (sixty point five per cent) of the Adjusted Equity; and
30.9.3 If Termination is on account of a Political Event, the Authority shall make a Termination Payment to the Concessionaire in an amount that would be payable under Clause 33.3.2 as if it were Authority’s Default.
Termination for Catastrophe In event of Catastrophic Damage, this contract may be modified un- der B8.32, following rate redetermination under B3.32, or terminated under this Subsection. Such termination shall not be considered a termination under B8.34.
Abuse, Neglect, Exploitation Grantee will;
a. take all steps necessary, to protect the health, safety and welfare of its clients and participants.
b. develop and implement written policies and procedures for abuse, neglect and exploitation.
c. notify appropriate authorities of any allegations of abuse, neglect, or exploitation as required by 25 TAC § 448.703.
Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.
Force Majeure Event After giving effect to any applicable provision, disruption fallback or remedy specified in, or pursuant to, the relevant Confirmation or elsewhere in this Agreement, by reason of force majeure or act of state occurring after a Transaction is entered into, on any day:—
(1) the Office through which such party (which will be the Affected Party) makes and receives payments or deliveries with respect to such Transaction is prevented from performing any absolute or contingent obligation to make a payment or delivery in respect of such Transaction, from receiving a payment or delivery in respect of such Transaction or from complying with any other material provision of this Agreement relating to such Transaction (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such Office so to perform, receive or comply (or it would be impossible or impracticable for such Office so to perform, receive or comply if such payment, delivery or compliance were required on that day); or
(2) such party or any Credit Support Provider of such party (which will be the Affected Party) is prevented from performing any absolute or contingent obligation to make a payment or delivery which such party or Credit Support Provider has under any Credit Support Document relating to such Transaction, from receiving a payment or delivery under such Credit Support Document or from complying with any other material provision of such Credit Support Document (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply (or it would be impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply if such payment, delivery or compliance were required on that day), so long as the force majeure or act of state is beyond the control of such Office, such party or such Credit Support Provider, as appropriate, and such Office, party or Credit Support Provider could not, after using all reasonable efforts (which will not require such party or Credit Support Provider to incur a loss, other than immaterial, incidental expenses), overcome such prevention, impossibility or impracticability;
POST-REVIEW DISCOVERIES If, during the implementation of an undertaking, a previously unidentified property that may be eligible for inclusion in the National Register is encountered, or a known historic property may be affected in an unanticipated manner, the Agency Official shall follow 36 C.F.R. § 800.13(b).
A. In the event that previously unidentified archeological sites or human remains are discovered during project construction, that portion of the project shall stop immediately and the project manager shall take appropriate steps to immediately secure the site, and shall notify the Agency Official within 48 hours. The Agency Official shall immediately notify the SHPO/THPO, Tribes, and other relevant consulting parties including descendent communities.
B. If human remains are discovered, they shall be respectfully covered over and protected. In addition, the project manager shall immediately notify local and/or state law enforcement authorities including medical examiner or coroner, pursuant to local and state law.
C. The Agency Official shall consult with the SHPO/THPO and Tribes or other descendent community representatives to determine if the discovered site appears eligible for the National Register. If it does appear eligible, the Agency Official shall submit a treatment plan for the avoidance, protection, recovery of information, or destruction without data recovery to the SHPO for review and comment. The treatment plan shall be consistent with the ACHP’s handbook Treatment of Archaeological Properties and subsequent amendments and SHPO Human Remains Discovery Protocol. If human remains are discovered, the treatment plan shall follow the guidance in Advisory Council on Historic Preservation Policy Statement Regarding Treatment of Burial Sites, Human Remains and Funerary Objects, including appropriate consultation with descendent communities. Avoidance and preservation in place are the preferred options for treating human remains.
D. The Agency Official shall notify relevant consulting parties of the unanticipated discovery and provide the proposed treatment plan for their comment. Construction work in the area of the discovery shall not continue until the plan has been accepted by SHPO/THPO and implemented.
E. An undertaking that may affect a human burial site shall comply with provisions of New York State and local laws, the terms of this Agreement notwithstanding.
Termination for Force Majeure 15.5.1. The License Agreement may be terminated for Force Majeure Reasons as specified in Article -14.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
